Upload
others
View
2
Download
0
Embed Size (px)
Citation preview
Page 1 of 51
TRINIDAD AND TOBAGO
IN THE HIGH COURT OF JUSTICE
SAN FERNANDO
Claim No. CV2007-02193
BETWEEN
RAGHUNATH SINGH & COMPANY LIMITED
Claimant
AND
NATIONAL MAINTENANCE TRAINING AND
SECURITY COMPANY LIMITED
Defendant
BEFORE THE HONOURABLE JUSTICE PETER A. RAJKUMAR
Appearances:
Mr. Ashraph for the Claimant
Mr. Colin Kangaloo instructed by Ms. Nadia Kangaloo for the Defendant.
Judgment
Page 2 of 51
Index Page
Background 3
The Claim 4
Issues 4
Conclusion 4
Disposition and Orders 5
Analysis and Reasoning 6
Facts not in issue 6
The Defendant’s case 7
Law 7
Issue 1 whether a contract had been concluded 7
Whether the contract between the claimant and the Defendant was frustrated 9
Findings 13
Law on frustration 20
The Conceptual Basis 22
Analysis 34
Construction of the contract – its nature and surrounding circumstances – findings 35
What was contracted for – the terms and construction of the contract 35
Alleged supervening event 36
How does the alleged supervening event affect if at all delivery of what was contracted for 36
Contractual provision/knowledge of the parties 37
Control over event 37
Issue – Whether the claimant has proved its damages in relation to its claim for loss of profit 37
Law – Proof of special damage 38
Loss of profit – Terminated contracts 41
The principles summarised 42
i. The nature of the claim/value 44
ii. The difficulty or ease with which proper evidence of value might be obtained 45
Loss of Profit arising from non availability of rental equipment 47
Has the claimant mitigated its loss 49
Conclusion 50
Disposition and Orders 51
Page 3 of 51
Background
1. The claimant responded to the invitation of the defendant, acting as agent for the
Government of Trinidad and Tobago to tender for a contract for the construction of the Palo Seco
High School (the school). The defendant’s tender of $22,297,672.32 was accepted on February
28th
2002. The claimant was asked to provide a performance bond, which it did on March 21st
2002 at a cost of $81,548.67.
2. The invitation to tender provided at clause 5(1) that the claimant was advised to visit the
proposed construction site and its surroundings prior to tender.
3. The site was 15 feet away from a producing oil well. Petrotrin – the operator of that well
declined to abandon it.
4. The cost of abandoning oil wells on the site was estimated to be $400,000.00 but the
defendant was of the view that it could escalate to $1 million.
5. It also came to the view after it accepted the tender that the Environmental Management
Authority would be reluctant to issue a certificate of environmental clearance for the site, which
was to be used for a school.
6. The claimant received no further written communication from the defendant until
September 11, 2002, when the defendant informed it that its client had issued instructions to
cease the commencement of activities, and that it was “seeking arrangements to acquire an
alternative site”. “ ..MTS is unable to enter into a formal agreement with your firm and
handover of the site for commencement of the works.”
7. The defendant declined to proceed with the contract.
Page 4 of 51
The claim
8. The Claimant claimed against the Defendant for:
(a) Damages for breach of contract made between the Plaintiff and the Defendant on or about
the 28th
day of February, 2002 for the construction by the Plaintiff of the school
(b) Further and/or in the alternative damages for loss or profit.
The claimant specifically pleads a claim for loss of profit under the contract in the amount of
$2,297,672.32 or 10% of its value, as well as the cost of the performance bond.
Issues
9. (a) Whether a contract had been concluded between the claimant and the defendant.
(b) If so, whether the contract between the Claimant and the Defendant had been frustrated
thereby relieving the Defendant of any obligations and/or liability under it.
(c) Whether the Claimant proved its claim for damages in relation to its claims for loss of
profit, to cost of performance bond, and loss of profit arising from inability to use its equipment.
Conclusion
10. a. A contract was concluded by the letter, (wrongly dated February 28th
2001), and
issued on February 28th
2002, accepting the claimant’s tender. No further contract document was
required to constitute a binding contract.
b. The circumstances in which the defendant elected not to proceed with the contract do not
amount to events of frustration and the defendant cannot claim to be absolved from its
obligations and liability under the contract.
The claimant is under an obligation to prove its damages and loss.
Page 5 of 51
c. It has not been disputed that the claimant was called upon to provide a performance bond
after acceptance of its tender and that it indicated to the defendant that it had complied by letter
of March 21st 2002. It claimed that it incurred a cost of $81,548.67 to do so, which evidence I
accept, as it was not disputed.
11. Given, however, that the major part of its claim is for in excess of $2 million representing
loss of profits of 10% of the contract value, I find that it has failed to supply sufficient evidence
of appropriate probative value in respect of that aspect of its claim.
12. In the circumstances I find that, in default of such evidence, the claimant has established,
a claim to nominal damages with respect to this aspect of its claim, and an award of nominal
damages is therefore made, in addition to the cost to it of establishing the performance bond.
13. The claim for loss of profit arising from inability to use its equipment was not pleaded,
and I find that it has not been proved.
Disposition and Orders
14. The defendant is to pay to the claimant:-
i. The sum of $81,548.67, (the cost of the performance bond).
ii. Interest thereon at the rate of 6% per annum from March 21st 2002.
iii. Nominal damages in the sum of $20,000.00 in respect of loss of profit.
iv. Interest thereon at the rate of 12 % per annum from the date of service of the writ.
v. Costs on the basis prescribed by the Civil Proceedings Rules for a claim in the total amount
as calculated above.
Page 6 of 51
Analysis and Reasoning
Facts not in issue
15. The Claimant alleges that on December 9, 2001 it submitted to the Defendant a tender for
a contract for the building of the Palo Seco High School at a price of $22,297,672.32.
16. Its tender was accepted by letter of February 28, 2002.
17. The Claimant effected a Performance Bond incurring a cost of $81,548.67.
18. On or about September 11, 2002 the Defendant informed the Plaintiff that it was unable
to proceed with the said contract and the works because it was making arrangements to obtain an
alternative site for the construction of the said school.
19. The Claimant alleged that it the Defendant is in breach of the contract and the Plaintiff
has incurred and suffered financial loss and particularised this as follows:
(a) Cost of establishing Performance Bond $81,548.67.
(b) Loss or profit at 10% of contract price $2,229,762.20.
20. The Defendant claims
i. That the said contract was frustrated. It pleaded:-
“ …. Alternatively the alleged contract was frustrated in that it became impossible of
performance without there being any fault on the part of the Defendant and in the
Page 7 of 51
premises, the Defendant was discharged from the performance of the alleged
contract due to matters pleaded at paragraph 10 hereinabove.”. (See paragraph
11 of the Defence)
ii. That by letter dated September 11, 2002 it indicated to the Plaintiff that it was unable to
enter into a formal agreement with the Plaintiff.
iii. That it is not liable to the Plaintiff for its claim for loss of profit.
The defendant contends that
21.
i. The contract between the Claimant and the Defendant was frustrated and the Defendant is
therefore not liable under this contract.
ii. The Claimant has led no probative evidence of its loss of profit and is therefore not
entitled to such damages.
iii. Even if such sum is proven, the Claimant has not mitigated its loss and is not entitled to
the loss of profit claimed. I consider it unnecessary to this decision to address this last
matter.
Law
Issue 1-Whether a contract had been concluded?
22. I find that it cannot seriously be contended that no contract had been concluded.
See for example Halsbury's Laws of England/CONTRACT (VOLUME 9(1) (REISSUE))/3.
669. Provisional agreements.
Page 8 of 51
Where there is an informal agreement which expressly requires or envisages the
subsequent execution of a formal contract, the legal effect of that prior informal
agreement at common law depends on the intention of the parties, as with letters of intent.
They may have entered into a binding provisional agreement, whilst envisaging its
subsequent replacement by a more formal one; or they may evince an intention only to
be bound on the execution of the formal contract, the prior informal agreement being of
no legal effect.
Where there is a definite acceptance of an offer to enter into a provisional agreement,
the fact that it is accompanied by a statement that the acceptor desires that the
arrangement should be put into a more formal shape does not relieve either party from
his liability under the provisional agreement, for instance: …an informal acceptance of
a tender for a large building contract;
If the envisaged formal contract does materialise, it may exactly reflect the terms of the
prior provisional agreement, in which case it may have little more than an evidential
value. Alternatively, it may differ materially from the provisional agreement, so that it
may be material to decide whether it has replaced that provisional agreement.
23. In this case the tender provides the answer in that the form of tender, provided by the
defendant, and duly completed by the claimant, at clause 5.5 provides “ unless and until an
agreement is prepared and executed, this tender, duly signed on the page overleaf, together with
your written acceptance thereof, shall constitute a binding Contract between us. “
24. Further Clause 33.1 of the conditions of contract provides that the employer will notify
the successful tenderer that his tender has been accepted (“by a letter of acceptance”).
Page 9 of 51
25. Further under clause 33.2 – The notification of award will constitute formation of the
contract.
a. The tendering documents comprised (para6-1) the invitation to tender, instructions to
tenderers, the conditions of contract part 1 and part 2, specimen forms, technical
specifications, bills of quantities and drawings.
b. The tender itself comprised (para.12-1) the form of tender, the bid bond, the priced bill of
quantities. Obviously therefore the effect of acceptance of the tender was to create a
binding contract, with at least conditions of contract and prices having been agreed at that
stage.
26. The Defendant’s letter of acceptance dated the 28th February, 2002 (erroneously dated
28th
February, 2001), constituted the notification of award.
27. There is therefore no ambiguity. A contract was concluded between the parties. At issue
is whether that contract was frustrated.
Whether the contract between the Claimant and the Defendant was frustrated
Factual Chronology
28. The circumstances in which the contract was not proceeded with are set out in the witness
statement of Mr Loreilhe, Divisional Manager of the defendant (“MTS”) who testified via his
witness statement as follows: - (summarized with emphasis added)
1. MTS was the Construction Management Agency for inter alia the design, construction, of
the Palo Seco High School (“the High School”).
Page 10 of 51
2. The initial choice of site for the construction of the High School (“the Original Site”),
chosen by the Ministry of Education, was approximately sixteen (16) acres and contained
two (2) non-functional oil wells.
3. The consultants believed that the technology was available to safely abandon the oil wells.
4. On February 7, 2001 an Environmental Assessment of the site was commissioned.
5. On October 15, 2001, EPTM Consulting Services Limited (“EPTM”) was engaged to
produce tender documentation for the plugging and abandonment of the two (2) oil wells
on the Original Site. EPTM was also subsequently engaged by MTS to manage the
implantation of the plugging and exercise of abandoning the two (2) oil wells.
6. (I find that it is clear therefore that MTS was the party who was overseeing the issues that
the presence of those oil wells on the original site could have caused and that they were
aware that there were such potential issues at that original site.)
7. On October 16, 2001 tenders were invited by MTS for the construction of the High School.
On December 6, 2001, MTS recommended Raghunath Singh & Co. in respect of the High
School with a tender sum of $22,297,672.32.
8. During December 2001, MTS received approval from the Ministry of Finance for the
award of tenders in respect of the said seven (7) schools and contracts were awarded by
MTS for six (6) schools, also during December 2001. However, the letter of award for the
High School was not issued as MTS was awaiting information for the projected date of the
implementation of the plugging and abandonment of the two (2) oil wells on the Original
Site
29. It is clear therefore that MTS was well aware that the plugging of oil wells on the
original site was an issue critical to any award.
30. The design and supervision consultants Gillespie and Steel Limited provided updated site
layout drawings and it was then discovered that they had shifted the Original to a position that
placed it close to a producing oil well (“the proposed new Site”) belonging to the Petroleum
Company of Trinidad and Tobago (“Petrotrin”). By its letter to MTS dated October 11, 2001
Page 11 of 51
however, Petrotrin had indicated that the Proposed new Site may pose a greater potential health
and safety risk to the occupants of the High School primarily because the perimeter of the
Proposed Site was only approximately fifteen (15) metres from a producing oil well and
other non-producing wells which would also have to be abandoned.
31. On January 10, 2002, MTS commissioned an air quality monitoring programme which
allegedly confirmed that there were no toxic emissions on the proposed new Site.
32. At a meeting between MTS and Raghunath Singh & Co. on February 6, 2002, MTS
advised that the abandonment of the producing Petrotrin oil well would be executed during
the month of March 2002.
33. On February 27, 2002, it was decided that the Proposed Site would be handed over to
Raghunath Singh & Co. on March 1, 2002 and that a letter of award would accordingly be
issued.
34. By letter erroneously dated February 28, 2001, instead of 2002, MTS certified that the
tender of Raghunath Singh & Co. had been accepted at a contract price of $22,297,672.32
exclusive of Value Added Tax. By the said letter, MTS also requested Raghunath Singh & Co.
to commence acquisition/consideration of the following to facilitate prompt commencement of
the works when instructed:
a. Performance Bond;
b. Insurances for the Works;
c. Advance Payment Guarantee;
Page 12 of 51
d. Detailed Implementation Schedule and Methodology Statement.
35. Raghunath Singh & Co. subsequently posted a performance bond in the sum of
$81,548.67.
36. No formal contract was executed as required by Clause 34 the Tender Documents. (I
have found that this makes no difference whatsoever).
37. On March 18, 2002, the approximate cost of the abandonment project was found to be
$400,000.00. MTS determined that, given the uncertainty of safely, securely and permanently
capping a producing oil well, the cost of the abandonment project could amount to as much as
$1,000,000.
38. At a meeting held between MTS and the Environmental Management Authority
(“EMA”) on March 19, 2002, the EMA raised the issue of conducting a risk assessment of the
Proposed Site.
39. A Risk Assessment Report was submitted April 19, 2002. The Report recommended the
shutdown of the producing Petrotrin oil well.
40. On March 27, 2002, MTS was instructed to apply for a Certificate of Environmental
Clearance (“CEC”) from the EMA.
Page 13 of 51
41. By letter dated April 29, 2002, the Project Management Unit of the Ministry of Finance
instructed that Petrotrin be urgently approached with respect to the shutdown of the producing oil
well with the alternative that a new site should be identified and acquired as soon as possible.
42. By letter dated April 30, 2002 MTS wrote to Petrotrin requesting permission to abandon
the producing oil well.
43. By letter dated May 20, 2002 Petrotrin advised MTS that it was unwilling to abandon the
producing oil well. MTS had no control over this position taken by Petrotrin.
44. By letter dated June 11, 2002 the EMA advised that an Environmental Impact
Assessment (“EIA”) was required for the proposed construction of the High School.
45. On August 8, 2002, he prepared a report on the status of sites for secondary schools. The
report recommended that a thorough investigation should be made of alternative sites prior to
any EIA study being done on the Proposed Site.
46. By letter dated August 7, 2002 from SEMPCU to MTS, SEMPCU confirmed that it was
quite obvious that a new site would have to be found for the High School since it appeared that
the EMA would not have provided a CEC for the Proposed Site. The SEMPCU letter also
confirmed that SEMPCU would not construct on a site for which it did not have a CEC from the
EMA or at least a response from the EMA which was not negative to the site. Given the concerns
of the EMA and the danger of building the High School near a producing oil well, it was
neither safe nor commercially feasible to build the High School on the Proposed Site. As a
Page 14 of 51
result of these matters, on September 11, 2002 MTS issued a letter to Raghunath Singh & Co.
informing them that MTS was unable to enter into a formal agreement with them.
Despite the best efforts of MTS, ….at no time, prior to and/or after the award of the tender to
Raghunath Singh & Co., was MTS in a position to hand over the Proposed Site to Raghunath
Singh & Co. for the construction of the High School.
Findings
47. The effect of the defendant’s evidence by its witness statement is that:-
i. there was an original site identified.
ii the original site was shifted to a proposed new site.
The original site contained 2 non producing oil wells which would have had to be abandoned. It
is clear therefore that MTS was well aware that the plugging of oil wells on the original site was
an issue critical to any award.
48. The proposed new site contained non functioning oil wells as well as being 15 metres
from a producing oil well.
49. MTS knew this by in or around October 11th 2001 as Petrotrin so advised it by letter.
50. MTS advised the claimant that the producing oil well would be abandoned in March
2002.
Page 15 of 51
51. MTS decided on February 27th 2002 that the proposed site would be handed over to the
claimant on March 1 2002 and a letter accepting the claimant’s tender was issued on February
28th
2002.
52. It subsequently transpired that-
i. Petrorin was not willing to abandon the producing oil well
ii. The cost of abandonment was determined to be $400,000.00 with a possible increase to
one million dollars
iii. An environmental impact assessment ,(EIA) would be required
iv. Rather than conduct the EIA the defendant decided to identify alternative sites.
53. It is clear that:-
a. the fact that oil wells, both producing and non producing, needed to be abandoned and there
must be a cost to this. Notwithstanding this MTS handed over the proposed site to the claimant.
b. the fact that there was a producing oil well in proximity to the site was an issue that was
known to MTS. They were so told by Petrotrin, and they conducted air quality tests. The effect
of its presence therefore could have been the subject of inclusion in any subsequent contract with
the claimant.
c. in fact MTS went so far as to tell the claimant in a meeting on February 6th 2002, they allege,
that the well would be abandoned in March 2002. The basis on which it did so is not explained
in the defendants witness statement.
d. it was never the case that the EMA took any action that would have prevented the
implementation of the contract.
Page 16 of 51
54. Petrotrin’s position that it was not willing to hand over the site was a reason put forward
by the defendant for not being able to hand over the site. However the fact that the producing oil
well had to be dealt with, and the possibility that Petrotrin may not have wished to abandon a
producing oil well were factors that must have been known to the defendant before it decided to
accept the tender of the claimant.
55. The letter of Petrotrin is dated October 11th
2001 refers to a meeting in October 2001
where the defendant was present and recognized the risks. Petrotrin then placed the claimant on
notice that the presence of the producing well 15 metres away from the perimeter of the proposed
site meant the scope and financial implications for the well abandonment effort for the new site
as well as the required actions to address the potential risks would be greater than originally
envisaged. Petrotrin’s letter also referred to it having been originally contemplated that Petrotrin
would be doing the abandonment work and MTS would pay it to do so.
56. The letter of award to the claimant was wrongly dated February 27th
2001 but in fact the
actual date was February 27th
2002.
57. At a meeting between MTS and Raghunath Singh & Co. on February 6, 2002, MTS
advised that the abandonment of the producing Petrotrin oil well would be executed during
the month of March 2002.
58. This is evidence which, if I accept it, is adverse to the defendant in the circumstances of
this case. There is no reason not to accept it. Its significance is that MTS was clearly assuming
responsibility for dealing with the producing oil well, and advising the claimant of this. In fact
that well was outside the parameters of the proposed site, and the claimant had no control over
that area in any event.
Page 17 of 51
59. It is also significant in that MTS clearly therefore recognized that the abandonment of
that producing oil well was important and had to take place.
60. Any abandonment exercise had to be effected by Petrotrin, as previously agreed with
Petrotrin.
61. Further, as the oil well was under the control of Petrotrin, it could not be abandoned
unless Petrotrin agreed.
62. It is reasonable to infer therefore that the advice to the claimant suggests that MTS had
some basis for advising the claimant that the abandonment would take place in the month of
March 2002.
63. Even if it did not that would have been the impression that MTS conveyed to the
claimant- that the producing well was to be abandoned and that MTS would see to the
arrangements in this regard with Petrotrin.
64. A Risk Assessment Report was submitted April 19, 2002. The Report recommended the
shutdown of the producing Petrotrin oil well.
65. This was highly foreseeable and I so find. It did not require an independent agency to
point out that it was sensible to undertake a risk assessment of the possible hazards associated
with a producing oil well so close to a high school.
Page 18 of 51
66. Even if the assessment determined that there was no risk it was prudent to first ascertain
this before accepting a tender, and concluding a contract.
67. The claim that the position of the EMA subsequently became a problem is clearly an
afterthought. In light of Petrotrin’s letter the haste to accept any tender before clarifying the
position with respect to the abandonment of the producing oil well, an assessment of the health
and safety issues surrounding construction of a school in the vicinity of such a well, and the cost
of abandoning this and other non producing wells, is inexplicable.
68. I find that the potential danger of building a high school near a producing oil well was
apparent to MTS well before the acceptance of the tender of the claimant. The reports,
recommendations and correspondence that it refers to, all after the fact of such acceptance, did
not constitute any new information. Logic and commonsense would have suggested that the
position regarding that oil well be confirmed with Petrotrin, before deciding to accept a tender
for construction of an adjacent school.
69. The defendant could have provided for these matters in its acceptance. It could have
made its acceptance of tender conditional upon the site being handed over, or the wells being
abandoned. Instead it proceeded to instruct the claimant to provide performance bond, insurance,
guarantees, and a detailed implementation and methodology statement, without referring to the
possibility that the site may not have been available if the wells could not be abandoned. The
reason for the haste in accepting the claimant’s tender in those circumstances has not been
satisfactorily explained.
70. The Court was asked to find that the contract was frustrated by the presence of the oil
well and the fact that it became dangerous to build a school in accordance with the tender on
such site. Tthe Defendant contended that to proceed to construct the school on the proposed site
Page 19 of 51
would have caused a danger to the school and its occupants and as such the Defendant could
not take the risk of building the school on that site. Further, that the building of the school
near the producing oil well would render the performance of any contract radically
different from that which was agreed to be undertaken originally, in particular given the
uncertainty of safely, securely and permanently capping the producing oil well and the cost
of so doing.
71. In fact however it did not become any more dangerous after the acceptance of the award
as it had been before the award.
72. The Court was asked to make a finding that not only would costs have increased but to
build the school taking into account the presence of the oil well would lead to the contractor
rendering a performance fundamentally different from what the original tender contemplated.
73. I am unable to accept this. The contract was for the construction of a building on a site.
The contract was awarded after the defendant was aware of the risks associated with the presence
of the producing oil well and the need for the abandonment of this well and other non producing
wells. It commissioned an air quality monitoring programme in January 2002 by Kaisen which
reported that there were no toxic emissions.
74. The effect of that oil well was therefore clearly in its contemplation when it accepted the
claimant’s tender in February 2002. The facts that
(a) The defendant’s assumption that Petrotrin would abandon that oil well was unjustified, and
(b) It subsequently had a change of heart concerning whether it was a sensible risk to take to
construct a school so close to a producing oil, and
Page 20 of 51
(c) It became uncertain whether the EMA was likely to grant it approval to do so,
do not detract from the countervailing fact that the presence of the oil well, and its impact on the
site was known to the defendant before it accepted the tender.
75. On the evidence, the Defendant had control of the site and was responsible for ensuring its
suitability and, before entering the contract, they knew of the risk or potential risk.
Law - Frustration
Chitty on Contracts Volume 30th
edition paragraph 23-050 page 1508
76. The Davis Contractors case. It is in building contracts that the best illustration may be
found of the principle that “it is not hardship or inconvenience or material loss which calls the
principle of frustration into play”, unless there is a radical change in the obligation. In Davis
Contractors Ltd v Fareham U. D.C. the plaintiffs agreed to build 78 houses for the defendants at
a fixed price, the work to be completed in eight months. Due partly to bad weather, but also to
an unforeseen shortage of labour caused by the unexpected lag in the demobilisation of troops
after the war, the work took 22 months to complete, and cost the builders some £17,000 more
than they anticipated. The builders claimed that the shortage of labour and the delay had
frustrated the contract, so that they were entitled to sue for the £17,000 on a quantum meruit.
The House of Lords unanimously held that the contract had not been frustrated. Viscount
Simonds denied that:
“...where, without the default of either party, there has been an unexpected turn of
events, which renders the contract more onerous that the parties contemplated that is by
itself a ground for relieving a party of the obligation he has undertaken.”
Page 21 of 51
Chitty on Contracts Volume 30th
edition paragraph 23-059 page 1514
77. Significance of a foreseen event, the parties to the contract may not have made express
provision for the event which has occurred but they may have foreseen it happening. In such a
case, the fact that the parties have foreseen the event but not made any provision for it in their
contract will usually, but not necessarily,
prevent the doctrine of frustration from applying
when the event occurs. While an unforeseen event will not necessarily lead to the frustration of
a contract. a foreseen event will generally exclude the operation of the doctrine. The inference
that a foreseen event is not a frustrating event is only a prima facie one and so can be excluded
by evidence of contrary intention. Thus, it is a question of construction of the contract whether
the parties intended their silence to mean that the contract should continue to bind in that
event, or whether they intended the effect of the event, if it occurs, to be determined by any
relevant legal rules. If one party foresaw the risk, but the other did not, it will be difficult for
the former to claim that the occurrence of the risk frustrates the contract. On the other hand, a
contract may be frustrated by supervening illegality, notwithstanding the fact that the war which
has brought about the supervening illegality was foreseen.
Chitty on Contract paragraph 23-060 page 1515
78.
The issue which the court must consider is whether or not one or other party has
assumed the risk of the occurrence of the event. The degree of foreseeability required to
exclude the doctrine of frustration is, however, a high one:
“...foreseeability’ will support the inference of risk-assumption only where the
supervening event is one which any person of ordinary intelligence would regard as
likely to occur... the contingency must be ‘one which the parties could reasonably be
thought to have foreseen as a real possibility.”
Page 22 of 51
Frustration - The Conceptual Basis
79. In Davis Contractors Limited v Fareham Urban District Council [1956] 2 All
E.R. 145 per LORD REID at pages 152g to 153 e (all emphasis added)
In order to determine how far the arbitrator's findings are findings of law and,
therefore, subject to review, I think it is necessary to consider what is the true basis of
the law of frustration. Generally, this has not been necessary; for example, Lord
Porter said in Denny, Mott & Dickson Ltd v James B Fraser & Co Ltd ([1944] 1 All
ER 678 at p 687):
“Whether this result follows from a true construction of the contract
or whether it is necessary to imply a term or whether again it is more
accurate to say that the result follows because the basis of the
contract is overthrown, it is not necessary to decide … “
These are the three grounds of frustration which have been suggested from time to
time, and I think that it may make a difference in two respects which is chosen.
Construction of a contract and the implication of a term are questions of law,
whereas the question whether the basis of a contract is overthrown, if not dependent
on the construction of the contract, might seem to be largely a matter for the
judgment of a skilled man comparing what was contemplated with what has
happened. And, if the question is truly one of construction, I find it difficult to see
why we should not apply the ordinary rules regarding the admissibility of extrinsic
evidence whereas, if it is only a matter of comparing the contemplated with the
actual position, evidence might be admissible on a wider basis. Further, I am not
satisfied that the result is necessarily the same whether frustration is regarded as
depending on the addition to the contract of an implied term or as depending on the
construction of the contract as it stands.
Frustration has often been said to depend on adding a term to the contract by
implication: for example, Earl Loreburn in F A Tamplin SS Co Ltd v Anglo-Mexican
Page 23 of 51
Petroleum Products Co Ltd ([1916] 2 AC 397 at p 404), after quoting language of
Lord Blackburn, said:
“That seems to me another way of saying that from the nature of the contract
it cannot be supposed the parties, as reasonable men, intended it to be
binding on them under such altered conditions. Were the altered conditions
such that, had they thought of them, they would have taken their chance of
them, or such that as sensible men they would have said 'if that happens, of
course, it is all over between us'? What, in fact, was the true meaning of the
contract? Since the parties have not provided for the contingency, ought a
court to say it is obvious they would have treated the thing as at an end?”.
I find great difficulty in accepting this as the correct approach, because it seems to
me hard to account for certain decisions of this House in this way. I cannot think that
a reasonable man in the position of the seaman in Horlock v Beal ([1916] 1 AC 486)
would readily have agreed that the wages payable to his wife should stop if his ship
was caught in Germany at the outbreak of war, and I doubt whether the charterers in
Bank Line Ltd v A Capel & Co ([1919] AC 435) could have been said to be
unreasonable if they had refused to agree to a term that the contract was to come to
an end in the circumstances which occurred. These are not the only cases where I
think it would be difficult to say that a reasonable man in the position of the party
who opposes unsuccessfully a finding of frustration would certainly have agreed to an
implied term bringing it about.
Page 153 h-154a
I think that there is much force in Lord Wright's criticism in Denny, Mott & Dickson
Ltd v James B Fraser & Co Ltd ([1944] 1 All ER at p 683):
“The parties did not anticipate fully and completely, if at all, or provide for
what actually happened. It is not possible to my mind to say that, if they had
thought of it, they would have said, 'Well, if that happens, all is over between
Page 24 of 51
us'. On the contrary, they would almost certainly on the one side or the other
have sought to introduce reservations or qualifications or compensations.”
It appears to me that frustration depends, at least in most cases, not on adding any
implied term but on the true construction of the terms which are, in the contract,
read in light of the nature of the contract and of the relevant surrounding
circumstances when the contract was made. There is much authority for this view. In
British Movietonews Ltd v London & District Cinemas Ltd ([1951] 2 All ER 617),
Viscount Simon said (ibid, at p 625):
“If, on the other hand, a consideration of the terms of the contract, in the light
of the circumstances existing when it was made, shows that they never agreed
to be bound in a fundamentally different situation which has now unexpectedly
emerged, the contract ceases to bind at that point—not because the court in its
discretion thinks it just and reasonable to qualify the terms of the contract, but
because on its true construction it does not apply in that situation.”
Page 154 d-e
On this view, there is no need to consider what the parties thought, or how they or
reasonable men in their shoes would have dealt with the new situation if they had
foreseen it. The question is whether the contract which they did make is, on its true
construction, wide enough to apply to the new situation: if it is not, then it is at an
end.
Lord Radcliff at page 159g-i
Frustration is not to be lightly invoked as the dissolvent of a contract.
Lord Loreburn ascribes the dissolution to an implied term of the contract that was
actually made. This approach is in line with the tendency of English courts to refer all
Page 25 of 51
the consequences of a contract to the will of those who made it. But there is something
of a logical difficulty in seeing how the parties could even impliedly have provided for
something which, ex hypothesi, they neither expected nor foresaw; and the ascription
of frustration to an implied term of the contract has been criticised as obscuring the
true action of the court which consists in applying an objective rule of the law of
contract to the contractual obligations that the parties have imposed on themselves.
So long as each theory produces the same result as the other, as normally it does, it
matters little which theory is avowed (see British Movietonews Ltd v London &
District Cinemas Ltd ([1951] 2 All ER 617 at p 624 per Viscount Simon)). But it may
still be of some importance to recall that, if the matter is to be approached by way of
implied term, the solution of any particular case is not to be found by inquiring what
the parties themselves would have agreed on had they been, as they were not,
forewarned. It is not merely that no one can answer that hypothetical question;
it is also that the decision must be given “irrespective of the individuals concerned,
their temperaments and failings, their interest and circumstances” (Hirji Mulji v
Cheong Yue SS Co ([1926] AC 497 at p 510)). The legal effect of frustration “does
not depend on their intention or their opinions, or even knowledge, as to the event”
(ibid, at p 509). On the contrary, it seems that, when the event occurs, the
“meaning of the contract must be taken to be, not what the parties did intend
(for they had neither thought nor intention regarding it), but that which the
parties, as fair and reasonable men, would presumably have agreed upon if,
having such possibility in view, they had made express provision as to their
several rights and liabilities in the event of its occurrence”
(Dahl v Nelson, Donkin & Co ((1881) 6 App Cas 38 at p 59, per Lord Watson)).
Page 160 d-e
So, perhaps, it would be simpler to say at the outset that frustration occurs whenever
the law recognises that, without default of either party, a contractual obligation has
Page 26 of 51
become incapable of being performed because the circumstances in which
performance is called for would render it a thing radically different from that which
was undertaken by the contract. Non haec in foedera veni. It was not this that I
promised to do. There is, however, no uncertainty as to the materials on which the
court must proceed.
“The data for decision are, on the one hand, the terms and construction of the
contract, read in the light of the surrounding circumstances, and, on the other hand,
the events which have occurred”
Page 160g
But, even so, it is not hardship or inconvenience or material loss itself which calls the
principle of frustration into play. There must be as well such a change in the
significance of the obligation that the thing undertaken would, if performed, be a
different thing from that contracted for.
Page 161g-h
Two things seem to me to prevent the application of the principle of frustration to this
case. One is that the cause of the delay was not any new state of things which the
parties could not reasonably be thought to have foreseen. On the contrary, the
possibility of enough labour and materials not being available was before their eyes and
could have been the subject of special contractual stipulation. It was not made so. The
other thing is that, though timely completion was, no doubt, important to both sides, it is
not right to treat the possibility of delay as having the same significance for each….
80. In National Carriers Ltd v Panalpina (Northern) Ltd [1981] 1 All E.R. 161 at page
165c per Lord Hailsham
The doctrine of frustration is of comparatively recent development.
Page 27 of 51
It is generally accepted that the doctrine of frustration has its roots in the decision of
the Court of Queen's Bench given by Blackburn J in Taylor v Caldwell (1863) 3 B & S
826, [1861–73] All ER Rep 24. (Lord Hailsham LC at page 165 c-e)
Lord Hailsham LC at pages165g-166f
At least five theories of the basis of the doctrine of frustration have been put forward
at various times, and, since the theoretical basis of the doctrine is clearly relevant to
the point under discussion, I enumerate them here. The first is the 'implied term', or
'implied condition', theory on which Blackburn J plainly relied in Taylor v Caldwell as
applying to the facts of the case before him. To these it is admirably suited. The
weakness, it seems to me, of the implied term theory is that it raises once more the
spectral figure of the officious bystander intruding on the parties at the moment of
agreement. In the present case, had the officious bystander pointed out to the parties in
July 1974 the danger of carrying on the business of a commercial warehouse opposite
a listed building of doubtful stability and asked them what they would do in the event of
a temporary closure of Kingston Street pending a public local inquiry into a proposal
for demolition after the lease had been running for over five years, I have not the least
idea what they would have said, or whether either would have entered into the lease at
all. In Embiricos v Sydney Reid & Co [1914] 3 KB 45 at 54, [1914–15] All ER Rep 185
at 188 Scrutton J appears to make the estimate of what constitutes a frustrating event
something to be ascertained only at the time when the parties to a contract are called
on to make up their minds, and this I would think, to be right, both as to the
inconclusiveness of hindsight which Scrutton J had primarily in mind and as to the
inappropriateness of the intrusion of an officious bystander immediately prior to the
conclusion of the agreement…
Hirji Mulji v Cheong Yue Steamship Co Ltd is, it seems to me, really an example of the
more sophisticated theory of 'frustration of the adventure' or 'foundation of the
contract' formulation, said to have originated with Jackson v Union Marine Insurance
Co Ltd (1874) LR 10 CP 125, [1874–80] All ER Rep 317; cf also eg per Goddard J in
W J Tatem Ltd v Gamboa [1938] 3 All ER 135 at 144, [1939] 1 KB 132 at 138. This, of
Page 28 of 51
course, leaves open the question of what is, in any given case, the foundation of the
contract or what is 'fundamental' to it, or what is the 'adventure'. Another theory, of
which the parent may have been Earl Loreburn in F A Tamplin Steamship Co Ltd v
Anglo-Mexican Petroleum Co [1916] 2 AC 397, [1916–17] All ER Rep 104, is that the
doctrine is based on the answer to the question, 'What, in fact, was the true meaning
of the contract?' (see [1916] 2 AC 397 at 404, [1916–17] All ER Rep 104 at 108). This
is the 'construction theory'. In Davis Contractors Ltd v Fareham Urban District
Council [1956] 2 All ER 145 at 160, [1956] AC 696 at 729 Lord Radcliffe put the
matter thus, and it is the formulation I personally prefer:
'… frustration occurs whenever the law recognises that, without default of
either party, a contractual obligation has become incapable of being
performed because the circumstances in which performance is called for
would render it a thing radically different from that which was undertaken by
the contract. Non haec in foedera veni. It was not this that I promised to do.'
In all fairness, however, I must say that my approach to the question involves me in the
view that whether a supervening event is a frustrating event or not is, in a wide variety
of cases, a question of degree, and therefore to some extent at least of fact, where in
your Lordships' House in Tsakiroglou & Co Ltd v Noblee & Thorl GmbH [1961] 2 All
ER 179, [1962] AC 93 the question is treated as one at least involving a question of law,
or, at best, a question of mixed law and fact: page 166g
Lord Wilberforce at page 170
2. Various theories have been expressed as to its justification in law: as a device by
which the rules as to absolute contracts are reconciled with a special exception which
justice demands, as an implied term, as a matter of construction of the contract, as
related to removal of the foundation of the contract, as a total failure of
consideration. It is not necessary to attempt selection of any one of these as the true
basis; my own view would be that they shade into one another and that a choice
Page 29 of 51
between them is a choice of what is most appropriate to the particular contract under
consideration. One could see, in relation to the present contract, that it could
provisionally be said to be appropriate to refer to an implied term, in view of the grant
of the right of way, or to removal of the foundation of the contract, viz use as a
warehouse. In any event, the doctrine can now be stated generally as part of the law
of contract; as all judicially evolved doctrines it is, and ought to be, flexible and
capable of new applications. Lord Wilberforce at page 170
Lord Simon of Glaisdale at page 175
I. Frustration of a contract takes place when there supervenes an event (without default
of either party and for which the contract makes no sufficient provision) which so
significantly changes the nature (not merely the expense or onerousness) of the
outstanding contractual rights and/or obligations from what the parties could
reasonably have contemplated at the time of its execution that it would be unjust to
hold them to the literal sense of its stipulations in the new circumstances; in such
case the law declares both parties to be discharged from further performance. Page
175
Fourthly, a number of theories have been advanced to clothe the doctrine of frustration
in juristic respectability, the two most in favour being the 'implied term theory' (which
was potent in the development of the doctrine and which still provides a satisfactory
explanation of many cases) and the 'theory of a radical change in obligation' or
'construction theory' (which appears to be the one most generally accepted today). My
noble and learned friends who have preceded me have enumerated the various theories;
page 176.
Lord Roskill at page 184 f-h
The doctrine is principally concerned with the incidence of risk: who must take the risk
of the happening of a particular event, especially when the parties have not made any
Page 30 of 51
or any sufficient provision for the happening of that event. When the doctrine is
successfully invoked it is because in the event which has happened the law imposes a
solution casting the incidence of that risk on one party or the other as the circumstances
of the particular case may require, having regard to the express provisions of the
contract into which the parties have entered. The doctrine is no arbitrary dispensing
power to be exercised at the subjective whim of the judge by whom the issue has to be
determined. Frustration if it occurs operates automatically. Its operation does not
depend on the action or inaction of the parties. It is to be invoked or not to be invoked
by reference only to the particular contract before the court and the facts of the
particular case said to justify the invocation of the doctrine. Page 184
Lord Roskill at page 188a-d
My Lords, I do not find it necessary to examine in detail the jurisprudential foundation
on which the doctrine of frustration supposedly rests. At least five theories have been
advanced at different times: see the speech of Lord Wilberforce in Liverpool City
Council v Irwin [1976] 2 All ER 39 at 43, [1977] AC 239 at 253–254. At one time
without doubt the implied term theory found most favour, and there is high authority in
its support. But weighty judicial opinion has since moved away from that view. What is
sometimes called the construction theory has found greater favour. But my Lords, if I
may respectfully say so, I think the most satisfactory explanation of the doctrine is
that given by Lord Radcliffe in Davis Contractors Ltd v Fareham Urban District
Council [1956] 2 All ER 145 at 159–160, [1956] AC 696 at 728. There must have been
by reason of some supervening event some such fundamental change of circumstances
as to enable the court to say, 'This was not the bargain which these parties made and
their bargain must be treated as at an end', a view which Lord Radcliffe himself tersely
summarised in a quotation of five words from the Aeneid: 'Non haec in foedera veni.'
Since in such a case the crucial question must be answered as one of law (see the
decision of your Lordships' House in the Tsakiroglou case) by reference to the
particular contract which the parties made and to the particular facts of the case in
Page 31 of 51
question, there is, I venture to think, little difference between Lord Radcliffe's view
and the so-called construction theory. Page 188.
81. In the case of CTI Group Inc v Transclear SA [2008] EWCA Civ 856
Facts
The dispute between the parties arose out of a contract made between the buyers and the
sellers on 7 May 2004 for the sale of 27,000mt of Indonesian cement in bulk fob the
“Mary Nour” at Padang. The sellers were unable to provide a cargo for the vessel at
Padang and on 17 May the parties entered into a substitute contract for the sale of the
same quantity of cement on substantially the same terms save that shipment was to be
made in Taiwan. In the event, however, the sellers failed to provide a cargo for the vessel
in Taiwan either, and as a result the buyers made a claim against them for damages in
the sum of US$449,726.96 representing the loss incurred in obtaining a cargo from an
alternative source in Russia: Moore-Bick LJ at page27a-b
In para 3 of the award the arbitrators record that it was common ground that the
supplier at Padang had declined to provide a cargo because of pressure brought to bear
on it by Cemex and that Cemex had also used its influence to persuade the supplier in
Taiwan to withdraw its offer of a cargo: page 27
Moore-Bick LJ at page 29a-d paragraph 6
The arbitrators held that in those circumstances the contract had become impossible of
performance. They expressed their conclusion in the following terms:
“39 The only conclusion which we could reach on the evidence was that there could
be no doubt that performance of the substance of the contract – the provision of a
cargo of bulk cement to be shipped from Asia to Mexico on the 'MARY NOUR' – had
become commercially impossible by 17 May 2004. Although (as one would expect) the
precise means by which this commercial embargo on the project was effected was
unclear, it seemed to be equally incontrovertible that it had resulted from pressure
Page 32 of 51
placed by Cemex on the potential suppliers once Cemex became aware that the
contract had been concluded. From that perspective, it struck us that this was indeed a
situation in which the contractual performance had become commercially impossible
and the only alternative performance (involving a shipment from the Mediterranean
or Black Sea area) was fundamentally different from that contemplated by the parties
. . . .”
On the appeal Field J took a different view of the matter. He held that the contract was
not frustrated because the sellers had taken the risk of a failure of their contemplated
source of supply. Page 29
Page 31-32 paragraphs 13-15 Moore-Bick LJ
[13] The dictum of Lord Radcliffe in Davis v Fareham at p 729 that:
“frustration occurs whenever the law recognizes that without default of either party a
contractual obligation has become incapable of being performed because the
circumstances in which performance is called for would render it a thing radically
different from that which was undertaken by the contract. Non haec in foedera veni. It
was not this that I promised to do.”
is generally accepted as encapsulating the modern law on frustration. However, not
every supervening event which prevents performance of the contract will result in its
being frustrated because it may be apparent from the general nature of the contract, its
particular terms and the context in which it was made that it was intended to apply in
the circumstances that have arisen. Thus in Davis v Fareham Lord Reid said at p 720:
“It appears to me that frustration depends, at least in most cases, not on adding any
implied term, but on the true construction of the terms which are in the contract read in
light of the nature of the contract and of the relevant surrounding circumstances when
the contract was made . . . . On this view there is no need to consider what the parties
thought or how they or reasonable men in their shoes would have dealt with the new
situation if they had foreseen it. The question is whether the contract which they did
Page 33 of 51
make is, on its true construction, wide enough to apply to the new situation: if it is
not, then it is at an end.”
[14] As each of these passages makes clear, it is essential to the doctrine of frustration
that the performance of the contract in the new situation should be fundamentally
different from that originally contemplated. In deciding whether that is the case it is
necessary to have regard to the general nature of the contract as well as its specific
terms, the context in which it was made and the contemplation of the parties as to the
range of circumstances in which it might come to be performed. Having regard to the
nature of the arbitrators' findings it is important to recognise that a contract will not
necessarily be frustrated simply because performance has become impossible, as some
of the cases to which our attention was drawn show, and that it will not be frustrated
simply because one party is prevented from performing in the manner originally
intended if performance in some other manner is possible.
[15] A good example of this latter point is to be found in J Lauritzen AS v Wijsmuller
BV (The “Super Servant Two”) [1990] 1 Lloyd's Rep 1, in which this court considered
the position of a contracting party placed, as a result of a supervening event for which
he had no responsibility, in the position of being unable to perform one or other of two
contracts. In that case Wijsmuller had agreed to transport a drilling rig belonging to
Lauritzen from Japan to Rotterdam using one or other of two specialised vessels,
“Super Servant One” and “Super Servant Two”. Wijsmuller intended to perform the
contract using “Super Servant Two”, but after the contract had been made “Super
Servant Two” sank. Wijsmuller had entered into other contracts which they could only
perform with “Super Servant One” and in the event they chose to perform those
contracts instead of their contract with Lauritzen. In proceedings brought by Lauritzen
Wijsmuller contended that the contract had been frustrated as a result of the sinking of
“Super Servant Two”, but that was rejected on the grounds that since the contract
provided for the use of either vessel, the loss of “Super Servant Two” did not render
performance impossible or fundamentally different.
Page 34 of 51
Page 35a-b
That obligation will be discharged by frustration if a supervening event not
contemplated by the contract renders that performance impossible or fundamentally
different from what was originally envisaged, but most events which result in the failure
of a supplier to provide the goods will not fall into that category.
Page 36b
However, as Lord Reid made clear in Davis v Fareham in the passage cited earlier, the
court is not concerned with what the parties thought or how they would have dealt with
the new situation if they had foreseen it, and the finding that performance had become
“commercially impossible” must be understood in the context of the award as a whole.
Page 36d-e
In order to rely on the doctrine of frustration it is necessary for there to have been a
supervening event which renders the performance of the seller's obligations impossible
or fundamentally different in nature from that which was envisaged when the contract
was made.
Analysis
82. In Panalpina, Davis and CTI Group v Transclear the alleged frustrating events were
found to be insufficient to successfully invoke the doctrine.
83. Whether the different theoretical bases of the doctrine of frustration all form part of a
continuum, any aspects of which may be applicable depending on the circumstances
(paraphrasing Lord Wilberforce in Panalpina), or whether the construction theory which is now
Page 35 of 51
in favour applies, from a practical perspective the exercise at trial requires a finding on each of
the following:-
1. What was contracted for- the terms and construction of the contract.
2. What was the alleged supervening event
(together the “data for decision” – per Lord Radcliff in Davis).
3. How does the alleged supervening event affect, if at all, delivery of what was contracted
for. Does it render the contractual performance now possible radically different from
what was undertaken? – (per Lord Radcliff at 729).
4. What provision does the contract make for happening of the alleged supervening event,
expressly, or, (far more likely when frustration is being alleged), impliedly?
5. What did the parties know about the possibility of the alleged frustrating event?
6. Which party if any had a greater degree of control over the happening of the alleged
frustrating event?
The last three matters, if applicable at all, go directly to the issue of which party impliedly
accepted the risk of the alleged frustrating event occurring.
Construction of the contract – its nature and the surrounding circumstances - Findings
84.
1. What was contracted for- the terms and construction of the contract.
The contract was for construction of a school at a specific site. The defendant was aware that the
site was near a producing oil well. There was no “new state of things that the parties could not
reasonably have foreseen”. The oil well was before their eyes. It could have been the subject of
express contractual stipulation.
Page 36 of 51
2. Alleged Supervening Event
85. The alleged supervening/frustrating event is the difficulty posed by the inability to have
the producing oil well capped/abandoned. The defendant could have made express contractual
stipulation for this. The terms of contract emanated from it. It did not do so.
86. At the time that it agreed to accept the tender of the claimant it contemplated
abandonment of the oil well taking place in the following month. The presence of that oil well
was not a surprise to it. Petrotrin had informed them of the presence of that well since the
previous year. The producing well was off the site and the defendant itself says that it expected
to have dealt with its abandonment by March 2002.
87. It is clear on the evidence that the defendant understood that the cost of the abandonment
exercise would be for its account. This is apparent from Petrotrin’s letter which predated the
acceptance of the claimant’s tender.
88. There is no evidence that Petrotrin ever gave any assurance to the defendant that it would
willingly give up production of that well and abandon it. In the absence of such an assurance it is
difficult to understand the defendant’s haste to accept a tender for construction of a school at that
site.
3. How does the alleged supervening event affect, if at all, delivery of what was
contracted for. Does it render the contractual performance now possible radically different
from what was undertaken?
Page 37 of 51
89. In the instant case the Defendant’s evidence is not that it was impossible to build on the
site but that it was more onerous. There is absolutely no evidence that the contract was
impossible to perform. On the authorities this is not sufficient to invoke frustration.
4. Contractual provision/knowledge of the parties
90. As to what provision the contract makes for happening of the alleged supervening event,
expressly or impliedly, I find that while the contract made no provision for the possibility of the
oil well not being abandoned, it is clear that the defendant knew about that distinct possibility
and that it considered that to be its responsibility. Furthermore, the distinct possibility that the
producing well would not be capped because Petrotrin would not agree, or that the cost of doing
so would be excessive, was a real likelihood. I find that it was one which any person of
reasonable intelligence would regard as likely to occur. See Treitel – Frustration and Force
Majeure – paragraph 13-009 - Degree of forseeability at page 466
5. Control over event
91. On the evidence it is the defendant which had a greater degree of control over the
happening of the alleged frustrating event, and chose to assume the risk that the oil well, which it
knew of, would have been abandoned by Petrotrin. These matters support the conclusion that the
Defendant accepted the risk of the supervening event.
I find that the contract therefore could not be deemed to be frustrated by its occurrence.
Issue
92. Whether the Claimant has proved its damages in relation to its claim for loss of
profit?
Page 38 of 51
Law - Proof of special damages
93. Pretrial loss is an item of special damage. It has to be pleaded, particularized and strictly
proved. See Charmaine Bernard (Legal Representative of the Estate of Regan Nicky
Bernard) v Ramesh Seebalack [2010] UKPC 15 at paragraph 16 Sir John Dyson SCJ (citing
Perestrello) infra:
In Bonham Carter v Hyde Park Hotel [1948] 64 TLR Lord Goddard CJ stated that parties
“must understand that if they bring actions for damages, it is for them to prove their damage; It
is not enough to write down the particulars, so to speak, throw them at the head of the court
saying ‘this is what I have lost; I ask you to give me these damages’. They have to prove it.”
94. The degree of strictness of proof that is required depends on the particular
circumstances of each case.
(a) As Bowen L.J. stated in Ratcliffe v Evans (1892) 2 Q B 524, 532 - 533: (all emphasis
added)
“In all actions accordingly on the case where the damage actually done is the gist of the action,
the character of the acts themselves which produce the damage and the circumstances under
which these acts are done, must regulate the degree of certainty and particularity with which
the damage done ought to be stated and proved. As much certainty and particularity must be
insisted on, both in pleading and proof of damage, as is reasonable having regard to the
circumstances and to the nature of the acts themselves by which the damage is done. To insist
upon less would be to relax old and intelligible principles to insist upon more would be the vainest
pedantry.”
(b) In Civil Appeal 41 of 1980 Gunness and Another v Lalbeharry, the appellant was injured in
a vehicular collision. In an action for damages for negligence the Judge allowed certain claims and
disallowed others. Among the claims disallowed was a claim for special damages relating to the loss
of various items of jewelry, handbag, cosmetics and $75.00 in cash. On Appeal the Court held that
the Judge erred in disallowing the claim. Braithwaite J.A with whom the other members of the Court
of Appeal agreed stated(@ page 2 ):
“In disallowing the appellant’s claim for these items, the judge merely stated:
Page 39 of 51
‘From the evidence which she gave and which was unsupported, I find that you failed to prove such
loss.’
There is no evidence to contradict the evidence of the appellant nor had she been shown not to be a
credible witness. There is therefore no justification for the judge’s finding in this respect. The fact
that her evidence is unsupported is clearly not sufficient to deny her claim for a loss which must be
taken, in the absence of evidence to the contrary, in the circumstances of her loss of consciousness
to be at least strong prima facie evidence of the fact which she alleged.” (all emphasis added)
(c) That a measure of flexibility exists in the degree of proof required for special damages was
confirmed by the Court of Appeal in Civil Appeal 162 of 1985 Uris Grant v Motilal Moonan Ltd.
and Frank Rampersad, where Ratcliffe v Evans was applied.
The appellant’s furniture and other articles were destroyed when a vehicle ran off the road and
crashed into a house in which she lived. She claimed damages in respect of the destroyed chattels.
According to the evidence the appellant had made a detailed list of the things destroyed the day
following the accident. In the statement of claim the Appellant’s special damage claim had been
particularized. A default judgment was taken up, and in the assessment before the Master, the
appellant produced in evidence the list she had prepared which itemized each item and the price
thereof. She however produced no receipt verifying the price she had paid for the items. She
admitted that she did not have such receipts, nor did the appellant retain the services of a valuator to
value the damage.
The Master held that the appellant had failed to prove the value of the items and awarded an “ex
gratia” payment. The Court of Appeal held that the Master erred. The Court at page 16 noted that the
appellant’s evidence as to her loss represented strong prima facie evidence and was unchallenged.
With respect to the lack of receipts to support her claim, it stated: - By the production in evidence of
the list of chattels destroyed together with the costs of their replacement, the appellant had
established a prima facie case both of the fact of loss of those articles and of the costs of their
replacement at the time. Her special damage had to be established on a balance of probabilities. The
respondent called no evidence in rebuttal. In the event, the Master, in my view, either had to accept
the appellant’s claim in full or, if for whatever reason she had reservations she should have
approached the matter along the lines in Ratcliffe’s Case by applying her mind judiciously to each
item and the cost thereof in the list. This she did not do. Instead she merely, as stated earlier, made
Page 40 of 51
an ex gratia award. She did so on the premise, wrongly in my view, that the appellant had called no
evidence of any kind in support of her claim.
In my view, the Master erred. The appellant did call prima facie evidence of her replacement costs
the fact of which, as I said was unchallenged. At this stage I must pose the question whether in this
country it is unreasonable, in a case of this kind, for a person to be unable to produce bills for
clothing, groceries, watches, kitchen utensils, furniture and/or other electrical appliances and/or
for that matter to remember the time of the purchase. To my mind, this is clearly in the negative and
to expect or insist upon this is to resort to the “vainest pedantry.”
With regard to proof of special damage the authors of McGregor on Damages citing the dictum of
Bowen, L.J. in Radcliffe’s Case supra and quoted earlier in this judgment state that in proof as with
pleading, “the courts are realistic and accept that the particularity must be tailored to the facts.” (all
emphasis added)
d. In a more recent decision of the Court of Appeal, David Sookoo, Auchin Sookoo v
Ramnarace Ramdath Cv. App No. 43 of 1998 per M.A de la Bastide, C.J, delivered
12th
January 2001, it was confirmed that that degree of flexibility had limits, depending
on inter alia:-
(i) The circumstances,
(ii) The nature of the claim,
(iii) The difficulty or ease with which proper evidence of value might be obtained, and
(iv) The value of the item involved.
“It is common experience that items of special damage are sometimes not proved to the hilt and
yet the Court may make an award in respect of them. It is a matter which depends on the
circumstances and evidence in each case. The Court has to decide whether on the material
before it, it can arrive at some acceptable conclusion as to the amount which it should award.”
(At page 4)
“…..These are the cases on which counsel for the Respondent relies. The sort of evidence which
a Court should insist on having before venturing to quantify damages will vary according to the
Page 41 of 51
nature of the item in respect of which the claim is made and the difficulty or ease with which
proper evidence of value might be obtained. It would also, depend in part on the value of the
individual item. It may not be reasonable to require expert evidence of the value of used
household items but where one is dealing with a motor-vehicle which usually has considerable
value, and in respect of which there should be no difficulty in securing proper evidence of
value, then the Court is entitled to adopt a more stringent approach.
I, accept the correctness of the decision in Grant’s case but that case is clearly distinguishable
on the facts from ours”. (At page 5)
e. See also the discussion on proof of special damages by the Honourable Justice of Appeal
Archie as he then was at pages 8 to 11 of the case of Civ. App. No. 20 of 2002 Anand Rampersad
v. Willie’s Ice Cream Limited – applying all of the above cases – as follows:-
At page 8 – “I wish to emphasise that the fact that a defendant may not challenge the values of
destroyed items given by the plaintiff does not automatically entitle the plaintiff to recover
whatever is claimed. The rule is that the plaintiff must prove his loss”.
At page 10 – “None of the latter three cases should be understood as derogating in any way
from the principle that the plaintiff must prove any special damages claimed. In particular, Uris
grant, which may appear to bear some similarity to the present case, is merely an example of a
case where the degree of particularity accepted by the Court of Appeal was considered to be
appropriate in those special circumstances. In this case the Plaintiff/Respondent is a commercial
enterprise. It would have been reasonable to expect that some evidence of the value of the
larger items could be found in its books and records.”
At page 10 –“ a lesser degree of strictness would apply to proof of the value of smaller items
such as kettles, mops (etc .In accordance with Uris Grant the Master, in the absence of any
evidence to the contrary, would have been entitled to accept a reasonable figure”.
At page 10-11 “the plaintiff cannot simply present a list of prices, it must show the basis on
which the figures are established” (all emphasis added)
Page 42 of 51
95. In Hudson’s Building and Engineering Contracts, Eleventh Edition, Volume 1 at
paragraph 8-172 it is stated:-
“Loss of Profit
Terminated Contracts
In ‘total prevention’ cases, where a contract has been discontinued as a result of the
owner breach, the Robinson v Harman compensatory principle will, in the more usual
case where work has been partially performed at the time of termination, entitle the
contractor to the full contract value of any work done up to that time, less sums
previously paid and possibly also, ... a sum for profit lost on the remaining work ...
...establishing a claim for loss of profit on uncompleted work following a contractor’s
rescission or termination may not be practical for a number of reasons, namely:
(1) The contractor must be able to establish that his contract prices for the remaining
work would as a fact have been profitable. This will depend primarily on the adequacy
of his original estimating and pricing of the cost of the contract, rather than any profit
percentage used when pricing ...” (emphasis added)
96. There has been no evidence before this Court on the adequacy of the original
estimating of the Bill of Quantities or the pricing under this tender, and furthermore no
probative evidence of the adequacy of the pricing of the cost of the contract has been given by a
person who was directly involved in the pricing exercise. Rather, what has been given in
evidence by Mr. Ali is a profit percentage used when pricing. This according to Hudson’s does
not show that the contract would as a fact have been profitable and the extent of such profit.
The defendant’s counsel’s submission to this effect is accepted.
97. The Claimant has only the evidence of Mr. Zaid Ali. Mr. Ali is a Finance Manager of the
Claimant. He is not a Quantity Surveyor. He states at Paragraph 8 of his witness statement:-
Page 43 of 51
The Claimant has been in the construction business for over 30 years. When preparing the
tender the value ascribed to any particular job would take into account a profit ranging between
15% to 20%. What is done is that a cost buildup estimate is prepared; this would represent an
estimate of the actual cost. To this estimate is added 15% to 20% which represents the
contractor’s profit margin. In the tender for the Palo Seco High School the mark up representing
the Claimant’s profit was 20%. If one factors in unforeseen events for example bad weather,
price increases both in material and labour and productivity problems then as a worst off
situation the profit margin would not fall below 10%. The agreed contract price was
$22,297,672.32 so that the Claimant having regard to the Defendant’s breach of contract would
have loss (sic) profit on the basis on 10% in the sum of $2,229,762.20.
98. Mr. Ali testified that he was involved in the tender but did not prepare the Tender and the
Bill of Quantities. As Finance Manager he was unable to provide evidence of what was involved
in the pricing of individual items in the Bills of Quantities associated with this tender. His
evidence as to whether there was a profit on each item, and if so what was that percentage profit
or even whether there was such a profit was in the form of generalizations, both in his witness
statement and under cross examination, as the record of his evidence reflects. It was not
supported by any calculations or analysis or documentation, though he admitted that such
documentation and records did exist. For example the “cost build up estimate” representing
actual cost was not produced.
99. It is quite clear from paragraph 8 of his Witness Statement that he was uncertain as to the
percentage profit that the Claimant Company could be expected to make under this contract,
especially as there is not a shred of documentation or accounting information to support it.
100. In that paragraph Zaid Ali states that the profit for this contract could be 20 % but no
lower than 10%, even taking into account “unforeseen events”. That could not be considered
Page 44 of 51
probative, far less cogent or compelling evidence, as to the level of profit, if any that could be
obtained from this contract.
101. The onus in this matter was on the Claimant to prove its loss of profits strictly.
The principles summarised
1. The principles revealed by the cases are that special damages must be particularized and
pleaded. (See Seebalack)
2. Special damages must be proved by evidence.
3. The degree of proof varies depending on
(i) The circumstances,
(ii) The nature of the claim,
(iii) The difficulty or ease with which proper evidence of value might be obtained,
and
(iv) The value of the item involved. (See Sookoo)
4. Even prima facie evidence may, in some instances suffice if not rebutted or
challenged, and common sense must be applied in deciding whether such
evidence can reasonably be expected to be available to the claimant. – (Uris
Grant, Guinness v Lallbeharry)
The nature of the claim/ value
102. In this case the quality of the evidence must be considered in the light of the nature of
the claim. The claim is for loss of profit of 10% of the contract price. That is in excess of 2
Page 45 of 51
million dollars. The evidence in support is set out in the witness statement of Mr. Ali is
singularly lacking in specifics.
The difficulty or ease with which proper evidence of value might be obtained
103. The company has records. It has a duty to support such a substantial claim by reference to
material that demonstrates inter alia,
a. that it is likely to have made a profit in the first place
b. that its tender actually did have a margin of profit built into it.
The various possibilities were that
(i) It did have a profit margin built into each item of 20 % as claimed,
(ii) That it had a profit margin that averaged out to be 20% on each item,
(iii) That it had a profit margin of some other amount,
(iv) That it had tendered at a loss as its costs were above the price tendered for some or all items.
104. After the close of evidence the claimant has provided no sufficient material to determine
which if any of these scenarios applies.
105. The unsupported assertion that there was a 20 per cent markup, that, when discounted for
unforeseen events for example bad weather, price increases both in material and labour and
productivity problems could not fall below 10 %, is extremely unconvincing.
106. Evidence from the records or quantity surveying personnel of this company that it had
properly costed the items in its tender, that it had a track record of performing construction
contracts and achieving at least this level of profit, that delays had been adequately considered
and costed, and the actual impact of such delays on the anticipated profit level projected, or in
fact any substantive material supportive of its claim, would have been more convincing than
what was in fact produced.
107. The failure to present such material led to the inference that there was no such material,
or that such material as existed did not support the claimant’s claimed loss of profit. Mr Ali's
Page 46 of 51
evidence on the aspect of proof of claim for loss of profit under cross examination was simply
not convincing as it, like his witness statement, was lacking in specificity.
108. His refusal to accept that when the uncertainties (to which he adverted in his witness
statement), were taken into account, the level of profit might have been less than 10%, while
maintaining that it could have been more, emphasized the self serving nature of his evidence on
this aspect. It also demonstrated why it could not be relied upon as establishing the alleged or
any percentage profit.
109. Evidence of the level of profit in other similar contracts by this contactor could have been
produced to establish that it was capable of and had generated profits on construction contracts
previously. The rough and ready, back of a napkin approach to the claim for special damages for
loss of profit is not adequate in this case, or compatible with a claim for in excess of two million
dollars.
110. The facts, records, and accounts that would be supportive of such a claim would be
expected to be within the custody and control of the claimant, a commercial enterprise, whose
records would be critical to its operations in determining for example whether it is profitable, the
amount of tax it needs to pay, and the accuracy of its pricing. These were not disclosed or
produced.
111. The Claimant’s witness provided no satisfactory method and analysis for coming to the
conclusion that its loss of profit was 10% of the contract price. He was not in a position to give
this evidence without the records of the company, which he did not produce. No expert Quantity
Surveyor was produced to assist the Court in determining the specific profit level built into the
pricing of this contract.
Page 47 of 51
112. I am constrained to find that the evidence of Mr. Zaid Ali is unreliable in relation to the
profit percentage figures that he purports to give at paragraph 8 of his witness statement.
113. In the circumstances of this case I find that this claim for loss of profit has not been
proved.
Loss of profit arising from non availability for rental of equipment.
114. At paragraph 7 of Zaid Ali’s Witness Statement the Claimant for the first time made a
claim for $462,000.00 for loss of profit arising from non availability for rental of equipment.
115. This is a claim that was only made via that Witness Statement. It was never pleaded by
the Claimant in its Statement of Claim and was never part of the Claimant’s case on the
pleadings. It is a head of loss that needed to be strictly pleaded to avoid taking the defendant by
surprise.
116. In the case of Charmaine Bernard (Legal Representative of the Estate of Regan
Nicky Bernard) v Ramesh Seebalack [2010] UKPC 15 at paragraph 16 Sir John Dyson SCJ
stated as follows (citing Perestrello):
But a detailed witness statement or a list of documents cannot be used as a substitute for a short
statement of all the facts relied on by the claimant. The statement must be as short as the nature
of the claim reasonably allows. Where general damages are claimed, the statement of case
should identify all the heads of loss that are being claimed. Under the pre-CPR regime in
England and Wales, RSC Ord 18 r 7 required that every pleading contained a summary of the
material facts and by r 12(1) that “every pleading must contain the necessary particulars of any
claim”. In Perestrello v United Paint Co Ltd [1969] 3 All ER 479, Lord Donovan, giving the
judgment of the Court of Appeal, said at p 485I:
Page 48 of 51
“Accordingly, if a plaintiff has suffered damage of a kind which is not the necessary and
immediate consequence of the wrongful act, he must warn the defendant in the pleadings
that the compensation claimed will extend to this damage, thus showing the defendant the
case he has to meet .The same principle gives rise to a plaintiff’s undoubted obligation
to plead and particularise any item of damage which represents out-of-pocket expenses
or loss of earnings, incurred prior to the trial, and which is capable of substantially
exact calculation. Such damage is commonly referred to as special damage or special
damages but is no more than an example of damage which is ‘special’ in the sense that
fairness to the defendant requires that it be pleaded….
The claim which the present plaintiffs now seek to prove is one for unliquidated damages,
and no question of special damage in the sense of a calculated loss prior to trial arises.
However, if the claim is one which cannot with justice be sprung on the defendants at
the trial it requires to be pleaded so that the nature of that claim is disclosed
…a mere statement that the plaintiffs claim ‘damages’ is not sufficient to let in evidence
of a particular kind of loss which is not a necessary consequence of the wrongful act and
of which the defendants are entitled to fair warning.”
117. This claim is therefore not available to the claimant at this stage.
118. In any event there is insufficient evidence of probative value relating to this claim. Mere
say so for a claim of this magnitude would not suffice. There is no evidence that the claimant
even possessed the items of equipment on which this claim was based.
Page 49 of 51
Third Issue
119. Has the Claimant mitigated its loss and is therefore not entitled to damages for loss
of profits.
Law
120. According to Hudson on Building Contracts (supra) at paragraph 8 - 173 at page 1071:-
“Very importantly, the duty to mitigate damage may mean that, in times when profitable
work is plentiful in the market, the contractor will have to give credit for his ability to
earn profits elsewhere on work which he has now become free to accept as a result of the
termination. In recessionary times, however, this defence will clearly be more difficult
for the owner to establish, as also if, even in profitable times, the contractor’s resources
were not fully committed in the project, so that he was in any case free to take on any
additional work on offer...”
121. I accept that the Claimant has not produced sufficient evidence of its accounts and his
documents to show whether it has mitigated its loss or not. The Claimant has not disclosed any
financial information about itself. It has brought no evidence of their books or accounts for the
years 2002, 2003 and 2004 to show the type of work that they were engaged in. The Court
therefore lacks vital information/evidence which should have been led by the Claimant.
113. The evidence of Mr. Zaid Ali is that the Claimant did have work in 2002 and 2003. If that
is so and if they did have work and were able to take on other projects they would have mitigated
their loss.
Page 50 of 51
114. Having made these observations I consider it unnecessary to further address this issue as
the outcome of this decision does not depend on it.
Conclusion
115. a. A contract was concluded by the letter, (wrongly dated February 28th
2001), and
issued on February 28th
2002, accepting the claimant’s tender. No further contract document was
required to constitute a binding contract.
b. The circumstances in which the defendant elected not to proceed with the contract do not
amount to events of frustration and the defendant cannot claim to be absolved from its
obligations and liability under the contract.
c. The claimant is under an obligation to prove its damages and loss.
(i) It has not been disputed that the claimant was called upon to provide a performance bond after
acceptance of its tender and that it indicated to the defendant that it had complied by letter of
March 21st 2002. It claimed that it incurred a cost of $81,548.67 to do so, which evidence I
accept, as it was not disputed.
(ii) Given, however, that the major part of its claim is for in excess of $2 million representing
loss of profits of 10% of the contract value, I find that it has failed to supply sufficient evidence
of appropriate probative value in respect of that aspect of its claim.
116. In the circumstances I find that, in default of such evidence, the claimant has established,
a claim to nominal damages with respect to this aspect of its claim, and an award of nominal
damages is therefore made, in addition to the cost to it of establishing the performance bond.
Page 51 of 51
117. The claim for loss of profit arising from inability to use its equipment was not pleaded,
and I find that it has not been proved.
Disposition and Orders
118. The defendant is to pay to the claimant:-
i. The sum of $81,548.67, (the cost of the performance bond)
ii. Interest thereon at the rate of 6% per annum from March 21st 2002.
iii. Nominal damages in the sum of $20,000.00 in respect of loss of profit
iv. Interest thereon at the rate of 12 % per annum from the date of service of the writ
v. Costs on the basis prescribed by the Civil Proceedings Rules for a claim in the total
amount as calculated above.
Dated this 6th
day of August 2012
………………………………..
Judge
Peter A. Rajkumar