Upload
others
View
6
Download
0
Embed Size (px)
Citation preview
1
PROJECT: ACCRA URBAN TRANSPORT PROJECT PHASE 1
COUNTRY: GHANA
SUMMARY OF THE FULL RESETLEMENT ACTION PLAN
Appraisal Team
Team Leader: M. T. Wadda-Senghore, Principal Transport Engineer,
GHFO/OITC1
Team Members: S. E Akyea, Senior Transport Engineer, GHFO/OITC1
M. Kinane, Principal Environmentalist, ONEC3
J. D. Tonato, Chief Urban Development Officer, OITC0
F.K. Koroma, Financial Mgt Specialist, GHFO/ORPF2
D. Osei-Boakye, Procurement Officer, GHFO/ORPF1,
Mrs. Efua Amissah-Arthur, Social Development
Specialist, GHFO
Mr Jeff Turner, Gender Specialist Consultant, SEOG
Mr. Peter Ofori-Asumadu, Transport Economist,
Consultant, OITC.
Sector Director: A. Oumarou
Regional Director (ORWA): A. Bernoussi, (Acting)
Sector Manager (OITC1): J. K. Kabanguka
Country Manager (Ghana): M. Akin-Olugbade
2
Project Title: Accra Urban Transport Project phase 1 SAP Code: P-GH-DB0-017
Country: Ghana Department: OITC
Division: OITC
1. Introduction
The Accra Urban Transport Project (AUTP) Phase 1 will affect more than 200 people. In line with
the requirements of the African Development Bank (AfDB) and the Government of Ghana (GoG)
a Full Resettlement Action Plan (RAP) has been prepared. This RAP summary provides highlights
on project description; the project location and affected sites; objectives of Resettlement Action
Plan; public consultations; legal and institutional framework; social economic survey and PAP
census; eligibility criteria; potential impacts and mitigation measures; income restoration program;
implementation arrangements; implementation process; RAP implementation activities and
schedule; grievance redress mechanism; costs and budget; monitoring and evaluation mechanisms.
2. Description of the project, project area and area of influence
2.1 Project description
This project focuses on improving urban mobility in the Greater Accra Region and entails
construction of an interchange at Pokuase connecting with the Bank financed Awoshie-Pokuase
road; with planned community works, specially providing institutional and technical responses
that will help inclusive urban development, and sustainable improvement of living conditions of
the people impacted by the project. The purpose of this intervention is also to promote better
management at the levels of national and local governments, both in terms of strategic planning,
internal organization in the areas of programming, implementation and maintenance of local public
investments. The Project components are presented in the table 1 below. The total project cost is
69 million USD, which will be funded by the GoG and the Bank.
Table 1: Project Components
Project Description
A) Upgrade urban mobility and planning tools for Greater Accra Region: (i) Construction of an
interchange at Pokuase; (ii) construction of 10 km local roads; (iii) Environmental and Social mitigation
measures
B) Improvement of urban public services delivery for the Local Community: (i) Provision of IT
equipment to all the 14 schools (3 new and 13 already constructed under the Awoshie-Pokuase Project) as
well as IT training programme for girls in primary to junior high school; (viii) Support to the local
women’s groups to enhance & boost their activities.
C)
Institutional Support: this component focuses on supporting and enhancing the performance of the
Executing Agency (the Department of Urban Roads - DUR), Project Coordination Unit (PCU) and the
Local Assembly (Ga West Municipal Assembly)
D) Project Management: to ensure good management and monitoring of implementation: (i)Supervision
services for the urban transport main civil works described above; (ii) Development of an Urban
Development Master Plan for the Greater Accra region; (iii) Monitoring and Evaluation of project’s
socioeconomic impact; (iv) Road Safety: Audit, Monitoring and Sensitisation; (v) Documentary Video of
Bank funded Transport projects in Ghana; (vi) Technical Audit; (vii) Financial Audit.
Source: PCN, September 2015
3
The proposed project seeks to provide integrated solutions to urban development in Accra, one of
the main challenges of Ghana’s Transportation Sector. This objective is influenced by the Sector
Medium-Term Development Plan (SMTDP) 2014-2017 for the two Transport sector Ministries
and the Ghana Shared Growth and Development Agenda (GSGDA). The vision for these national
policy documents for the transport sector of Ghana is to provide “An integrated, efficient, cost-
effective and sustainable transportation system responsive to the needs of society, supporting
growth and poverty reduction and capable of establishing and maintaining Ghana as a
transportation hub of West Africa”.
2.2 Description of the project’s area of influence
Project area of direct influence: For the local road, a width of 7 m has been considered for the
assessment of project’s impacts. For the interchange, a radius of 200 m has been considered from
the center for the said assessment.
Extended area of influence: The site for the proposed projects falls under the jurisdiction of the
Ga-West, Ga East and Ga Central Municipal Assemblies and is bounded by seven main
communities; Pokuase, Ayawaso Amasaman, Amamorley, Ofankor, Anyaa and Kwabenya.
Whereas Pokuase, Ayawaso Amasaman, Amamorley, Ofankor are located in the Ga West
Municipal Assembly, the Kwabenya community falls under the Ga East Municipal Assembly and
Anyaa under Ga Central Municipal Assembly.
Demography: The total population of the three (3) municipalities was estimated to be six hundred
and thirty nine thousand, six hundred and thirty (639, 630) according to the 2010 Population and
Housing Census (table 2). Generally, females were estimated to be more than their male
counterparts, comprising three hundred and twenty six thousand, three hundred and twenty four
females (326,324 or 51%) and three hundred and thirteen thousand, three hundred and three males
(313,306 or 49%). Among all, Ga West had the highest population of two hundred and sixty two
thousand, seven hundred and forty two (262,742) whilst Ga Central had the least population size
of one hundred and seventeen thousand, two hundred and twenty (117,220).
Table: 2 population Size of the Studied Communities
Municipal Community Male Female
Total Freq % Freq %
Ga West
Amasaman 1,659 50.2 1,646 49.8 3,305
Pokuase 7,142 50.2 7,081 49.8 14,223
Ayawaso 2,735 49.5 2,792 50.5 5,527
Amamorley 1,492 50.4 1,469 49.6 2,961
Ofankor 12,138 49.6 12,323 50.4 24,461
Ga Central Anyaa 23,469 48.9 24,492 51.1 47,961
4
Ga East Kwabenya 653 51 627 49 1,280
Source: GSS, 2010 PHC
Socioeconomic activities: The Ga West municipality has three major economic sectors consisting
agriculture, industry and commerce. The main agricultural activities include cassava cultivation,
fishing and pineapple production whilst commerce is mainly small/ medium scale trading. There
are four main economic activities in the Ga East municipality which are industry, service,
commerce and agriculture. The industry sector can boast of establishments such as the Guinness
Ghana Breweries Limited (ABC) and Phyto Riker (GIHOC) Pharmaceuticals at New Achimota;
Trasaacco Limited, Micheletti Company and Royal Aluminum Company around Pantang and
many others.
3. Potential impacts
From baseline information gathered at the fieldwork phase and issues that transpired during the
consultation with stakeholders, the impacts of the project particularly during the construction
phase are assessed below.
3.1 Potential Positive Impacts during construction Phase and operation
The project is expected to create opportunities in terms of Employment and Income generation
for both skilled and unskilled labour. The presence of a labour force will also increase economic
and employment opportunities for residents through the sale of goods (such as food/drink, crafts,
wood etc.) and other services. The project will also increase revenue for the Municipal
Assembly. During the construction phase, material sourcing and transport will bring some revenue
to the assembly. During operation, the project would lead to an overall upgrading of the
socioeconomic setting of the area. The project would impact positively on the regional economy,
as accessibility and commercial activities would be enhanced thereby facilitating regional
economic integration. Access to services and facilities should be improved in the long-term
through greater reliability and, possibly increased availability of public transport. Public and
private transport opportunities should improve because of faster travel speeds, reduced frequency
of breakdown, and lower maintenance costs. Road Safety, Accidents and Comfort: In view of
the high volume of pedestrians in the vicinity of the proposed interchange, the issue of facilities
for pedestrians has been included in the design to cater for their needs. The design also seeks to
eliminate the steepness or poor vertical alignment that is experienced at The ACP junction, thereby
reducing the occurrence of vehicular accidents at that point. Vehicle Operating and
Transportation Costs: The project has potential to benefit road users through reduced vehicle
maintenance costs and delays. Improvement in Traffic Congestion: The development of the
interchange is expected to deal with the potential bottleneck on the Accra- Kumasi Highway
that will arise from the construction of the Awoshie-Pokuase road. An interchange will ensure
5
uninterrupted flow of traffic on the Accra-Kumasi road as well as between Pokuase ACP and
Awoshie.
3.2 Potential Negative Impacts during Construction Phase and operation
The largest impact on water quality is expected to be on the Sunkwa Stream. Road construction
will intensify the effects of natural soil erosion due to vegetation removal, soil disturbance, and
exposure of bare soil surface. Major air pollutants (dust, gaseous emissions and particulate
matter) impact on air quality. Dust pollution from construction activities will however cease in the
operation phase. Uninterrupted movement of heavy and light vehicles may cause increase in
ambient noise and vibration levels on the project road. Landscape Modification: Excavations
quarry and borrow materials stockpiling as well as the parking of construction equipment are also
expected to take place during the construction phase. Travelers and commuters may experience
possible inconvenience on the road diversions during the construction period. Solid wastes
(excavated materials, domestic solid waste), and liquid wastes would be generated whilst
rehabilitating the road. Poor sanitation and solid waste disposal in construction camps and work
sites are likely to have negative impacts on human health and the environment. Construction of
the interchange is likely to result in the temporary disruption in utility supply to areas along the
project road as well as others serviced by these lines. Disturbance to Guako Sacred Grove: The
project zone is located close to the Guako Sacred Grove. The project will encroach on about 0.096
ha of the forest land. Within the ROW, a total of three hundred and twenty three (323) Project
Affected Persons (PAPs) were identified for both the 10 km Local Roads Upgrade and the
Pokuase Interchange Project. This was made up of 144 PAPs identified on the Pokuase Interchange
Project and 179 PAPs on the 10 Km Local Roads Upgrade. The affected assets are: (i) 100
sandcrete structure single storey container/shed/wooden structure or multistorey; (ii) 101
containers; (iii) 13 walls; (iv) 24 kiosks; (v) 41 sheds; (vi) 27 wooden structures. Those structures
are used as residences, shops, multi-use, etc. In addition two unions will be affected namely, the
taxi drivers and water tankers. Conflicts will occur between the pedestrian traffic and the
activities at the working area.
During the operation phase several land use changes may occur which may lead to the loss of
the main objectives of easing traffic flow. Among the effects include: (i) Potential unplanned
developments along the corridors attracted by easy transportation; (ii) Increased demand for
residential, schools, recreation facilities and health facilities effects on public resources; (iii)
Potential increase in traffic flow and categories into the areas. Health, Safety and Security: The
construction of the interchange will allow higher traffic speed which may have subsequent impacts
such as potential increased road accidents as the road users adapt to new road use trends; (iii)
Potential immigration of business, institutions and residential facilities; (iv) Potential increased
demand on available sanitation and hygiene facilities along the corridors; (v) Increased chances
of higher infections and spread of HIV/AIDS and other communicable diseases. Interchange may
be used as event poster wall / board Churches, schools, politicians and other event organizers
for the past years had used foot bridges and interchanges in the country as event poster boards.
4. Organizational responsibility
6
The Ministry of Roads and Highways is responsible for policy formulation in the road sector. It
has oversite responsibility for the three road agencies namely Ghana Highway Authority (GHA),
Department of Feeder Roads (DFR) and the Department of Urban Roads (DUR). DUR is the
executing agency for the construction of the interchange and its ancillary projects.
DUR is responsible for implementing the project, and will therefore implement and monitor the
RAP. The identification, referencing, sensitisation, registration as well as payment of PAPs will
be carried out by the DUR. DUR has an Environmental and Safeguards Unit, which is supported
by the accounts unit will pay all PAPs due compensation.
The Land Valuation Division (LVD) of the Lands Commission is the government agency with the
statutory institution responsible for the assessment and approval of compensation values in Ghana.
LVD will value the properties of all affected persons. They will also receive and verify
documentation on affected properties before the issuance of offer letters to PAPs for payment.
The Ministry is responsible for budgetary provisions for the money to be used for the pavement of
the compensation to the PAPs. DUR made allocation for payment of PAPs in its annual budget,
this amount will be released for the payment of compensation to all affected persons.
All the organisations have the personnel and capacity to carry out their various responsibilities for
the implementation of the project.
5. Community participation
An effective resettlement planning requires continuous participation and thorough consultations
with a wide range of project affected persons and stakeholders in the general area of the project.
These include individuals or groups who will be positively or negatively affected by the project
including potential host communities. Comprehensive consultations have been held with various
stakeholders and the project affected persons from the reconnaissance stage through the public
consultations, the project affected persons census along the road; a socio-economic survey and an
assets inventory.
5.1 PAPs consultation as part of the initial ESIA and ARAP
As part of the preparation of the Abbreviated Resettlement Action Plan1 (which was not taking
into account the local roads), discussions were held in 2013 with the PAPs and relevant
stakeholders. Meetings were held with the government officials and other opinion leaders among
the community to sensitize the on the project and its effect on social-economic aspect of the
community.
The purpose was to collect and collate the opinions as part of the public/community participation
process and project design. The discussions centred on issues such as: (i) Impact of the proposed
interchange project works on the livelihood of household; (ii) land take; (iv) valuation procedures
and compensation issues. During these meetings about 90 PAPs were consulted including food
vendors mostly women, mechanics, water tankers and taxi drivers, etc.
1 The initial design (without the local roads) of the project was going to affect less than 200 people.
7
As much as all the PAP appreciate and are supportive to the project, they also had concerns.
Vehicle Operators (taxis and water tankers) and Petty Traders on site were concerned by : (i) Land
take and Disruption of Livelihood as result of the proposed Project; (ii) Traffic Disruptions; (iii)
Provision of parking area for taxi drivers; (iv) delays in payment of compensation.
The PAPs were assured that GoG will take all necessary measures to ensure that the compensation
is expedite. It was indicated, that the cut-off date will be notified to them formally in due course.
5.2 PAPs consultation as part of the current ESIA and RAP
Prior to carryout the second round of the socioeconomic survey, meetings were held with the
government officials and project affected people to sensitize them on the project and discuss the
various potential impacts. The issue of the PAPs as a result of the project was highlighted and
participants appraised on the mitigation measures available by the project.
The process of carrying out the assessment of their assets was also explained to create awareness
and form a basis for subsequent discussions. Public consultations were held at various locations as
determined by administrative boundaries for ease of administration and management of the
stakeholder’s composition and record keeping for future reference and analysis. Community
members including PAPs were consulted as follow:
Pokuase on November 28, 2014 and June 16, 2015;
Ayawaso on November 27, 2014 and June 19, 2015;
Amasaman June 17, 2015;
Amamorley June 18, 2015 and
Kwabenya November 27, 2014.
Most of the PAP have been consulted also individually through a questionnaire on a one on one
basis. In addition to the compensation . The preferred mode of compensation is cash
compensation for more than 66% of the PAPs (table 3).
Table 3: Preferred Mode of Compensation
Mode of Compensation Male Female Total
Freq % Freq % Freq %
Cash compensation 111 34.4 104 32.2 215 66.6
Resettlement at a place of my choice 16 5.0 16 5.0 32 9.9
Replace Affected part of the structure 3 0.9 6 1.9 9 2.8
Resettlement and Cash Compensation 27 8.4 36 11.1 63 19.5
Government should decide 1 0.3 1 0.3
Can't tell 3 0.9 3 0.9
Total 158 48.9 165 51.1 323 100
8
5.3. Conclusions and recommendations
Community members from Pokuase, Ayawaso and Kwabenya made their inputs into the
discussions about the project and the RAP. Some of the concerns raised prompt payment of
adequate compensation; Alternative provisions for Taxi and Tanker Drivers; Employment
opportunities for the locals should be ensured (they highlighted the need for the contractor to
include job quotas for locals), preservation of cultural/religious properties, making the project
design disability friendly and the need to involve the municipal assembly in the implementation
process. The PAPs urged that at least six (6) months grace period should be given to them to
organize and vacate the proposed area after they have been compensated.
The opinion leaders indicated that there are some customs and traditions which must be observed
by the contractors before construction begins. In Pokuase for instance, the community frowns on
behaviour such as adultery and defecating in the bush. It is also against their traditions to fetch
water from the Nsaki and Sunkwa rivers on Sundays. They advised that proper rites and
pacification be initiated before construction begins. It was also noted in Ayawaso that Shrines such
as the Asafo, Okai Kwei, Omanye, Opobi and Obuade River are located in the forest around the
Ayawaso palace and nobody is allowed to go there on Saturdays. The Obuade River is a clean
river which serves as a source of water supply for the community and therefore entry into the river
with slippers is not allowed.
The community folks advised that a well-qualified contractor should be assigned to the project.
Work must be completed on time to avoid continuous traffic, dust and congestion at the proposed
project site. Also, in the event of road diversions, there is the need for police presence to ensure
that drivers adhere or use the approved road diversions to prevent traffic. The affected persons
were mainly concerned about resettlement. They envisaged that the project will affect their
operations in that they will have to move from their current locations. They indicated that there
are alternative lands in the municipality where they can be relocated to continue their operations.
This can be done through negotiation with the Ga West Municipal Assembly. Also, the ACP
Tanker Drivers Association suggested that they could be contracted to supply water for the project
during the construction phase. In addition, to driving, the drivers said they have individual skills
such as carpentry, masonry, plumbing; steel bending etc. that can be relevant to the project.
The cutoff date after which no persons will be included in the enumeration as PAPs is 12th
December, 2014 for affected persons located at the interchange and 31 July 2015, for the local
roads PAPs. This has been formally notified to the PAPs.
6. Integration with host communities
No PAP is expected to be resettlement outside the community where they are currently. The taxi
drivers will be relocated in a terminal less than 1 km away from where they operate currently.
7. Socio-economic studies
7.1 Socioeconomic characteristics
9
Findings of Socio-economic studies conducted in the project area and among the Project Affected
Persons are highlighted in the RAP and shows that the sites for the proposed projects fall under
the authority of the Ga-West, Ga East and Ga Central Municipal Assemblies and is surrounded by
seven main communities; Pokuase, Ayawaso, Amamorley, Amasaman, Ofankor Anyaa and
Kwabenya. Whilst Pokuase, Ayawaso Amasaman, Amamorley, Ofankor are located in the Ga
West Municipal Assembly, the Kwabenya community falls under the Ga East Municipal Assembly
and Anyaa under Ga Central Municipal Assembly.
The study revealed that the project sites are currently occupied by about three hundred and forty-
three (343) individual persons and two main transport unions made up of 41 taxi drivers and 40
water tanker drivers who are likely to be affected by the project. It was agreed with the unions that
the taxi drivers and water tankers will be treated as a group. The solution will not be individualized
as for the other PAPs but will be for the registered members at the time of the survey.
Among the respondents, 50.7 percent are females and the remaining 49.3 percent are males.
Slightly more than half (51.1%) of all respondents are between the ages of 20 and 40 years while
38.7 percent is also aged 41 – 60 years (figure 1). The largest proportion (48%) of PAPs have
Junior High School/Middle School Leaving Certificate (JHS/MSLC) level as their highest
educational level followed by 18.9 percent with Senior High School/Secondary School (SHS/Sec).
Majority (72.1%) of PAPs, comprising 35.9 percent males and 36.2 percent females, are married.
PAPs that are single constitute 13.9 percent (9% males and 5% females).
A little less than half (49.2%) of the PAPs have household sizes ranging from 4 – 6 persons (table
4), this is followed by the 7 – 9 persons range comprising 20.4 percent (10.5% males and 9.9%
females).
More than half of the PAPs (55.4%), made up of 26.9 percent males and 28.5 percent females are
going to be affected by the upgrading of community roads, work around the proposed project sites
whilst 44.6 percent are going to be affected by the interchange at Pokuase.
0,0
5,0
10,0
15,0
20,0
9,0
13,014,9
6,5
3,1 1,9 0,60,3
12,1
17,0
11,5
5,9
2,2 0,9 1,2
Pe
rce
nta
ge o
f P
AP
s
Age of PAPs
Age and Sex of PAPs
Male
Female
10
Table 4: Household size
Household Size Male Female Total
Freq % Freq % Freq %
1 - 3 25 7.7 31 9.6 56 17.3
4 - 6 79 24.5 80 24.8 159 49.2
7 - 9 34 10.5 32 9.9 66 20.4
10 - 12 10 3.1 9 2.8 19 5.9
13 - 15 3 0.9 2 0.6 5 1.5
16 + 1 0.3 1 0.3
No response 7 2.2 10 3.1 17 5.3
Total 158 48.9 165 51.1 323 100
About 28.5 percent of the PAPs (11.1% males and 17.3% females) work only at the current
location whilst 15.2 percent live there only. A further 6.2 percent females and 4.3 percent males
work as well as live there whilst 0.9 only own property at the location and 0.3 rent out property
there. In the area earmarked for the proposed interchange, PAPs comprised 44.6 percent of the
total: 34.1 percent only work there, 7.1 percent live there only whilst 3.4 percent live and work
there at the same time. Almost a third (32.5%) of respondents have an average turnover of
GH¢201-200 on a good day. Half of all the respondents with large businesses have an average
turnover of more than GH¢10,000 daily.
The structures likely to be affected by the proposed project include both permanent and temporary
ones. The permanent structures comprise sandcrete multi-storeys, sandcrete single storeys whilst
the temporary structures include sheds, metal containers of various sizes, kiosks of various sizes,
wooden structures combinations of all types. The structures are being used for residential, offices,
and shops. Whereas some have multiple uses, usage as shops accounted for the bulk of the total
structures. A vast majority (84.9%) of PAPs comprising 41 percent males and 43.9 percent females
own their structures. In all, there are five (5) PAPs (4 males and one female) who have bare plots
of land with no structure on it. In Pokuase and Ayawaso, the community leaders indicated that
there is alternative land available and one only has to contact the chief and follow the necessary
procedures to obtain it. In Kwabenya however, the community leaders said that there is no
alternative land available for affected persons to relocate to.
7.2 Vulnerability analysis
A recommended by the AfDB involuntary resettlement policy, particular attention should be paid
to the needs of disadvantaged groups among those displaced. This policy defines these groups as
‘’ Distinct groups of people that may suffer dis-proportionaly from project related activities (e.g.
female-headed households, children, elderly, ethnic, religious and linguistic minorities,
handicaps, etc.). A group has been included, namely PAPs renting and residing in temporary
structures. On this basis, a total of 52 PAPs are considered vulnerable and will require additional
support. This is made up 25 males and 27 females. This represents 16.1% of total PAPs (table 5).
Table 5: Number of PAPs who are Vulnerable
11
Sex Freq %
Male 25 48.1
Female 27 51.9
Total 52 100.0
Given that some PAPs may find themselves in different subcategories, the assessment defined a
scale in terms of vulnerability: (i) vulnerable and; (ii) very vulnerable (table 6).
Table 6: Vulnerable Indicators
VULNERABILITY INDICATORS MALE FEMALE TOTAL
Freq % Freq % Freq %
Below Poverty level (less than US2 per day) 1 4 5 18 6 11.5
Elderly (60+years) 19 76 7 25 26 50.0
Widowed 0 6 22 6 11.5
Rented Temporary Structures 5 20 4 14.8 9 17.3
Elderly + Rented Temporary Structures 0 1 3.7 1 1.9
Elderly + Widowed 0 4 14.8 4 7.7
Total 25 100 27 100 52 100.0
Most of the vulnerable people are eldery of above 60 years (50%) followed by the PAPs renting
temporary structures (17%). There are 11.5% of that are considered venerable because they fall
below poverty level (table 7).
Table 7: Vulnerability Scale
Vulnerability Scale Vulnerability Indicators - Elderly Male Female Total
Freq % Freq % Freq %
Vulnerable Below Poverty level 1 4.0 5 18.5 6 11.5
Elderly 19 76.0 7 25.9 26 50.0
Rented Temporary Structures 5 20.0 4 14.8 9 17.3
Widowed 6 22.2 6 11.5
Vulnerable Total 25 100.0 22 81.5 47 90.4
Very Vulnerable Elderly + Rented Temporary Structures 1 3.7 1 1.9
Elderly + Widowed 4 14.8 4 7.7
Total Very Vulnerable 5 18.5 5 9.6
Grand Total 25 100.0 27 100.0 52 100.0
8. Legal framework, including mechanisms for conflict resolution and appeal
8.1 Ghanian laws
Ghanaian Law provides that involuntary acquisition of private property must be done in
accordance with laid down statutory procedures. The RAP was thus formulated based on several
legislative instruments of Ghana, principal among them being:
12
The Constitution of the Republic of Ghana, 1992: As enshrined in the 1992 Constitution
of the Republic of Ghana, Article 20 provides for the protection from deprivation of property
that may be compulsorily taken possession of or acquired by the State unless the following
conditions are satisfied- No property of any description or interest in or right over any
property shall be compulsorily taken possession of or acquired by the State under specific
conditions.
State Lands Act (as amended): Act 125 (as amended) is the main enactment normally used
for compulsory acquisition. It provides that the President may by Executive Instrument (EI)
acquire any land for the public interest. The modalities for the acquisition are spelt out in the
Act and its Regulation – State Lands Regulation (1962) LI 230 and culminate in the
publication of an EI. Once the EI is published, the lands specified are deemed acquired and
vested in the President. Consequently all previous interests are extinguished. The Act
provides for compensation payment based on market or replacement values. Lump sum
compensation is prescribed under the Act. Cost of disturbance and other incidental expenses
or damages are to be considered in the award of compensation. A major limitation of Act
125 is that provision has not been made for public consultation and involvement in the
acquisition process. As effective consultation is crucial for project implementation, the
acquiring agency will conduct extensive consultation with the affected locations and with
other stakeholders at every stage of project implementation;
Administration of Lands Act 1962 Act 123: Act 123 of 1962 was enacted to facilitate the
management and administration of stool lands (and other lands). The Act empowers the
Minister responsible for the lands to manage stool lands in accordance with the provision of
the law. The entitlements are however to be assessed by giving due consideration to the
values of the land (and other losses suffered) and the benefits to be derived by the people in
the area (by way of the use to which the state is going to put the land);
The Ghana Land Policy 1999: The Government of Ghana in 1999 put together the above
policy to serve as a broad framework and policy guidelines aimed at enhancing land
management systems, land use, conservation of land resource and enhancing environmental
quality. All these are intended to ensure coordinated and orderly use of land, a vital resource,
by present and future generations.
8.2 International applicable policies and requirements
The African Development Bank (AfDB) set outs five (5) main policy statements and operational
safeguards requirements that the Bank’s clients are expected to meet when addressing social and
environmental impacts and risks. These five operational safeguards (OS) are outlined as follows:
(i) OS 1: Environmental and Social Assessment; (ii) OS 2: Involuntary Resettlement: Land
13
Acquisition, Population Displacement and Compensation; (iii) OS 3: Biodiversity and Ecosystem
Services; (iv) OS 4: Pollution Prevention and Control, Greenhouse Gases, Hazardous Materials
and Resource Efficiency; (v) OS 5: Labour Conditions, Health and Safety.
The OS-2 consolidates the policy commitments and requirements set out in the Bank’s policy on
involuntary resettlement, and it incorporates refinements designed to improve the operational
effectiveness of those requirements. In particular, it embraces comprehensive and forward-looking
notions of livelihood and assets, accounting for their social, cultural, and economic dimensions. It
also adopts a definition of community and common property that emphasizes the need to maintain
social cohesion, community structures, and the social interlinkages that common property
provides. The safeguard retains the requirement to provide compensation at full replacement cost;
reiterates the importance of a resettlement that improves standards of living, income earning
capacity, and overall means of livelihood; and emphasizes the need to ensure that social
considerations, such as gender, age, and stakes in the project outcome, do not disenfranchise
particular project-affected people.
8.3 Grievance Procedures
The objective of the Grievance Redress Procedure is to address and resolve grievances or
complaints from affected persons promptly, fairly, and in a manner that is, to the extent possible,
acceptable to all parties. The following principles will be applied: (i) Provide straightforward and
accessible ways for affected persons to voice complaints or resolve any disputes that might arise
related to Project implementation; (ii) Seek solutions to any tensions and conflicts early on, to
avoid the use of a ‘firefighting’ approach; (iii) Identify and implement appropriate and mutually
acceptable actions to address complaints; (iv) Respond in a timely manner, and with sensitivity to
the needs of complainants; (v) Ensure that claimants are satisfied with outcomes of the corrective
actions, and maintain a dialogue with them to the extent possible; and (vi) Avoid resorting to higher
levels of adjudication, such as judicial proceedings, as much as possible.
All grievances will be received by the Grievance Committee (GC), through two designated PAP
representatives who are member of the Grievance Committee. The GC will have a membership of
seven (7) drawn from DUR, the Ga East and Ga West Municipal assemblies within which the
project falls. Three (3) PAPs will serve as the representatives for all the PAPs, one from each
community and one representative from an NGO will be selected to complete the GC team. The
GC will respond to any grievances that the PAPs may have during the RAP implementation.
There will be two contact people from the GC to attend to all complaints as the first step by
recording all complaints. The record will include name and contact of complainant, issue of
complaint, date and time and receiving officer. The complainant will verify that the complaint
lodged has been appropriately captured on the complaints sheet (to be designed and provided by
DUR Environmental Unit). The grievances most likely to occur during the implementation of the
RAP may include the following: (i) Disagreement over compensation amount assigned; (ii) Delays
in receiving compensation; (iii) Disagreement over asset ownership; (iv) Disagreement over
proportionate sharing of assets with joint ownership.
The Committee will meet fortnightly to consider all lodged complaints and propose measures to
address them. It is expected that all grievances would be addressed amicably at the committee
14
level. However, in the unlikely case that a particular issue proves difficult to address, the
complainant has the option of seeking redress at a higher level i.e. court of law and the committee
members will co-operate.
8.4 Grievance Procedures
The details of each grievance will be recorded on a Grievance Form, along with name and address
of the applicant, the application date, type of application, and the name of the officer receiving the
grievance. A sample form is presented in appendix ….. A database of recording grievances along
the lines described above will also be developed. In receiving the grievances of vulnerable affected
persons (e.g., women, those above 65, the illiterate, or the physically challenged), the DUR
Environmental Unit shall pay particular attention to any special needs, difficulties or concerns that
they may have. The steps for grievance redress are as follows:
Two (2) designated PAP representatives already serving on the GC shall receive
grievances/complaints for the attention of the Grievance Committee. The GC shall inform the
complainants on the status of their grievances within 7 days after the application.
If the grievance can be resolved by the GC (i.e., if it necessitates no consultation with other
organizations), possible corrective actions will be determined within 10 days. If resolution of
grievance is seen to require commitment beyond the Grievance Committee, the members shall
coordinate and consult with the relevant officials. In such cases, the time frame for the
determination of possible corrective actions shall be 15 days.
A complainant is allowed to procure the services of an independent valuer at no cost to the
PAP2, who would help that person determine an acceptable compensation. This can be
presented to the committee as a grievance.
The GC will investigate the complaints concerning processes
The Committee will communicate their proposed solution to the complainant and will also
forward to DUR PCU the complaint, the outcome of investigations and their
recommendations.
After the case has been evaluated in detail and the possible corrective actions determined, the
proposed solutions or corrective/preventive actions shall be discussed with the complainant.
PAPs that are entitled to compensation or additional compensation will receive their
entitlements from DUR Environmental Unit upon the recommendation of the Grievance
Committee.
Complaints that relate to the quantum of compensation will be referred to LVD to validate the
compensation rates with the accompanying independent valuation report clearly stating the
assumptions and rates used to arrive at compensation claims. The independent valuer of the
Complainant would be invited to meet the LVD on an agreed date to resolve the issues
involved in the disagreement. After negotiations, the LVD would communicate their
recommendations to the DUR Environmental Unit which would in turn inform the claimant
of the outcome.
If the said GC recommends payment of the claim, then the DUR Environmental Unit would
ensure that it is done before the structure under review is taken over.
2 The acquiring entity, i.e. DUR is required to pay for the expenses involved in the PAP engaging his/her own valuer.
15
Once an agreement has been reached between the applicant and the responsible party on the
corrective actions, the applicant will be asked to sign off the grievance closeout form on
his/her acceptance of the solution.
If the applicant remains dissatisfied with the outcome, additional corrective action will be
agreed on and carried out by the responsible party.
Whenever a complainant’s claim cannot be resolved satisfactorily, DUR Environmental Unit
will procure the services of an arbitrator to mediate between the complainant and said
committee. It is only after this mediation has failed that a claimant can then exercise the option
of going to Court, as provided under Section 20 under Chapter 5 of the Constitution of the
Republic of Ghana.
The Committee has a maximum of 30 days following the application within which to resolve any
grievances properly lodged with it. The applicant will then be informed by the designated officer
and the corrective actions recorded in the Grievance Closeout Form.
9. Institutional framework
The Department of Urban Roads (DUR): The Department of Urban Roads, which is another
agency within the Ministry of Roads and Highways, is a civil service institution responsible for
the provision of roads other than trunk roads in the metropolitan areas. The DUR oversees the
overall impact implications on the other road networks, the Right-Of-Way and alignment issues
including utility co-ordination works and the interface between the north-west roads project.
The Land Valuation Division (LVD): The Land Valuation Division (LVD) was formally set up in
1986 to perform functions related to valuation of various properties for specified purposes and is
now a division of the Lands Commission. The LVD is accordingly the statutory agency responsible
for the processing of compensation claims on compulsory acquisitions. The LVD will be assisted
by DUR to identify and reference permanent and temporary structures and determine
compensation value. The compensation valuation list from the LVB is forwarded to the acquiring
agency for processing and payment.
The Municipal Assemblies: The Municipal Assemblies involved will play a significant role in the
implementation of resettlement schemes and also serve as media for public education and
community consultations. Some of the administrative structures of the Assemblies, that are, offices
of the Assembly member and the Unit Committees are normally used to inform and educate people
in the project area about the intended projects, their impact and proposed mitigation measures. The
Assembly members also act as witnesses during payment of Supplemental Assistance to PAPs.
Town and Country Planning Department (TCPD)The Department was set up, among others, to
ensure that developments are done in an orderly manner and that land use is maximized. It is
responsible for the preparation of layouts for towns and cities. The TCPD ensures that the ROW
is implemented according to the approved planning schemes on each road.
The Environmental Protection Agency (EPA): The EPA was charged with the duty of prescribing
standards and guidelines relating to environmental protection and/or pollution. Development of
16
road network is one of the undertakings that require the issuance of environmental permit before
construction can be done.
Utility Agencies: The utility companies that are likely to play a role in the resettlement schemes
are: the Electricity Company of Ghana (ECG), Urban Water Company Limited (UWCL) and the
mobile phone companies. These agencies at the appropriate times will disconnect and reconnect
customers to their services before and after relocation as the case may be. Special priority has to
be given to PAPs so that they are not treated as usual applicants for services to their new places.
10. Eligibility
10.1 Eligibility
Eligibility will be based on the category of losses suffered as at the cut-off date (which in the case
of the Pokuase Interchange project was December 12th 2014). The category of losses suffered will
be identified through the various interests and rights derived from customary laws, common law
and international conventions. Eligible persons are presented in the Entitlement Matrix below.
Within the purview of the requirements of Ghanaian law and the Bank, these people are those who:
Have legal rights to land, including customary and traditional rights;
do not have legal rights to land at the time of the census but have recognized rights of
enjoyment or certain claims to the land or property; and
Occupy land although they have no legal right to it.
The cutoff date after which no persons will be included in the enumeration as PAPs is 12th
December, 2014 for affected persons located at the interchange and 31 July 2015, for the local
roads PAPs.
10.2 Proof of Eligibility
The DUR and LVD will consider various forms of evidence as proof of eligibility. The proof of
eligibility will cover: affected persons with formal legal rights, documented in the form of land
title registration certificates, leasehold indentures, tenancy agreements, rent receipts, building and
planning permits, business operating licenses, and utility bills, among others, will be eligible.
However unprocessed/unregistered formal legal documents will not bar eligibility. Procedures for
confirming authenticity of any such documents are established by LVD. These affected persons
may also include house owners and owners of residential plots with no formal or recognized legal
rights. The criteria for establishing non-formal, undocumented, unrecognized claims to eligibility
are one’s (PAP’s) presence on the corridor during the PAP census survey which ended on July 31st
2015.
10.3 Entitlement matrix
The entitlement matrix captures (table 8) all affected parties, the characteristics of the impact, and
the types of compensation/reinstatement due them. Categories in this table overlap because those
17
being offered re-instatement fall into several groupings and the groupings tend to overlap. For
instance, some of the owners of permanent and temporary structures own land as well. Again,
some of the business operators also own property such as land or structures.
Table 8: Entitlement Matrix for Pokuase Interchange and 10km Internal Roads
Category SUB-Category Type of
Loss
Compensation
for Structure
Compensation
for Loss of Other
Assets
Compensation
for Loss of
Income
Moving
Allowance
Type of
Compensation
Residents/H
ouse/Land
owners
Owners of
structures
Structure/
Location
for
Structure
Replacement
cost for
immovable
facilities
Pay full cost of
removal and
fixing of
movables
Where
applicable
Coverage of
full cost for
the total
transport
expenses
for the
removal of
chattels
Compensatio
n for
demolished
structures or
civil
improvement
Owners of
Land
(residential
plots)
Land
Compensation
for land at
prevailing
market price
- Where
applicable
- Compensatio
n for lost
parcel of land
at full
replacement
cost
Tenants
(Residential
& Business)
Rental
Accommo
dation
Relocation to
New location
of similar type
With or without
documents PAP
will be paid
compensation to
enable
relocation
Coverage of
full cost for
the total
transport
expenses
Compensatio
n for
disturbance.
One year rent
advance for
same type of
accommodati
on
Business Artisans Loss of
business
location
-
Pay full cost of
removal and
fixing of
movables
Payments in
lieu of
business
profits while
relocating -
six months
Coverage of
full cost for
the total
transport
expenses
Compensatio
n for
demolished
structures or
civil
improvements
or
compensation
for relocation
of structures
11. Valuation of, and compensation for losses
Inspection and referencing of all land, buildings and other structures falling within ROW was
carried out between 18th and 23rd December 2014 and May 2015. The purpose of the inspection
and referencing of the affected properties was to collect the descriptive and other technical data on
the affected properties. Both the internal and external areas were thoroughly inspected, except the
areas which are not accessible. The existing Buildings were sketched and measurements taken of
all buildings and other structures.
18
11.1 Data collection and analysis
Information from the Market were picked to assist in establishing appropriate Unit Rates for the
assessment of the affected Properties. Land Sales in the immediate vicinity of the subject
Properties, and similar neighbourhoods were also collected for Analysis. Capital Values of similar
properties were also obtained for analysis to derive both Unit Rates for Land and Capital Value of
the Properties. Construction Cost Data including prices of basic building materials and furnishes
were compiled from the Open Market for analysis and compilation of Unit Rates for the
assessment.
Basically, all the primary and secondary data collected were analyzed using computer applications
such as Microsoft Excel Database and AutoCAD to establish a database for the valuation of the
properties. Specific components to be completed include: (i) The preparation of measured
drawings of land and buildings to produce block plans; (ii) Preparation of schedule of
accommodation and computation of floor areas; schedules shall be prepared to show the
dimension, the gross internal and external areas of the accommodation; (iii) Lease documents, and
available correspondence shall be analyzed to find out the unexpired terms since they have a bearing
on the valuation.
11. 2 Valuation Methodology
Valuation for permanent structures: The Full Replacement Cost Method is what is used in this
FRAP for owners of permanent structures in line with Ghananian and the AfDB requirements. It
is based on the assumption that, the Capital Value of an existing development can be equated to
the cost of reinstating the development on the same plot at current labour, material and other
incidental costs; without any appropriate allowance for accrued depreciation with respect to
physical functional and economic obsolescence. The rationale behind this trend is to afford
affected owners the chance to replace their lost properties with new ones.
The first step shall be to establish the current Cost of Construction per square meter taking into
account the architectural design, building heights, layout, floor spaces, plot size, fittings and
fixtures and other physical attributes which have cost implications. The requisite information shall
be obtained by analyzing the Construction Cost of Properties comparable to the subject Property.
Necessary adjustments would be made to arrive at an appropriate rate for the subject Valuation.
An amount of external work shall be added to the Cost of “brick and mortar” depending on existing
development/improvements on the site.
Disturbance: In addition to the assessment of Land and Buildings, Disturbance will also be
assessed. Disturbance as interpreted under section 7 of the State Lands Act is the “reasonable
expenses incidental to any necessary change of residence or place of business”. By implication,
this represents the expense and other losses above the Value of Land and covers the expenses of
moving to alternative premises, cost incidental to removal such as loss of fixtures. In the case of
owner-occupiers of business, disturbance will in addition, cover the injury to the goodwill suffered
19
by the removal to alternative premises, the Loss in Value, caused by the forced sale of stock, and
also the Loss of Profits. Another form of disturbance that will be added to the value of the
properties is professional fees for Valuers and Lawyers who may be engaged by the property
affected persons to advise them on their claims for compensation.
Containers/Kiosks: Payment of supplemental assistance to owners of temporary structures will
also be made. The assessment of Supplemental Assistance is based on the premise that Temporary
Structures could be moved and relocated. Anticipated cost of transporting/moving the structures
to the desired destination would be related to the size of the structure and assumed reasonable
location. In addition to the cost of moving the structure, all temporary structures which have
concrete/sandcrete bases will be assessed to include the concrete/sandcrete works.
Land valuation: The Value of Land shall be determined by comparing Market evidence on recent
sale of plots in the vicinity or similar neighbourhoods. The rate per acre/hectare shall be established
as a basis for assessing the Land Value for the subject Property taking into consideration the
differences in attributes between the subject Property and the comparable with regards to the
specific advantages of the location.
Supplemental assistance to vulnerable people: Each person falling into this category as defined
above will receive an additional amount. This additional amount will be equivalent to 15% and
20% of the value of the compensation to be provided, respectively for vulnerable and very
vulnerable persons.
12. Identification and selection of resettlement site, site preparation and relocation
PAPs will not have to be relocated on a specific relocation site. Therefore there are no particular
measures to be taken in this regard.
13. Environmental protection
Environmental protection will be ensured in accordance with the Environmental and Social
Management Plan (ESMP) contained in the Environmental and Social Impact Assessment.
14. Implementation schedules
RAP implementation activities, responsible agencies and the time frame are agreed as tabulated
below. The PAP implementation is proposed over a period of 15 months (table 9).
Table 9: Indicative implementation schedule
Task Responsible Agencies Time Frame
Approval of the RAP DUR, EPA 3rd week, December 2015
Disclosure of the RAP in the
project area
DUR Environmental Unit, municipal
assemblies
End of December 2015
20
Task Responsible Agencies Time Frame
Formation of Grievance
Committee
DUR Environmental Unit, municipal
assemblies, PAPs
End of December 2015
Distribution of offer letters LVD , DUR Environmental Unit 2nd week, January 2016
Signing and submission of
Acceptance letters
PAPs 3rd week, January 2016
Payment of compensation Government of Ghana (Ministry of
Finance and Economic Planning), DUR
Environmental Unit
2nd week, February 2016
Assistance of the affected
population
DUR Environmental Unit, municipal
assemblies
End of February, 2016
Relocation of temporary structures PAPs, DUR Environmental Unit,
municipal officials
End of February, 2016
Demolition (Partially or fully) of
immovable structures
PAPs, DUR Environmental Unit,
municipal officials, Contractor
April, 2016
Submission of RAP
implementation report to AfDB
DUR Environmental Unit July, 2016
Monitoring and evaluation of the
living standards of the relocated
persons
DUR Environmental Unit,
NGO/Consultant
February-July, 2016
RAP completion audit report DUR Environmental Unit, Consultant,
municipal assemblies
November, 2016
15. Costs and budget
Funding of resettlement activities is incorporated into the project budget and will be provided by
the Government of Ghana. In total, it is estimated that resettlement on Pokuase Interchange will
cost three four million ninety seven thousand forty-seven and two hundred and forty seven Ghana
cedi (4,097,247 GHc). This is broken down in table 10 below. It is worth mentioning that the taxi
drivers and water tankers as treated as a group and not as individuals. The provision made are to
cover the cost of the relocation to new sites agreed with them.
Table 10: Estimated Cost of Resettlement
# Description Amount (GH¢)
1 Permanent Structures 757,870
2 Temporary Structures 163,900
3 Land (7 acres) 2,500,0003
4 Alternative site for the taxi drivers 200,000
5 Provision for supplemental assistance to vulnerable PAP 80,000
Sub Total 3,701,770
6 Water Tankers Cost of construction of a new water
abstraction point included in the works
7 Marking & Referencing of affected Properties (DUR) 3,000
8 Valuation of Property by Land Valuation Division 5,000
9 Survey of Land by Survey and Mapping Division 5,000
10 Grievance and Redress Committee 8,000
11 Sensitization Campaign 10,000
3 Prior to the beginning of the works, this section will be updated to take into account the PAPs that shall be compensated as part of the Awoshie Pokuase project.
21
Sub Total 23,000
Total 3,724,770
12 Monitoring and auditing and other implementation activities 372,477
Grand Total 4,097,247
16. Monitoring and evaluation
Project monitoring and evaluation will include internal and external monitoring, AfDB supervision
missions, a mid-term review and a final evaluation incorporating the completion report of the
implementing agencies.
DUR Environmental Unit will oversee the implementation program and make sure project
activities are executed on time. The objectives of the RAP will be regularly monitored and
evaluated to assess its relevance, efficiency and impact.
Basically, monitoring will ascertain that: (i) PAPs are successfully relocated and re-instated to
pre-project levels; (ii) difficulties facing PAPs in the new location are identified and addressed;
(iii) Record of experiences are kept for future reference; (iii) internal performance monitoring
milestones will enable DUR judge progress on the ground against indicators set out in the RAP;
(iv) Support for vulnerable groups is appropriately conducted; (v) All complaints are considered
and the deliberations made known.
Objective and verifiable indicators should be defined to ensure an effective and efficient
monitoring of the RAP. In this regard, the following indicators in the table 11 below can be used.
Before the beginning of the works DUR will update the RAP and its indicators where applicable.
Table 11: Monitoring indicators Monitoring
Parameter
Responsible Indicators / Period Performance Objectives
Participation PAP/DUR Number and type of PAPs
Number of PAPs taking part
Number of households and persons who
have been physically displaced due to
the construction of the right-of-way
All PAPs and their property have
been identified
Negotiation
and
compensation
PAP/LVD Nature and amount of compensation by
PAPs
Number of reports of agreements signed
All PAPs entitled to compensation
have been compensated
A consensus has been reached on
the compensation due all PAP
Moving and
resettlement
process
DUR/GWMA Number of PAPs made aware
Number of PAPs properly resettled
All PAPs to be resettled have so
been as planned
Resolution of
all legitimate
grievances
Grievance
Committee/Attorney
General/DUR
Number of conflicts
Types of conflicts
Reports of resolved cases (agreements)
(monthly)
All disputes have been resolved
amicably
Satisfaction of
PAPs
Grievance
Committee/DUR Number of PAPs made aware
Type of support granted
Number of PAPs satisfied
All PAPs are satisfied with the
resettlement conditions
The impact assessment will involve conducting a comparative analysis based on a baseline
situation study at project take-off, a situation study at mid-term and another at end of project. It
22
will be entrusted to an external competent entity in Ghana. Terms of reference for service delivery
will be developed for this purpose by the project management unit. An external audit of the
implementation of the RAP will be performed to verify the conformity of its implementation.
List of documents consulted
Environmental and Social Impact Assessment (ESIA) report, 2015
Social Impact Assessment report, 2015
Environmental and Social Management Plan (ESMP) report, 2015
Resettlement Action Plan report, 2015
For the African Development Bank
Mam Tut Wadda-Senghor, Principal Transport Engineer,
AfDB Ghana Office, E-mail: [email protected]
Modeste Kinane, Principal Environmental Specialist,
AfDB Headquarters, Cote d’Ivoire, E-mail: [email protected]