Upload
helen-rose
View
213
Download
0
Embed Size (px)
Citation preview
c om p u t e r l aw & s e c u r i t y r e v i ew 2 6 ( 2 0 1 0 ) 3 1 7e3 1 9
ava i lab le at www.sc ienced i rec t . com
www.compseconl ine .com/publ i ca t ions /prodc law.h tm
Case comment: BSkyB v. EDS [2010] EWHC 86 (TCC) case no:HT-06-311 26.01.2010
Helen Rose
Bristows, London, UK
Keywords:
BSkyB v. EDS
Fraudulent misrepresentation
IT systems contracts
0267-3649/$ e see front matter ª 2010 Bristodoi:10.1016/j.clsr.2010.03.008
a b s t r a c t
The Technology and Construction Court has issued its long-awaited decision in the epic
court battle between BSkyB and EDS. Mr Justice Ramsey found that EDS had fraudulently
induced Sky into a £54 million contract for a new customer relationship management
(CRM) system. Since judgment was given, EDS has been ordered to pay Sky £270 million in
damages and interest.
ª 2010 Bristows. Published by Elsevier Ltd. All rights reserved.
1. Background to the dispute persuaded on the basis of the plan to continue with EDS as
Sky’s CRM project was by no means unusual as an IT systems
development and integration project that ran into difficulties
over delays and everincreasing costs. It is more unusual in
that those disputes have rarely come to court. In its claim
against EDS, BSkyB sought over £700 million in damages and
alleged fraud, misrepresentation and breach of contract.
Below, the background to the disputes is summarised, and key
findings from the 468 page judgment are highlighted.
In 2000, Sky identified an urgent need to update its
customer relationship management system which had been
built up over a number of years. Sky was concerned about
the ability of the existing system to deal with an increasing
number of customers. A new, enhanced CRM system would
lead both to costs savings and to increased profits resulting
from a decline in the number of dissatisfied customers
leaving Sky.
Sky issued an Invitation to Tender for a contract to build
and implement a new “world class” contact centre for Sky and
to implement the new system in existing call centres.
Suppliers including EDS and PWC put in formal responses to
the ITT. After further commercial discussion EDSwas selected
as the preferred supplier. In November 2000, EDS entered into
a contract with Sky for delivery of the new CRM system to go
live 9 months later. Delays in implementation of the project
arose. EDS provided Sky with a “catch-up” plan and Sky was
ws. Published by Elsevie
systems integrator. In July 2001, the parties amended the
contract to reflect the new plan but further delays arose and,
as a result, Sky decided to take over EDS’s role as systems
integrator.
Ultimately, Sky provided the CRM system itself. The project
was completed 4 years late and more than £2 million over
budget. Sky claimed damages of over £709 million from EDS
2. The misrepresentation claims
Sky alleged that EDS had made various misrepresentations
that had induced Sky to enter into the contract with EDS for
delivery of the CRM system. Sky claimed that those false
statements were made fraudulently or, in the alternative,
that they were made negligently. Sky also alleged that, after
delays arose in delivery of the project, Sky was induced to
enter into an amendment to the contract by EDS’s negligent
misrepresentations.
Theallegationof fraud, as opposed tonegligence,wascrucial
because EDS’s liability for negligence under the contract was
capped at £30 million. In addition, an exclusion of certain cate-
gories of loss, including loss of anticipated savings and loss of
profits, applied to EDS’s liability for negligence. By contrast,
EDS’s liability for fraudulent misrepresentation was unlimited.
Indeed,onthebasisofexistingcase law, thesafestapproachisto
r Ltd. All rights reserved.
c om p u t e r l aw & s e c u r i t y r e v i ew 2 6 ( 2 0 1 0 ) 3 1 7e3 1 9318
draft on the basis that a clause purporting to exclude or limit
liability for fraud will not be enforced by the courts.
2.1. The fraudulent misrepresentation e “We can deliveron time.”
Mr Justice Ramsey found that there was an implied represen-
tation by EDS that it believed it could deliver the new CRM
systemon time andhad reasonable grounds for so believing.He
hadnodoubt that statementsmadebyEDS in its response Sky’s
ITT and in subsequent project plans amounted to representa-
tions by EDS that it held the opinion that it could achieve go-live
of the system by 31 July 2001. The response included references
to EDS providing the system “on time” and “within the required
timescales” and included project plans showing go live occur-
ring on 31 July 2001 or, after later revisions, on 6 August 2001.
Mr Justice Ramsey also found that EDS made an implied
representation that it had carried out a proper estimate of the
time required to complete the project and had reasonable
grounds for holding the opinion that go-live by the specified
date was achievable. In the context of the procurement
process, whereby Sky hadmade clear that ability to achieve go
live within 9 months was a requirement for selection, Sky
would reasonably have understood that the representations
made by EDS about ability to meet timescales were made on
the basis of proper estimates and on reasonable grounds.
In fact, key employee Joe Galloway, described by the court
as “the mastermind behind EDS’s Response to the ITT”, did
not believe that EDS could deliver on time, had made no
calculations supporting such a belief and had been told by
colleagues that the timescales could not be met. There were
no reasonable grounds for a statement that EDS believed it
could deliver on time, so that the implied representation that
there were such grounds was false.
Not only was the representation false, it was also made
dishonestly. Similar timescales submitted by other bidders for
different packages did not suggest to the court that EDS’s
estimate of timescales was honestly made. EDS’s case on
dishonesty was not helped by the fact that Joe Galloway was
found to have lied repeatedly in court about his qualifications
and to have forged emails supposedly sent to Sky, so that his
credibility as a witnesswas “completely destroyed”. Mr Justice
Ramsey found that Joe Galloway had approached the whole
question of time to achieve go live in a “cavalier fashion” and
had ignored the need for analysis. He had simply told Sky
what it wanted to hear with respect to timescales. Sky did not
realise that EDS had carried out no proper planning process
with respect to timescales and was induced to enter into the
contract by the fraudulent representations.
The successful claim in fraudmeant that the liability cap of
£30 million did not apply to Sky’s claims for losses suffered by
it as a result of having been induced to contract with EDS.
2.2. The negligent misrepresentation e “We can stilldeliver.”
Again, EDS was held impliedly to have represented that the
revised plan for completion of the project by July 2002
produced by it and provided to Sky was achievable and had
been the product of proper analysis and re-planning. Sky was
persuaded by that representation to enter into an agreement
amending the contract and settling existing claims for breach
of it. However, in this case, the misrepresentation was negli-
gently rather than dishonestly made. Therefore, the liability
cap in the prime contract operated to limit EDS’s liability.
2.3. The failed misrepresentation claims
The court rejected Sky’s other allegations of misrepresenta-
tions against EDS concerning costs, availability/skills of
resources, and the technology and methodologies to be used.
For example, the court found that there had been no misrep-
resentation by EDS as to cost because, in estimating a budget
of £54 million for the project in its tender documents, EDS had
carried out a proper analysis of the cost of completing the
project and therefore had reasonable grounds for holding the
opinion that it could and would deliver the project within that
budget. This contrasted with the position with respect to
estimates of time required to complete the project, where no
proper analysis had been carried out. It is interesting that the
court took a fairly relaxed view of the extent of analysis
required to be carried out as the basis for a reasonably held
opinion that a costs estimate could be met. Mr Justice Ramsey
acknowledged that the process was fairly informal and to
some extent necessarily took a “broad brush” approach but
rejected Sky’s submissions that a more detailed and rigorous
analysis of likely costs and resources required ought to have
been carried out.
3. Mitigation of losses
EDS alleged that Sky failed to act reasonably to mitigate its
losses. The parties’ IT experts agreed, and the court found that
therewas a large gap between the effort and time taken by Sky
to complete the CRM project and the effort and time that
would have been expended by a competent systems inte-
grator. However, the court found that Sky had acted reason-
ably in its conduct of the project and rejected the suggestion
that any difference between Sky’s performance and that of
a competent systems integrator would establish that Sky had
acted unreasonably. Neither did Sky act unreasonably in
choosing to prioritise initial implementation of a version of
the CRM systemwith less than the full expected functionality.
4. Liability to and of corporate groupmembers
It was decided that no duty of care should be imposed upon
EDS’s parent company (EDS Corporation) in favour of BSkyB or
its subsidiary (Sky Subscribers Services Limited (SSSL)), or
upon EDS Limited in favour of BSkyBwhichwould circumvent
or escape the contractual exclusions or limitations of liability
in place between the contracting parties, EDS Limited and
SSSL. The respective parent companies had been involved in
the bid process and Sky alleged that negligent misrepresen-
tations had been made by EDS Corporation to BSkyB.
However, the court decided that no duty of care on which
liability in negligence could be based arosewith respect to EDS
c om p u t e r l aw & s e c u r i t y r e v i ew 2 6 ( 2 0 1 0 ) 3 1 7e3 1 9 319
Corporation or in favour of BSkyB. The contractual structure
decided upon by the parties, with EDS Limited contracting
with SSSL to provide the system subject to agreed exclusions
and limitations of liability, prevented any such duty of care
arising which would circumvent those exclusions and
limitations. This result is a pragmatic one andwill be a relief to
contracting parties who may deal (before or after contracting)
with employees of various members of a group of companies
with little distinction being drawn between them.
5. Contractual interpretation issues
In deciding Sky’s claims, the court decided some points on
interpretation of the contracts which should be borne inmind
by those drafting IT systems contracts (or indeed any
contracts for services).
� The “entire agreement” clause in the prime contract did not
exclude EDS’s liability for negligent pre-contractual
misrepresentations. A statement that the contract “super-
seded all previous representations between the parties” did
not exclude liability for misrepresentations inducing a party
to enter into the contract in the first place. Neither did
a statement that the clause did not exclude liability for
fraudulent misrepresentation imply that the clause did
exclude liability for negligent misrepresentation. A clear
acknowledgement that the parties had not relied on any
representations when entering into the contract was
needed to exclude liability for negligentmisrepresentations.
The clause, as drafted, did not go far enough.
� EDS’s argument that an interim settlement which settled
then-existing claims for breach of contract had also settled
claims for misrepresentation was rejected. If the parties to
a settlement agreement mean to “wipe the slate clean” with
respect to all potential claims, they must make that inten-
tion clear.
� A Memorandum of Understanding marked ‘subject to
contract’ and signed by the parties was not a legally binding
agreement e the parties had clearly contemplated that
a revised contract would be entered into. Once Sky took over
as systems integrator, EDS and Sky proceeded on the basis
of the terms set out in the Memorandum but they did so “at
risk” pending execution of a binding agreement giving effect
to its terms. No such agreement was ever entered into but
the court held that this was because the commercial
impetus to agree and sign a revised contract was lost once
the Memorandum was in place. If any aspects of a letter of
intent or heads of terms or other document capturing
principles intended to form the basis of a future agreement
are intended to be legally binding (for example, confidenti-
ality provisions or interim payment terms) this should be
expressly stated in the document.
6. Conclusion
Before judgment, Sky’s claims for fraud had raised concerns
that the decision could lead to an increased “legalisation” of
tender processes. With the threat of unlimited liability for
fraudulent misrepresentations looming over them, suppliers
might take a defensive, overly cautious, attitude to submitting
bids. In turn, this attitude might lead to an increase in bid
costs which would be passed on to customers or even cause
a decline in the number of suppliers willing to bid for certain
contracts at all.
In the event, Sky’s claims for fraud succeeded where the
court found that no proper process had been gone through at
all to support the relevant statements made in a response to
ITT and the supplier knew that this was the case. The result is
not surprising and in its analysis the court took into account
the difficulties of providing completely accurate projections at
the bid stage where requirements are unclear. Therefore, the
likelihood of a drastic change in suppliers’ approaches to
bidding for work should not be over-estimated. Of course,
suppliers will need to take care when giving estimates of time,
costs and statements as to capability to deliver a project. Such
statementsmust be carefully considered,must be supportable
and the basis for them must be recorded.
The case acts as a reminder of the importance of care in
drafting exclusions and limitations of liability. Yes, EDS is
liable to pay Sky damages of over £200 million. But the
amount of that liability is attributable to the court’s finding
that EDS acted dishonestly. If Sky’s fraud claim had failed,
with EDS found liable only for negligent misrepresentation
and breach of contract, EDS would have succeeded in relying
on the limitations and exclusions of liability in the contract
such that its liability would have been capped at £30 million,
with liability for loss of profits and loss of anticipated savings
totally excluded. The gulf between the level of damages
obtained by Sky and that which would have been obtained
had the liability cap applied may encourage customers to
seek to achieve the same result without the burden of
proving fraud. Those customers in a strong negotiating
position may seek to include specific key representations in
their contracts and then to carve liability for breach of these
out of the cap. This approach would avoid the need to show
fraud in order to reach the result achieved by Sky in this case.
Helen Rose ([email protected]) Associate, Bristows,
London, UK.