LEVEL 1 - University of California, San Diegormp-public.ucsd.edu/fdc/Job Bids/TUOLUMNE APARTME… · Web viewmandatory meeting location: fd&c large conference room SUBMITTALS DUE:

TUOLUMNE APTS FIRE + LIFE SAFETY INF – PH I PROJECT NO. 5054/A4L-409/962590UNIVERSITY OF CALIFORNIA, SAN DIEGO

PREQUALIFICATION QUESTIONNAIREFor

GENERAL CONTRACTOR

TUOLUMNE APTS FIRE + LIFE SAFETY INFRASTRUCTURE (INF) – PH IUNIVERSITY OF CALIFORNIA, SAN DIEGO

(5054)

SUBMITTED BY:

< please enter your company name here >

UNIVERSITY OF CALIFORNIA, SAN DIEGOFACILITIES DESIGN & CONSTRUCTION

10280 NORTH TORREY PINES ROADLA JOLLA, CA 92037

ISSUE DATE: THURSDAY, MARCH 24, 2016MANDATORY PREQUALIFICATION MEETING: THURSDAY, MARCH 31, 2016

MANDATORY MEETING LOCATION: FD&C LARGE CONFERENCE ROOMSUBMITTALS DUE: THURSDAY, APRIL 7, 2016

General Contractor Page 1 of 29 Prequalification QuestionnaireGC P/Q Quest(UCSD Rev. 01/26/2016)


(Where a time period is given, such as the last ten [10] years, the period is to be measured backwards from the date this prequalification questionnaire is required to be submitted to the University of California at San Diego.)

Note: Submission of an incomplete and/or unclear Prequalification Questionnaire may result in the determination of the prospective Contractor as NON-PREQUALIFIED.

SUBMITTED BY: (Name and Title) Printed or Typed

(Signature)

(Firm Name. If a Joint Venture, state name if JV Entity)

(Contact Name for all notices and correspondence)

(Address)

(City, State, Zip Code)

________________________ ________________________(Telephone Number) (Facsimile Number)

(E-mail Address)

Each prospective Contractor must have the following California General Building Contractor’s License, License Classification: B, current, active and in good standing with the California Contractor’s State License Board on the date and time of the Prequalification Questionnaire submittal is due and must submit this Prequalification Questionnaire with all portions completed, including required attachments.

Each prospective Contractor must answer all of the following questions and provide all requested information, where applicable. Any prospective Contractor failing to do so may be deemed to be not responsive and not responsible with respect to this Prequalification at the sole discretion of the University. Each prospective Contractor must submit four (4) printed sets and one (1) flash drive with complete submittal of the questionnaire. All Contractors that have submitted a Prequalification Questionnaire will be notified in writing of either successfully or not successfully achieving prequalification status. The decision of the University is final and is not appealable within the University of California system.



All information submitted for Prequalification evaluation will be considered official information acquired in confidence, and the University will maintain its confidentiality to the extent permitted by law.

It is critical that the prospective Contractor fills out all information required accurately, completely, truthfully and to the best of their knowledge. Ambiguous or incomplete information may lead to an unfavorable rating and subsequent status as non-prequalified.

WHERE NECESSARY, COPY THE FORMS IN THIS PACKAGE. USE ONLY THESE FORMS.

1. PREQUALIFICATION DECLARATION

I, ________________________________________________, hereby declare that I am the(Printed Name)

_________________________________ of ____________________________________(Title) (Name of Firm)

submitting this Prequalification Questionnaire; that I am duly authorized to sign this Prequalification Questionnaire on behalf of the above-named firm; and that all information set forth in this Prequalification Questionnaire and all attachments hereto are, to the best of my knowledge, true, accurate and complete as of its submission date.

The undersigned declares under penalty of perjury that all of the prequalification information submitted with this form is true and correct and that this declaration was executed in

________________________________ (County), __________________________, (State)

on ______________________________ (Date).

____________________________________(Signature)



2. ATTENDANCE AT MANDATORY PREQUALIFICATION CONFERENCE

Did a representative of your firm attend the Mandatory Prequalification Conference at the University of California, San Diego, La Jolla?

YES NO

Name/names of those attending: _________________________________________

Date of Meeting Attended:____________________________________________

3. LICENSE

A. Does your firm hold the following California contractor's license, which is current, valid, and in good standing with the California Contractor's State License Board?

License Classification: B - General Building Contractor

YES NO

1. If the entity submitting this prequalification questionnaire is a Joint Venture, does the Joint Venture entity itself currently hold a (B – General Building Contractor) California contractor's license, which is current, valid, and in good standing with the California Contractor's State License Board?

YES NO N/A

B. Provide the following information about your firm's contractor's license:

1. Name of license holder exactly as on file with the California Contractor's State License Board:__________________________________________________________________

2. License Classification: _______________________________________________

3. License Number: _____________________________________________________

4. Date Issued: _______________________________________________________

5. Expiration Date: ____________________________________________________



C. Is your firm registered with the State of California Department of Industrial Relations (DIR)?

YES NO

Public Works Contractor Registration Number: _______________________________

D. Can you truthfully state that your firm's contractor's license hasn’t been suspended or revoked by the California Contractor's State License Board within the last five (5) years?

YES NO

If answer is “No,” explain on attached additional sheets.

If the entity submitting this prequalification questionnaire is a Joint Venture, can the Joint Venture entity truthfully state that no member of the Joint Venture has ever had their firm's contractor's license suspended or revoked by the California Contractor's State License Board?

YES NO N/A


E. Has a complaint ever been filed with the Contractor’s State License Board against your company that required a formal hearing or inquiry?

YES NO

F. Does your firm have experience utilizing CPM logic, Primavera Project Planner scheduling software on your projects and would you utilize this experience on this project?

YES NO

If “No,” name the software application(s) used or the software application you would propose for use on this project for scheduling.



4. SURETY

Prospective Contractor desiring to be prequalified are informed that they will be subject to and must fully comply with all bid conditions including 100% payment and 100% performance bonds.

Prospective Contractor shall submit the below form, signed by representative of surety and notarized. If firm has used current surety for less than ten years, list surety(ies) previously used and indicate number of years used to demonstrate ten (10) complete years of surety history.

A. Is the surety to be used listed in the latest published State of California Department of Insurance list of Insurance Organizations Authorized by the Insurance Commissioner to Transact Business of Insurance in the State of California?

YES NO

B. Is the prospective Contractor able to obtain bonding up to and including the cost for this construction contract estimated at $7,000,000 of which no more than 50% is currently committed to other projects?

YES NO

1. If the entity submitting this prequalification questionnaire is a Joint Venture, is the Joint Venture entity itself able to obtain bonding up to and including the cost for this construction contract estimated at $7,000,000 of which no more than 50% is currently committed to other projects?

YES NO N/A

C. Is it true that the surety has not paid out any monies for the construction activities of the prospective Contractor whatsoever within the last ten (10) years?

YES NO


1. If the entity submitting this prequalification questionnaire is a Joint Venture, is it true that the surety has not paid out any monies for the construction activities of any member of the Joint Venture within the last ten (10) years?

YES NO N/A

D. How long has the Prospective Contractor been with this surety? years



E. Surety Declaration:

Provide this Declaration of your surety(ies) for completion. Do not have the surety submit this information directly to the University.

The undersigned declares under penalty of perjury that all of the above surety information is true and correct and that this declaration was executed in

County, California, on (date).

(Signature)

(Name and Title - Printed or Typed)

(Representing [Surety Name])

(Surety License Number)

(Firm Name)

(Address) (City, State, Zip Code)

________________________________________________________________________________________________________(Telephone Number) (Facsimile Number)

(Email Address)

(ATTACH NOTARIZATION of SURETY REPRESENTATIVE’S SIGNATURE)


5. INSURER

Prospective Contractor desiring to be prequalified are informed that they will be subject to and must fully comply with all bid conditions including the following insurance coverage and associated limits.

Prospective Contractor shall submit the below form, signed by representative of insurer and notarized. If firm has used current insurer for less than ten years, list insurer(s) previously used and indicate number of years used to demonstrate ten (10) complete years of insurer history.

A. Is the insurer to be used listed by Best with a rating of A- or better and a financial classification of VIII or better (or an equivalent rating by Standard & Poor’s or Moody's)?

YES NO

Indicate Best Rating:

Indicate Best Financial Classification:

B. Is the prospective Contractor able to obtain insurance in the following limits for each of these construction contracts?

YES NO

1. If the entity submitting this prequalification questionnaire is a Joint Venture, is the Joint Venture entity itself able to obtain insurance in the following limits for each of these construction contracts?

YES NO N/A

MinimumComprehensive or Commercial Form General Liability Insur ance - Limits of Liability RequirementEach Occurrence - Combined Single Limit for Bodily Injury and Property Damage $1,000,000Products - Completed Operations Aggregate

$2,000,000Personal and Advertising Injury $1,000,000General Aggregate - Not Applicable to Comprehensive Form $2,000,000

Business Automobile Liability Insurance - Limits of Liabil ity Each Accident - Combined Single Limit for Bodily Injury and Property Damage

$1,000,000

C. How long has the Prospective Contractor been with this insurer? years

D. Insurance Declaration:

Provide this Declaration to your insurance carrier for completion. Do not have the carrier submit this information to the University.

The undersigned declares under penalty of perjury that all of the above insurer information is true and correct and that this declaration was executed in

County, California, on (date).

(Signature)

(Name and Title - Printed or Typed)

(Representing [Insurer Name])

(Insurer’s License Number)

(Firm Name)

(Address) (City, State, Zip Code)

(Telephone Number) (Facsimile Telephone Number)

(Email Address)

(ATTACH NOTARIZATION of INSURER REPRESENTATIVE’S SIGNATURE)

6. CONSTRUCTION EXPERIENCE

Submit Project Data on a minimum of two (2) and a maximum of five (5) comparable projects successfully completed within the last ten (10) years constructed in the United States of America one of which was constructed in the State of California.

A comparable project is defined as having a construction cost at the bid date of at least $6,000,000 or a total of $18,000,000 for the projects submitted, and the following example building types:

Multi-Unit Residential Complexes, with Special consideration for residential projects completed in a University setting,

and

Such projects should have possessed the following construction challenges: Fast-paced construction schedules within an abbreviated summer construction

window and with hard construction completion end-dates. Renovations of buildings requiring proactive and innovative solutions due to

noise, dust, and pedestrian traffic while the surrounding campus community is fully operational for the summer quarter.

Renovations with limited staging area within large campus community Renovations/upgrades to existing facilities requiring proactive and innovative

solutions due to unknown and/or unforeseen field conditions. Project complexity requiring critical path construction scheduling to complete on

time.Such projects should include these specific components:

Fire Alarm & Fire Sprinkler systems integration Elevator systems repairs, upgrades and modernizations.

A. If the entity submitting this prequalification questionnaire is a Joint Venture, the Joint Venture entity itself must demonstrate adequate previous construction experience. Joint Venture teams newly-formed to pursue this prequalification opportunity are not eligible for prequalification.

B. Listed projects must have been managed and constructed under the business name submitted for prequalification. Projects completed by employees for former employers are not acceptable.

C. Submit the following Project Data Sheets for each project submitted as evidence of your firm's Contractor expertise.

PROJECT DATA SHEET (A separate sheet must be prepared for each project submitted.)

1. Project Name: _________________________________________________________________

2. Project Location: ___________________________________________________________

3. Project Description: ___________________________________________________________

4. Constr. Type:

5. Size (gross square feet): ____________

6. What was your company’s role on this project?

Prime (General) Contractor Subcontractor to GC 2nd Tier Subcontractor 3rd Tier Subcontractor Prime Subcontractor to Owner Other: _________

List the Business Entity (name) your company used to perform work for this project: ____________________________________________________________________________________

7. If the entity submitting this prequalification questionnaire is a Joint Venture, did the Joint Venture entity itself construct and manage this project?

YES NO N/A

8. Was this work performed under a Job Order Contract (JOC)?

YES NO N/A

9. How is this project comparable to the 5054 Tuolumne Apts Fire + Life Safety INF – PH I project? ______________________________________________________________________________

______________________________________________________________________________

10. Was the project completed within budget?

Cost At Bid: $

Cost At Completion: $

Explanation: ____________________________________________________________________

11. For any differing amount between cost at completion and cost at bid, distribute the sources and/or causes of these changes into the following categories:

Document Problems: $ Unforeseen Conditions: $ Owner Generated Scope: $ Regulatory Agency: $ Other: $

12. Was construction begun and completed within the last ten (10) years?

YES NO

13. Was the project completed within the original contract time or the adjusted contract time?

YES NO

If completion did not occur within the original or the adjusted contract time, indicate elapsed time in whole calendar days between original or adjusted contract time and actual final completion. For projects that have not reached final completion, indicate current status with respect to contract time:_________________________________________________________________________________

14. Did the project include occupied facilities?

YES NO

15. What communications strategies were used by your firm to assist the project team in mitigating the impacts of construction on the occupied facilities? ______________________________________________________________________________

16. Was the project for a university or public institution?

YES NO

17. What strategic decisions did your firm contribute to the project which supported the project’s success (e.g. value engineering, phasing, innovation, new technology, etc.)? ______________________________________________________________________________

18. Did the project include adherence to critical path scheduling?

YES NO

19. Did project contain upgrades to and/or integration of new fire alarm systems?

YES NO

20. Did project contain upgrades to and/or integration of new fire sprinkler systems?

YES NO

21. Did project contain upgrades to and/or integration of new elevator systems equipment?

YES NO

22. Did the project include a quality control/quality assurance program?

YES NO

If “Yes,” explain: _______________________________________________________________

23. Did the project include California State Fire Marshal review and approval (planning, scheduling and obtaining State Fire Marshal approval of materials, shop drawings, and systems testing)?

YES NO

24. Did the project include California Division of State Architect Handicapped Accessibility Compliance review and approval?

YES NO

25. Did the project include USGBC LEED CI requirements/certification or their equivalent?

YES NO

If answer is “Yes,” explain: _________________________________________________________

26. Did the Owner assess any back-charges?

YES NO

If answer is “Yes,” explain: __________________________________________________________

27. Did the Owner assess any liquidated damages?

YES NO

If answer is “Yes,” explain: _________________________________________________________

28. Name of Project Executive:_____________________________________

Qualifications of this Project Executive:________________________________________________________________________________________________________

29. Name of Project Manager: ___________________________________________________

Qualifications of this Project Manager: _______________________________________________________________________________________________________________________

30. Name of Project Superintendent: ___________________________________________________

Qualifications of this Project Superintendent: _______________________________________________________________________________________________________________________

31. Name of Project Engineer: ________________________________________________________

Qualifications of this Project Engineer: ____________________________________________________________________________________________________________________________

32. Did your firm self-perform any of the work?

YES NO

If “Yes,” please specify the trades you self-performed or have the capability to self-perform:

__________________________________________________________________________________________________________________________________________________________________________________________________________________________________________

Client Firm Name:

Client Contact: Title:

Client Address: City, State Zip

Client Phone: Client Fax:Client E-mail Address:Architect/Engineer/Consultants:Architect/EngineerContact Name: Phone:Architect/EngineerE-mail Address:

(Attach additional pages with other pertinent project information as necessary.)

7. CURRENT PROJECTS FOR THE REGENTS OF THE UNIVERSITY OF CALIFORNIA

Submit the following Current Projects for The Regents of the University of California Project Data Sheet for each current project (regardless of project delivery strategy) between your firm and The Regents of the University of California. If none, indicate none (do not leave blank).

CURRENT PROJECTS FOR THE REGENTS OF THE UNIVERSITY OF CALIFORNIA

PROJECT DATA SHEET (A separate sheet must be prepared for each project submitted.)

1. Project Name:

2. Project Location (which campus?):

3. Type of Facility: _____________________________________________________________

4. Project Description:

5. Constr. Type:

6. Size (gross square feet): __________________

7. Is this project comparable to the 5054 Tuolumne Apts Fire + Life Safety INF – PH I project? If “Yes,” explain how:

___________________________________________________________________________

8. Current Project Status:

9. Anticipated Completion Date:

10. Description of Firm’s Performance On Project Thus Far:

a. With Respect To Time:

b. With Respect To Budget:

11. For any differing amount between cost to date and cost at bid, distribute the sources and/or causes of these changes into the following categories:

Document Problems: $ Unforeseen Conditions: $ Owner Generated Scope: $ Regulatory Agency: $ Other: $

12. Business name of entity that is performing this project:

13. If the entity submitting this prequalification questionnaire is a Joint Venture, is the Joint Venture entity itself performing this project?

YES NO N/A

UC Client Contact: Title:

UC Client Phone: ( ) Fax: ( )

UC Client E-mail Address:

Architect/Engineer/Consultants:

Architect/EngineerContact Name: Phone:

Architect/EngineerE-mail Address:

(Attach additional pages with other pertinent project information as necessary.)

8. STAFF EXPERIENCE AND PROJECT SAFETY

The Project Manager and Project Superintendent listed will be considered qualified only if he/she has successfully completed at least one (1) comparable project each.

A. Contractor hereby commits as a minimum to assignment of the specific field staff as outlined below. Contractor to submit a complete staffing chart as part of this package.

One Project Executive (part-time) during construction.

The Project Executive will be on site part-time during construction and on site for construction meetings.

One Project Manager (full-time on site) during construction

Contractor shall assign one Project Manager to oversee, manage and coordinate the project. The magnitude and complexity of the project will necessitate that this position manage the entire construction process. This position will need to be involved with all aspects of the project including but not limited to all scheduling and budgeting meetings, overall construction process development and execution, multi-staff operation management and coordination. The project manager will take the lead position in all Architect and University issues including overall contract administration, RFI, RFP and contract change order negotiations, campus and community relations. The project manager will be the main contact on behalf of the general contractor and will be responsible for guiding the construction development process to successful completion. The project manager will be responsible for budget, quality and schedule.

One Project Superintendent (full-time on site) during construction

The Contractor will assign one Project Superintendent to manage, coordinate and facilitate the field supervision staff for each of the various components of the project construction process. The major function of this position will be in addition to the normal superintendent’s daily workload, subcontractor interaction and production, and various field related coordination issues.

One Project Engineer (full-time on site) during construction

The Contractor will assign one Project Engineer to perform Quality Control duties, submittals, shop drawings and MEP coordination.

One Project Clerk (as needed) during construction

B. At the time of bid, the successful Contractor will be required to reconfirm staff assignments to the project based on this submittal. If any of the named staff submitted are no longer employed by the firm at the time the project starts, or are otherwise unavailable, the firm's bid may be considered non-responsive. Substitution of other individuals with equivalent experience may be considered by the University, however resumes, comparable project history and other relevant information must be submitted to the University prior to the determination of the bid results.

C. Project Management -

The Contractor shall keep on the job throughout its duration a competent Project Manager and Project Superintendent, all of whom must be satisfactory to the University. The Project Manager and Project Superintendent shall be the same individuals proposed by the Contractor during the procurement process for this project. The Project Manager shall represent the Contractor, and all communication given to the Project Manager shall be as binding as if given to the Contractor. The Contractor shall not change either the Project Manager or the Project Superintendent on the project from those originally proposed for the project without the prior written consent of the University. The University will only grant written consent for such change in the case of undue hardship on the individual or if the Project Manager and Project Superintendent shall leave the employ of the Contractor.

By submitting a proposal for this project, the Contractor agrees to pay a training fee of $10,000 should they change Project Executive, Project Manager, or Project Superintendent without the written consent of the University.

D. Safety Program

The safety of the Contractor employees, employees of the University and other visitors to the Project are of the utmost importance to the University. The Contractor shall take whatever steps are necessary to maintain a clean and safe work environment for their employees, the employees of their Subcontractors and vendors, and any other visitors to the project.

E. Part-Time Project Executive: 5054 Tuolumne Apts Fire + Life Safety INF – PH I Project.

1. The name of the specific Project Executive to be committed to this project and continuously retained throughout this project is:

(Attach resume)

2. Total years of experience: years

3. Years at this position: years

4. Years with this firm: years

5. The Project Executive named above was assigned to the following comparable projects for which data sheets have been included in this questionnaire:

Project: Construction Cost:

a.

b.

c.

6. The Project Executive named above worked on the following similar projects that are described in the attached resume:

a.

b.

c.

F. Full-Time Project Manager: 5054 Tuolumne Apts Fire + Life Safety INF – PH I Project

1. The name of the specific Project Manager to be committed to this project on a full-time basis and continuously retained throughout this project is:

(Attach resume)


3. Years at this position: ______years


5. The Project Manager named above was assigned to the following comparable projects for which data sheets have been included in this questionnaire:


a.

b.

c.

6. The Project Manager named above worked on the following similar projects that are described in the attached resume:

a.

b.

c.

G. Full-Time Project Superintendent: 5054 Tuolumne Apts Fire + Life Safety INF – PH I Project

1. The name of the specific Project Superintendent to be committed to this project on a full-time basis and continuously retained throughout this project is:

(Attach resume)


3. Years at this position: years


5. The Project Superintendent named above was assigned to the following comparable projects for which data sheets have been included in this questionnaire:


a.

b.

c.

6. The Project Superintendent named above worked on the following similar projects that are described in the attached resume:

a.

b.

c.

H. Full-Time Project Engineer: 5054 Tuolumne Apts Fire + Life Safety INF – PH I Project

1. The name of the specific Project Engineer to be committed to this project on a full-time basis and continuously retained throughout this project is:

(Attach resume)


3. Years in this position: years


5. The Project Engineer named above was assigned to the following comparable projects for which data sheets have been included in this questionnaire:


a.

b.

c.

6. The Project Engineer named above worked on the following similar projects that are described in the attached resume:

a.

b.

c.

9. ADDITIONAL GENERAL CONTRACTOR REQUIREMENTS

A. If fully prequalified and a successful fee bidder, the General Contractor will be required to use the following computer software programs: Microsoft Word Processing, Microsoft Excel Cost Analysis, Primavera Project Planner Project Scheduling, e-Builder Project Management and Control, Outlook Email, and Internet Explorer Web Browser.

10. SAFETY PROGRAM

A. Does your firm have a written Injury and Illness Prevention Program (IIPP) that complies with California Code of Regulations, Title 8, Sections 1509 and 3203?

YES NO

Brief Description: _________________________________________________________

B. Does your firm have a written safety program that meets CAL/OSHA requirements?

YES NO

C. Will your firm have personnel permanently assigned and dedicated to Safety on this project?

YES NO

D. If “Yes,” state the names of all such personnel who will be assigned and individually list their specific duties:

Name, Title Specific Duties___________________________________ ______________________________________________________________________ ______________________________________________________________________ ______________________________________________________________________ ___________________________________

Attach resumes (include certification and safety related training received.)

E. Have you had accidents, which resulted in a construction fatality on any of your projects over the last 2 years?

YES NO

If the answer is “Yes,” please explain.________________________________________________________________________________________________________________________________________________

F. Is your firm’s current Workers’ Compensation Experience Modification Rate (EMR) equal to 1.5 or less?

YES NO

Provide your California Workman’s Compensation Modifier for each of the last three (3) years.

__________________________________________________________________

G. Provide EMR verification (regardless of whether EMR is under or over 1.5) from State of California or from insurance company for the most recently completed year.

H. Has your firm been cited by OSHA in the past 5 years?

YES NO


I. Does your firm have a Small Business/Underutilized Business Outreach Program?

YES NO

If “Yes,” please include a summary of your efforts (up to one [1] page).

11. QUALITY CONTROL/QUALITY ASSURANCE PROGRAM (QC/QA)

A. Does your firm have a written quality control/quality assurance program?

YES NO

B. Will your firm have personnel permanently assigned and dedicated to QC/QA on this project?

YES NO

C. If “Yes,” state the names of all such personnel who will be assigned and individually list their specific duties:

Name, Title Specific Duties___________________________________ ______________________________________________________________________ ______________________________________________________________________ ___________________________________

D. Provide brief description of your Quality Control/Quality Assurance Program:______________________________________________________________________________________________________________________________________________

E. Describe how your Program will be applied to this project:______________________________________________________________________________________________________________________________________________

12. BUSINESS CONSTRUCTION REVENUE

For the purposes of this prequalification questionnaire, "business construction revenue" shall be defined as payments to prospective Contractor for construction services as a General Contractor.

A. Can you truthfully state that your firm has had an average annual business construction revenue of at least $10,000,000 (excluding any and all legal awards) over the last five (5) consecutive years?

YES NO

B. If the entity submitting this prequalification questionnaire is a Joint Venture, can the Joint Venture entity truthfully state that each member of the Joint Venture has had an average annual business construction revenue of at least $10,000,000 (excluding any and all legal awards) over the last five (5) consecutive years?

YES NO N/A

C. Can you provide audited financial statements (if requested) for the last ten (10) years?

YES NO

If answer is “No,” what type of statements will you provide?_______________________

DO NOT INCLUDE FINANCIAL STATEMENTS WITH THIS PREQUALIFICATION QUESTIONNAIRE.

D. List average yearly volume of work for each of the past 5 years (revenue and amount of reinvestment income).

YEAR REVENUE/VOLUME REINVESTED INCOME______________ __________________________ ______________________________________ __________________________ ________________________

______________ ________________________________________________________________ __________________________________________________

______________ ________________________________________________________________ __________________________________________________

E. List value of work currently on backlog, with percent complete, as appropriate.

WORK VALUE %COMPLETE

____________________________________ ____________________________________________________________ ____________________________________________________________ ____________________________________________________________ ____________________________________________________________ ____________________________________________________________ ________________________

13. MEDIATION, ARBITRATION AND LITIGATION HISTORY (all Owners including The Regents of the University of California)

A. Separately list all CURRENT AND/OR PENDING disputes. Use #1-6 below to provide the details of each incident.

pursued via mediation, arbitration or litigation, initiated within the last fifteen (15) years, in which additional compensation is sought, and/or breach of contract is alleged, and/or indemnity is sought between your firm (or any principal of your firm) and any Owner (including The

Regents of the University of California)

1. Project Name:

2. Project Location:

3. Owner/Client Name:

4. Nature of Claim:

5. Dollar Amount of Initial Claim: $

6. Current Status:

B. If your company does not have any incidences or occurrences, please note below.

____________________________________________________________________If “None,” indicate “None” (DO NOT LEAVE BLANK).

C. Separately list all RESOLVED (SETTLED, ARBITRATED, LITIGATED) disputes:

pursued via mediation, arbitration or litigation, resolved within the last fifteen (15) years, in which additional compensation was sought, and/or breach of contract was alleged,

and/or indemnity was sought between your firm (or any principal of your firm) and any Owner (other than The

Regents of the University of California)

1. Project Name:

2. Project Location:

3. Owner/Client Name:

4. Nature of Claim:

5. Dollar Amount of Initial Claim: $

6. Dollar Amount of Final Settlement: $

7. Year Resolved (if settled)

8. Final Status:

D. If your company does not have any incidences or occurrences, please note below.

________________________________________________________________If “None,” indicate “None” (DO NOT LEAVE BLANK).

14. DISCIPLINARY MEASURES HISTORY

A. Can you truthfully state that your firm has not been disqualified or barred from doing business with a public agency (e.g., federal, state, county, city, University of California System, California State University System, etc.) within the last fifteen (15) years?

YES NO

1. If the entity submitting this prequalification questionnaire is a Joint Venture, can the Joint Venture entity truthfully state that no member of the Joint Venture has been disqualified or barred from doing business with a public agency (e.g., federal, state, county, city, University of California System, California State University System, etc.) within the last fifteen (15) years?

YES NO N/A

15. MISCELLANEOUS REQUIREMENTS

A. Has your Firm ever refused to perform change order or warranty work requested by an Owner?

YES NO


B. What is your Firm’s procedure for answering an Owner’s request to perform warranty work?

Please describe:________________________________________________________________________________________________________________________________________________

C. Describe your firm's claim-avoidance strategy and/or philosophy:________________________________________________________________________________________________________________________________________________

Documents

LEVEL 1 - University of California, San Diegormp-public.ucsd.edu/fdc/Job Bids/TUOLUMNE APARTME… · Web viewmandatory meeting location: fd&c large conference room SUBMITTALS DUE: