14
#+> l;- -; EXHIBIT 4 The School Board of Broward County, Florida Procurement & Warehousing Services Department 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- . _1_= Y'' Document OO52O: Agreement Form THIS AGREEMENT made and entered into this 19th day of December. 2O17 by and between THE SCHOOL BOARD OF BROWARD COUNTT, FLORIDA (Hereinafter referred to as "Owner" and LEGO CONSTRUCTION CO. (Hereinafter referred to as "Contractor") WHEREAS, Owner is the owner of certain real property located in Broward County and Owner desires to have: Construction of Renovations at Coconut Creek Elementar5r School, including, but not limited to reroofing, replacement of fire alarm system, provision of new fire sprinkler system, replacement of air conditioning equipment and controls, renovation of media center and adjacent toilets, replacement of aluminum storefront entrances, replacement of exterior lighting fixtures, and related improvements. Project / Bid No.: Location No: Project Title: Facility Name: P.0014 t3 I t7-21 lC REBrD I42I Renovations Coconut Creek Elementary School Constructed pursuant to drawings, specifications and other design documents prepared by Jorge A. Gutierrez, Architect. (Hereinafter referred to as Project Consultant). WHEREAS, the Contractor is desirous of performing the Work in accordance with the Contract Documents and all applicable laws, codes and ordinances. NOW THEREFORE, in exchange for the mutual covenants and promises set forth herein and the sums of money agreed to be paid by the Owner to Contractor, the parties agree as follows: ARTICLE 1. AGREEMENT 1.01 This Construction Contract, along with the Contract Documents consisting of the Agreement Form, M/WBE Program Requirements, Documents contained in the Project Manual, General and Supplementar5r Conditions, Addenda, Drawings, Specifications, and modifications issued after execution of the Contract embodies the entire agreement 'llte School Boalcl of Browarcl Counff, Floricla Agreement Forn for Hard Bicl May 18, 2016 Document OO52O Page 1 of 13

l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

  • Upload
    others

  • View
    1

  • Download
    0

Embed Size (px)

Citation preview

Page 1: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

#+>l;-

-;

EXHIBIT 4The School Board of Broward County, Florida

Procurement & Warehousing Services Department7720 W. Oakland Park Blvd., Suite 323

Sunrise, Florida 33351 175,41321-O5O5=-

. _1_=Y''Document OO52O: Agreement Form

THIS AGREEMENT made and entered into this 19th day of December. 2O17 by and between

THE SCHOOL BOARD OF BROWARD COUNTT, FLORIDA

(Hereinafter referred to as "Owner" and

LEGO CONSTRUCTION CO.

(Hereinafter referred to as "Contractor")

WHEREAS, Owner is the owner of certain real property located in Broward County and Ownerdesires to have:

Construction of Renovations at Coconut Creek Elementar5r School, including, but not limitedto reroofing, replacement of fire alarm system, provision of new fire sprinkler system,replacement of air conditioning equipment and controls, renovation of media center andadjacent toilets, replacement of aluminum storefront entrances, replacement of exteriorlighting fixtures, and related improvements.

Project / Bid No.:Location No:Project Title:

Facility Name:

P.0014 t3 I t7-21 lC REBrDI42IRenovationsCoconut Creek Elementary School

Constructed pursuant to drawings, specifications and other design documents prepared by JorgeA. Gutierrez, Architect. (Hereinafter referred to as Project Consultant).

WHEREAS, the Contractor is desirous of performing the Work in accordance with the ContractDocuments and all applicable laws, codes and ordinances.

NOW THEREFORE, in exchange for the mutual covenants and promises set forth herein and thesums of money agreed to be paid by the Owner to Contractor, the parties agree as follows:

ARTICLE 1. AGREEMENT

1.01 This Construction Contract, along with the Contract Documents consisting of theAgreement Form, M/WBE Program Requirements, Documents contained in the ProjectManual, General and Supplementar5r Conditions, Addenda, Drawings, Specifications,and modifications issued after execution of the Contract embodies the entire agreement

'llte School Boalcl of Browarcl Counff, FloriclaAgreement Forn for Hard BiclMay 18, 2016

Document OO52O

Page 1 of 13

Page 2: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

7.O2

1.O3

between Owner and Contractor and supersedes all other writings, oral agreements, orrepresentations.

The parties shall not be bound by or be liable for any statement, representation,promise, inducement or understanding of any kind or nature not set forth herein.

NO CHANGES, AMENDMENTS OR MODIFICATIONS OF ANY OF THE TERMS ORCONDITIONS OF THE CONTRACT SHALL BE VALID UNLESS REDUCED TO WRITINGAND SIGNED BY BOTH PARTIES.

ARTICLE 2. ENUMERATION OF THE CONTRACT DOCUMENTS.

2.Al The Contract Documents consisting of the Agreement Form, M/WBE ProgramRequirements, Documents contained in the Project Manual, General andSupplementary Conditions, Drawings, Specifications, and all Addenda andmodifications issued after execution of the Contract thereto together form the Contract,and they are fully a part of the Contract as if written herein word for word. The followingis an enumeration of the Drawings and Project Manual for this Project:

2.O2 The Drawings:

Drawing DrawingNumber TitleG-001G-002A- 101A-lo2A- 103

AA-101AA-102AA-103AA-104AA-105AA-106AA-tO7AA-201AA-202AB-101AB-102AB-103AB-104AC-101AD-101AE-101AF-301AF-302AF-303AF-304AF-305AF-306AF-307

COVER, LOCATION MAPGENERAL NOTES AND INDEX SHEETBUILDING PLAN OVERALLLIFE SAFETY PLAN BUILDING 1

LIFE SAFETY PLAN BUILDING 2, 3 AND 85DEMOLITION FLOOR PLAN BUILDING NO. 1 AREA AFLOOR PLAN BUILDING NO. 1 - AREA AFLOOR PLAN BUILDING NO. 1 . AREA BFLOOR PLAN BUILDING NO. 1 - AREA CREFLECTED CEILING PLAN BUILDING NO. 1 - AREA AREFLECTED CEILING PLAN BUILDING NO. 1 - AREA BREFLECTED CEILING PLAN BUILDING NO. 1 - AREA CPART PLAN & INTERIOR ELEVATIONS BUILDING NO. 1

BUILDING SECTIONSFIRST FLOOR PLAN BUILDING NO. 2SECOND FLOOR PLAN BUILDING NO. 2FIRST FLOOR REF. CEILING PLAN BUILDING NO. 2SECOND FLOOR REF. CEILING PLAN BUILDING NO. 2FLOOR PLAN & REF. CEILING PLAN BUILDING NO. 3FLOOR PLANS & REF. CEILING PLANS BUILDINGS NO. 4 AND NO. 5FLOOR PLAN & REF. CEILING PLAN BUILDING NO. 85ROOF GENERAL NOTESROOF GENERAL NOTESEXISTING/DEMOLITTON ROOF PLAN BUTLDTNG NO. 1

EXISTTNG/DEMOLITTON ROOF PLANS BUTLDTNG NO. 2 & 3EXISTING/DEMOLITION ROOF PLAN BUILDING NO. 4, 5 & 85ROOF PHOTOS OF EXISTING CONDITION BUILDING NO. 1

ROOF PHOTOS OF EXISTING CONDITION BUILDINGS NO. 2, 3, 4 &,85

The School Boarcl of Bror.valcl County, FloriclaAgreenent Form for Hard BidMay 18,2016

Docrrment OO52O

Page 2 of 13

Page 3: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

AF-308AF-309AF-310AG-500AG-501AG-502AG-503AG-504AG-505AG-506AS-101E-001E- 101E-TO2E-103E-104E- 105E- 106E-20tE-202

FA-OO1FA- 100FA-101FA-102FA-103FA-104FA-105FA-106FA-t07FA-201FA-202FA-203FP-OO1FP-100FP-101FP- 102FP-103FP-104FP-105FP-106FP-107M-OO1M- 101M-102M-to2M- 104M-105M-106M-107M-108P-101c-2s-1

ROOF PLAN BUILDING NO. 1

ROOF PLAN BUILDING NO. 2ROOF PLAN BUILDINGS NO. 3, NO. 4, NO. 5 & NO. 85ROOF DE"IAILSROOF DE"IAILSROOF DETAILSROOF DETAILSEXTERIOR ELEVATION, DOOR SCHEDULE & DE"TAILSDETAILSDETAILS & SECTIONSSITE PLANELECTRICAL INDEX SYMBOL LEGEND AND NOTES PARTIALELECTRICAL PLAN BUILDING NO. 1 - AREAPARTIAL ELECTRICAL PLN BUILDING NO. 1 - AREA BPARTIAL ELECTRICAL PAN BUILDING NO. 1 - AREA CELECTRICAL PLAN BUILDING NO. 2 (FIRST FLOOR)ELECTRTCAL PLAN BUILDING NO. 2 (SECOND FLOOR)ELECTRICAL PLAN BUILDING NO. 3ELECTRICAL ROOF PLANDETAILFIRE ALARM INDEX, SYMBOL, LEGEND AND NOTESFIRE ALARM SITE PLANPARTIAL FIRE ALARM PLAN BUILDING NO. 1 - AREA APARTIAL FIRE ALARM PLAN BUILDING NO. 1 - AREA BPARTIAL FIRE ALARM PLAN BUILDING NO. 1 - AREA CFIRE ALARM PLAN BUILDING 2 (FIRST FLOOR)FIRE ALARM PLAN BUILDING 2 (SECOND FLOOR)FIRE ALARM PLAN BUILDING 3FIRE ALARM PLAN BUILDING 4, 5 & 85FIRE ALARM RISERFIRE ALARM RISERFIRE ALARM CALCSFIRE PROTECTION INDEX, SYMBOL LEGEND AND NOTESFIRE PROTECTION SITE PLANPARTIAL FIRE PROTECTION PLAN BUILDING NO. 1 - AREA APARTIAL FIRE PROTECTION PLAN BUILDING NO. 1 - AREA BPARTIAL FIRE PROTECTION PLAN BUILDING NO. 1 - AREA CFIRE PROTECTION PLAN BUILDING 2 (FIRST FLOOR)FIRE PROTECTION PLAN BUILDING 2 (SECOND FLOOR)FIRE PROTECTION PLAN BUILDING 3FIRE PROTECTION PLAN BUILDING 85MECHANICAL, INDEX, SYMBOL, LEGEND AND NOTESPARTIAL MECHANICAL PLAN BUILDING NO. 1 - AREA APARTIAL MECHANICAL PLAN BUILDING NO. 1 - AREA BPARTIAL MECHANICAL PLAN BUILDING NO. 1 - AREA CMECHANICAL PLAN BUILDING 2 (FIRST FLOOR)MECHANICAL PLAN BUILDING 2 (SECOND FLOOR)MECHANICAL PLAN BUILDING 3MECHANICAL ROOF PLANSMECHANICAL DETAILSPARTIAL PLUMBING PLAN BUILDING NO. 1 - AREA AFIRE PLANBUILDINGS 1, 2 & 3 ROOF WIND PRESSURES

The School Boald of Brorvarcl County, FloriclaAgr-eenent Foln for Hard BidMay 18, 2016

Docunent OO52O

Page 3 of 13

Page 4: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

S-2 BUILDING 1 CORRBCTIVE WORK

2.O3 The Project Manual:

DivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivisionDivision

0 - Documents1 - General Requirements2 - Site Work3 - Concrete4 - Masonry5 - Metals6-Wood&Plastic7 - Thermal & Moisture Protection8-Doors&Windows9 - Finishes1O - Specialties11 - Equipment12 - Furnishings13 - Special Construction14 - Conveying Systems15 - Mechanical16 - Electrical

ARTICLE 3. CONTRACT SUM

3.O1 The Owner shallpay, and the Contractor shall accept, as full and complete paSrmentfor the Contractor's timely performance of its obligations hereunder, the fixed price of:

Dollars $$92.197.oo

This shall constitute the Contract Price, which shall not be modilied except byChange Order or by Unit Prices, if any, as provided in the Contract Documents.

ARTICLE 4. TIME FOR CONTRACTOR'S PERFORIVIANCE.

4.Or Upon execution of the contract by both the successful Bidder and the Owner,submittal of the required performance and pa5rment bonds, certificates of insurance,and receipt and approval of the required post-bid information, the Owner will issueDocument (X)55O, Notice to Proceed which will stipulate the commencement datefor the Work.

4.O2 The Contractor shall commence the performance of the Work on the date stipulated onDocument O055O, Notice to Proceed, and shall diligently continue its performance toand until final completion of the Project.

4.O3 Required date(sf of Substantial Completion

4.03.01 The Contractor shall accomplish Substantial Completion of the Work on or before:

312 consecutive calendar days from the comrnencement date stipulated onDocument OO55O: Notice To Proceed

4.O3.O2 Preceding Substantial Completion, the following Milestone Dates are required tocommence and be completed as follows:

The School Boartl of Brorvard County, FloriclaAgreement Forn for Harcl BidMay 18, 2O16

Docllment OO52O

Page 4 of 13

Page 5: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

Phase Commencement Date:Required SubstantialComrrletion Date

N/e

4.O4 Liquidated Damages for Substantial Completion:

4.O4.Ol Owner and Contractor acknowledge that any sums due and payable hereunder by theContractor shall be payable, not as a penalty, but as liquidated damages representingareasonable estimate of delay damages, inconvenience, additional overhead and costs,lik"ly to be sustained by the Owner, estimated at the time of executing this Contract.If the Owner reasonably believes in its discretion that Substantial Completion will bedelayed, the Owner shall be entitled, but not required, to withhold from any amountsotherwise due the Contractor an amount then believed by the Owner to be adequate torecover liquidated damages applicable to such delays. If and when in its discretion theContractor overcomes the delay in achieving Substantial Completion, or any partthereof, for which the Owner has withheld payment, the Owner shall promptly releaseto the Contractor those funds withheld, but no longer applicable, as liquidateddamages.

4.O4.O2 In the event more than one Milestone is involved, then the liquidated damages due foreach Milestone shall be as follows:

4.O4.O3Each Milestone Five Hundred Dollars $500.00 per day

Partial use or occupancy of the Work shall not result in the Work deemed substantiallycompleted, and such partial use or occupancy shall not be evidence of SubstantialCompletion.

4.O4.O4 Substantial Completion, in the context of this Contract, does not refer to any priordates wherein the Owner employs other contractors to work on the same site of theProject or Work.

ARTICLE 5. SUBSTANTIAL COMPLETION AND FINAL PAYMENT.

5.01 Substantial Completion:

5.O1.01 When the Contractor believes that Substantial Completion has been achieved, theContractor shall noti$r the Project Consultant in writing and shall provide to the ProjectConsultant a listing of those matters yet to be finished. The Project Consultant willdetermine whether the Work (or portion thereof) is appropriately ready for a SubstantialCompletion Inspection.

5.01.02 If the Work is determined to be ready for a Substantial Completion Inspection, theProject Consultant and Owner will thereupon conduct an inspection of the Work todetermine if the Work is, in fact, substantially complete and establish a list of itemsnecessary for the Contractor to correct or finish. When Substantial Completion hasbeen granted as evidenced by the Substantial Completion Inspection, the ProjectConsultant will issue a letter formally establishing the Substantial Completion Date forthe Work or portion thereof.

5.O 1.03 Upon Substantial Completion, the Owner shall pay the Contractor an amountsufficient to increase total pa5iments to the Contractor to the Contract Price, less anyamounts attributable to liquidated damages, togetherwith two hundred percent (2OOVI)

'I'he School Boatd of Browarcl County, FioliclaAgreenent Folm for Harcl BiclMay 18, 2O16

Doctunent OO52O

Page 5 of 13

Page 6: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

of the reasonable costs (as determined by the Owner at its sole discretion), forcompleting all incomplete work, correcting and bringing into conformance all defectiveand nonconforming Work and handlitrg utty outstanding or threatened claims or anyother matters which could cause the Owner damage, cost, expense or delay.

5.O2 Final Completion:

When the Contractor believes that the Work or portion thereof, is finally complete andis ready for a final inspection, the Contractor shall noti$r the Project Consultant. in,r*iting. The Project Consultant \Mill then determine whether the Work (or portionthereo$ is appropriately ready for a Final Completion Inspection.

5.O2.O2 If the Work is determined to be ready for a Final Completion Inspection, the ProjectConsultant and Owner will thereupon conduct an inspection of the Work to determineif the Work is, in fact, finally complete. When Final Completion has been granted asevidenced by the Final Completion Inspection, the Project Consultant will issue a letterformally establishing the Final Completion Date for ttre Work or portion thereof.

5.02.03 When the Project Consultant and Owner confirms that the Project is complete in fullaccordance with the Contract Documents and has passed all required inspections,including but not limited to those required by the State Department of Education,andlor from any and all governmental bodies, boards, entitles, etc., and that theContractor has performed all of its obligations to the Owner, the Project Consultantwillprovide a final Approval for Payment to the Owner certi$ring to the Owner that theProject is complete and the Contractor is entitled to the remainder of the unpaidContract Price, less any amount withheld pursuant to Contract Documents.

5.02.O1

5.03

5.03.01

Liquidated Damages for Final Completion:

If the Contractor fails to achieve final completion within 30 consecutive calendar daysof the date of Substantial Completion, the Contractor shall pay the Owner the sum ofi

Dollars $_5OOper day for each and every calendar day of unexcused delay in achieving finalcompletion beyond the date set forth for final completion of the Work.

5.03.02 In the event the Project involves more than one Milestone Date; the final completiondate and liquidated damages amount for each Milestone Date shall be as follows:

Each Milestone Five Hundred Dollars $5OO.OO per day

5.03.03 Any sums due and payable hereunder by the Contractor shall be payable, not as apenalty, but as liquidated damages representing a reasonable estimate of delaydamages, inconvenience, additional overhead and costs fikely to be sustained by theOwner, estimated at or before the time of executing this Contract. When the Ownerreasonably believes that final completion will be inexcusab\r delayed, the Owner shallbe entitled, but not required, to w'ithhold from any amounts otherwise due theContractor an amount then believed by the Owner to be adequate to recover liquidateddamages applicable to such delays.

The School Boarcl of Browarrl County, FloliclaAgreenent Foln for Har-cl BiclMay 18, 2016

Docunent O052O

Page 6 of 13

Page 7: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

5.04 Prior to being entitled to receive final payment and as a condition precedent thereto,the Contractor shall provide the Owner, in the form and marurer required by Owner, ifany, with a copy to the Project Consultant: of the following:

5.04.01 An alfidavit that all of the Contractor's obligations to subcontractors, laborers,equipment or suppliers, or other third parties in connection with the Project, havebeen paid or otherwise satisfied;

5.O4.O2 Such other documents as required by the Owner from each subcontractor, lower tiersubcontractor, laborer, supplier or other person or entity who has or might have aclaim against the Owner;

5.04.03 All product warranties, operating manuals, instruction manuals and other things ordocuments customarily required of the Contractor, or reasonably required by Owner,including but not limited to those required elsewhere in the Contract Documents, aspart ofits Project Closeout procedures;

5.O4.O4 The Owner shall, subject to its rights set forth in the Contract Documents, make finalpa5rment of all sums due the Contractor within thirty (30) days of the final Approval forPa;rment.

5.04.05 The Owner and Project Consultant may acknowledge satisfactory completion andaccept the Work notwithstanding the existence of certain items of Work which areincomplete. As set forth in Article 5.03.03 of Article 5 hereof, the Owner may, but isnot obligated to guarantee completion of incomplete items of Work by escrowing fundsequal to two hundred (2OOVI) percent of the estimated cost of the incomplete Work andshall establish a reasonable date by which all incomplete Work must finally becomplete.

ARTICLE 6. TIME AND DELAYS.

6.01 411 time in the Contract Documents is calculated on a consecutive calendar day basis

6.O2 Time is of the essence in this Contract, and any breach of same shall go to the essencehereof, and Contractor, in agreeing to complete the Work within the time hereinmentioned, has taken into consideration and made allowances for all reasonablehindrances and delays incident to his work.

6.03 Contractor agrees to commence the Work when directed by Owner and to diligentlyand continuously perform such Work and to coordinate the Work with other Workbeing performed on the Project by other trades so that the Owner shall not be delayedby any act or omission of Contractor in completion of the Project within the timespecified above.

6.O4 Contractor shall make payments promptly to its vendors, subcontractors, suppliersand for labor, material and equipment used by it in the performance of its work.

6.05 The Contractor shall not be entitled to any claim for damages or an extension of Timeon account of hindrance or delays from any cause whatsoever, but if caused by any actof God or active interference on the part of the Owner, such act, hindrance, or delaymay orrly entitle the Contractor to receive an extension of time as its sole and exclusiveremedy.

The School Boarcl of Broward County, Flor-icta

Agr-eenent Forn for Halcl BiclMay 18, 2O16

Docrrment OO52O

Page 7 of 13

Page 8: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

6.05.01 Adverse weather such as rain is not to be considered to be an Act of God unless itexceeds the ten (1O) year average as published by the National Weather Service (orequivalent organizatton acceptable to the Owner at its sole discretion) for that time ofyear in Broward County.

6.O5.O2 An extension of time to complete the Work shall be determined by the Owner providedthat the Contractor provides the Owner with notice in writing of the cause of said act,hindrance or delay within twenty (20) days after its occurrence.

6.05.03 In the event the request for extension is not made in writing within that twenty (20)day time period, Contractor acknowledges and agrees it has forever waived any and allriglrts to such an extension.

6.05.04 A11 extensions of time shall be authorized only by a written change order executed bythe Owner and Project Consultant.

6.O5.05 This "no damage for delay" clause will encompass any damages for delay or disruptioneven if the Contractor completes construction of the Work in a timely fashion inaccordance with this Contract.

6.O5.06 Damages as referenced in this "no damage for delay" shall include any type of damagesthat are or could be awarded by any court or arbitration panel such as, by way ofgeneral example, but not limitation, tort, contract, strict liability, consequentialdamages, liquidated damages and/or punitive damages.

6.05.07 By way of specific example but not limitation, damages as referenced within this clauseincludes loss of use, loss of profits, labor inefficiency, loss of bonding capacity, overheadand repair costs, costs of capital replacement, loss of wages, pain and suffering, loss ofproduction costs to replace facilities, equipment and/or product loss, increased and/orextended home office overhead, increased general conditions, costs of mobilization anddemobilization, decrease in value, andf or any other damage or loss.

6.05.08 The Contractor recognizes and specifically acknowledges the terms and conditions ofthe "no damage for delay" clause upon execution of this Contract.

ARTICLE 7. CONTRACT BONDS

7.Ol The Contract shall become effective and in full force upon the execution of thisagreement, concurrently with the delivery of a bond issued by a Surety Companyacceptable to Owner in its sole discretion, such Surety being qualified and rated inaccordance with Article 42.08 of Document 007O0, General Conditions of the Contract,and approved by the United States Treasury Department and licensed to do businessin the State of Florida.

7.O2 This Agreement must be executed and signed by a resident agent having an office inFlorida, representing such Surety Company, for one hundred per cent (lOOVo\ of theContract price, said bond guaranteeing the performance of this Contract and assecurity for the payment of all persons performing labor and providing materials inconnection with this Contract.

The School Boarcl of Browalcl County, F'loliclaAgreeurent Forn for Halcl BiclMay 18, 2016

Docunent OO52O

Page 8 of 13

Page 9: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

7.O3

7.O4

7.O4.OL

The form of Bonds required is included elsewhere in the Contract Documents. This isin addition to any bonds of subcontractors or others.

Insurance Provider and Surety: Refer to Document 00700 - General Conditions, Article42.09 Contractor's Insurance.

Contractor and Surety shall have a continuing obligation to insure that all insuranceor suret5r requirements are satisfied throughout the construction of the project anduntil all post completion obligations, including punch list and warranty requirements,are completed or expire.

ARTICLE 8. NOTICES

8.O1 Any notices provided for hereunder shall be in writing and may be served eitherpersonally on the authorized representative of the receiving party at the jobsite, with acopy via telecopy or facsimile to the addresses shown below, or by registered mail orovernight delivery/courier service (e.9., Federal Express) to that party at the addressesshown below:

Party: Address:Owner: Superintendent of Schools

The School Board ofBrowardCounty, Florida

600 SE Third AvenueFt. Lauderdale, FL 33301Attn: Robert W. Runcie

With Copies To Project MamagerOffice of Facilities andConstructionThe School Board of BrowardCounty, FloridaANDDirectorProcurement & WarehousingServicesThe School Board of BrowardCount5r, Florida

2301 NW 26th StreetFt. Lauderdale, FL 3331 1

Attn: Stephen Gaydosh

Mary C. CokerProcurement & WarehousingServices Department7720 W. Oakland Park Blvd.Suite 323Sunrise Florida 33351

Contractor: LEGO Construction CO 1O11 Sunnybrook Rd. Suite 905Miami FL 33136Attn: Luis Garcia

Suret5r: Hartford Casualty InsuranceCompany

One HartfordPlazaHartford, CT 06155-000 1

8.O2

Surety's Agent: Charles J. Nielson One HartfordPlazaHartford, CT 06155-OOO 1

Project Consultant: Jorge A. Gutierrez, Architect 19950 West Country Club Drive,LLC Suite 905,

Aventura, Florida 33 18OThese addresses may be changed by either of the parties by written notice to the otherparty.

The School Boarcl of Browarcl County, FloridaAgreement Form for-Harcl BiclMay 18, 2016

Docrrrnent OO52O

Page 9 of 13

Page 10: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

9.01

ARTICLE 9. CONTRACTOR'S RTSPONSIBILITIES

The Contractor must comply with public records laws. Florida State StatuteILg.O7O1 requires that the Contractor keep, maintain and provide public access topublic records. The Contractor shall ensure that public records that are confidentialand exempt from public records disclosure are not disclosed, except as authorizedby law. The Contractor shall be responsible for retaining public records and transfer,at no cost to the pubtc agency, all public records in their possession uponcompletion or termination of the contract. Electronically stored records must beprovided in a format compatible with the information technologz systems of thepublic agency. Failure to comply with these provisions will constitute a breach ofcontract and will have financial consequences.

The School Boarcl of Browarcl County, FloriclaAgreement Forrr for Harcl BiclMay 18, 2O16

Docrrment OO52O

Page 10 of 13

Page 11: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

fn witness thereof, the said Contractor, LEGO Construction CO., and the Owner, The SchoolBoard of Broward Count5r, Florida, have caused this contract to be executed and their corporatesea-ls afhxed by and through their proper ofhcers, thereunto duly authoized, on this day and yearfirst above written.

OWNER

(Corporate Seal) THE SCHOOL BOARD OF BROWARDcouNTY, FLORIDA

ByNora Rupert, Chair

ATTEST

Robert W. Runcie, Superintendent of Schools

Approved as to Form and l,egal Content By:

Office of Counsel

The School Boald of Browarcl County, FloriclaAgreement Form for Harcl BiclMay 18, 2O16

Docrrmett OO52O

Page 11 of 13

Page 12: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

(Corporate Seal)

CONTRASIOR

By Luis

Secretary-or-

Witness

COITTRACTOR NOTARIZATION

STATE OF FtorrdqCOUNTY OF Mto.^^i DoL

The foregoing instrument was aclmowledged before me this 15 day of December 20t7

by Luis Garcia, President of LEGO Construction Co

'tltllll"i'.1r\-" ic;"1 g,: i r,j

/,'r.\l^\-.LVt.(\!f,

.-",-'J :...^,:. ;i ..1 - t,i_.' t,,

-\ v..^Rf'\ir\'4 :.." \"2-,, /\

^ .41\ 1/ \. r't,.^\ \J ""ri:. -- ,. , \' i F" .n

^: (t ." "S-), f". ir I ! (': :.:- trr; ;.'i *:fi 2{l()0 ;:-'l:2, "'.lonio\"" +'

'/ -t\{!. + .\''ttt t uii,t,tt'

F

wi7

^ -,{ of on

behalf of the Contractor.Luis Garcia and,

me or produced

an oath.

My commission expires: Mol I5 t 20.8

are personally known to

as identification and did/did not first take

Signature - Notary Public

J "la P t4zotrPrinted Name of Notary

Fp r2 3 +9LNotary's Commission No.

JULIO ALDEMAR PINZON

Notary Public - State ol Florida

My Comm. Expires May 15,2018Commission # FF 123752

The School Board of Broward CountSr, FloridaAgreement Form for Hard BidMay 18,2016

Document 00520Page 12 of L3

Page 13: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

SURBTT ACKNOWLEDGMENT

The Surety acknowledges that it has read the foregoing Constmction Contract and hasfamiliarized itself with the obligations of the Contractor and the Surety as stated therein, whichobligations are agreed to by Surety and are incorporated, by reference to the ConstructionContract, in the Payment and Performance Bonds.

SURETY:

Its:

Date:

Charles J. Nielson, Attorney-in-fact

FloridaSTATE OF

COUNTY OF Miami-Dade

l5th December 20L7Theforegoinginstrumentwasacknowledgedbeforemethisd"yof-'-

by Charles J. Nielson of Hartford Casualty Insurance Companyon

December 15,2017

behalf of the Surety.

He/she is personally known to me or produced personally known

identification and did/did not first take an oath.

My commission expires

Signature -Gicelle Pajon

t"

Printed Name of NotaryGG 058656

Notary's Commission No.

AS

*

PublicPubtic

END OF DOCUMENT

The School Board ofBroward Coungr, FloridaAgreement Form for Hard BidMay 18,2016

Document 0O520Page 13 of 13

Page 14: l;- Y'' =- . 1bcpsagenda.browardschools.com/agenda/01439/Item JJ-14... · 2018-05-18 · 7720 W. Oakland Park Blvd., Suite 323 Sunrise, Florida 33351 175,41321-O5O5 =- Y''. _1_= Document

POWER OF ATTORNEYDi rect lnqu i ries/Clai ms to :

THE HARTFORDBOND, T.12

One Hartford PlazaHartford, Connecticut 061 55

[email protected]

calf 888-266-3488 or fax: 860-757-5835Aqencv Code: 21-229752KNOW ALL PERSONS BY THESE PRESENTS THAT:

X Hartford Fire Insurance Company, a corporation duly organized under the laws of the State of Connecticut

Hartford Casualty lnsurance Company, a corporation duly organized under the laws of the State of Indiana

l-X-l Xartford Accident and lndemnity Gompany, a corporation duly organized ur.rder the laws of the Srate of Connecticut

Hartford Undenvriters lnsurance Gompany, a corporation duly organized under the laws of the State of Connecticut

Twin City Fire Insurance Company, a corporation duly organized under the laws of the State of Indiana

Hartford lnsurance Company of lllinois, a corporation duly organized under the laws of the State of Illinois

Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State of lndiana

Hartford lnsurance Company of the Southeast, a corporation duly organized under the laws of the State of Florida

X

having their home office in Hartford,up to the amount of unlimited:

Connecticut, (hereinafter collectively referred to as the "Companies") do hereby make, constitute and appoint,

Charles J. Nielson, Mary C. Aceves, Charles D. Nielson, Joseph Penichet Nielson, David R. Hooverof

MiamiLakes, FLtheir true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only asdelineated above by X, and to execute, seal and acknowledge any and all bonds, undertakings, contracts anl other written instruments inthenature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts andexecuting or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.

In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on March 1, 2016 the Companieshave caused these presents to be signed by its Senior Vice President and its corporate seals to be hereto affixed, duly attested by its AssistantSecretary. Further, pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they areand will be bound by any mechanically applied signatures applied to this Power of Attorney.

flNJohn Gray, Assistant Secretary M. Ross Fisher, Senior Vice President

STATE OF COHNECTICUT rI *r. Hartford

COUNTY OF HARTFORD

'On this 5th day of April,2016, before me personally came M. Ross Fisher, to me known, who being by me duly sworn, did depose andsay: that he resides in the County of Hartford, State of Connecticut; that he is the Senior Vice Presldent of the Companies, the corporationsdescribed in and which executed the above instrument; that he knows the seals of the said corporations, that the seals affixed to the saidinstrument are such corporate seals; that they were so affixed by authority of the Boards of Directors of said corporations and that he signed hisname thereto by like authority.

..").-.://

/,/n,, , /t\ .)-lc7;.,. .'f'p./.'Nora M- Stranko

Notary PublicMy Commission Expires March 31, 2018CERTIFICATE

l, the undersigned, Assistant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correctcopy of the Power of Attorney executed by said Companies, which is still in full force effective as of December 15,2017 .

Signed and sealed at the City of Hartford.

@@@ffi@#'ffi

ts?!I

tr70a

I 9t9t

I fttt

Kevin Hecl