Upload
others
View
15
Download
0
Embed Size (px)
Citation preview
ADJUDICATOR’s DECISION Made under s26 of the Building and Construction Industry Payments Act 2004 QLD (“the Act”)
1 | P a g e
Adjudication Application: 1161637_187 ANA : Able Adjudication Pty Ltd (N1161637)
Adjudicator : Andrew Bruce Wallace (J47895)
Application Details
Claimant
Name : Civelec Pty Ltd
ABN : 87 114 143 261
Respondent
Name : Traffic Systems Technology Pty Ltd
ABN : 55 689 700 612
Project
Type : Commercial – Installation of traffic signals
Location : Napper Road and Chilchester Drive, Arundel Gold Coast
Payment Claim
Date Served : 3 August 2011
Amount : $68,810.16 (including GST)
s18 Payment Schedule
Date : 17 August 2011
Amount : NIL
s21 Notice Date : N/A
s21 Payment Schedule
Date : N/A
Amount : N/A
Application Detail
Application Date : 23 August 2011, but not served on the Respondent until 25 August 2011 and not filed with the ANA until 31 August 2011
Acceptance Date : 29 August 2011
Response Date : 1 September 2011
Adjudicator’s Decision Adjudicated Amount : $6,561.50 (including GST)
Due Date for Payment : 17 August 2011
Rate of Interest : The rate prescribed under s.48(1) of the Supreme Court Act 1995 for debts under a judgment or order
Claimant Fee Proportion (%) : 50%
Respondent Fee Proportion (%) : 50%
Date : 15 September 2011
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 2 | P a g e Andrew Wallace J47895
Decision This is a decision made under the Building and Construction Industry Payments Act 2004
(Qld) (“the Act”).
In respect of the Claimant’s Payment Claim, I decide that:
The amount of the progress payment to be made by the Respondent to the Claimant is
the adjudicated amount referred to on page 1 herein;
The date upon which the payment became due is the Due Date for Payment referred to
on page 1 herein;
The rate of interest on the adjudicated amount is the rate referred to on page 1 herein;
and
The parties are liable to pay the adjudication fees in accordance with the details
referred to on page 1 herein.
______________________________________________________________
Introduction and Background
1. This is a matter involving an adjudication application arising from a partly written and
partly oral construction contract (“the Contract”) for the supply and installation of
electrical reticulation, trenching and ancillary civil works (“the Works”) associated with
the installation of traffic signals (“the Project”) on the corner of Napper Road and
Chichester Drive, Arundel on the Gold Coast.
2. In so far as the Contract was written, the terms were contained in a tender document
prepared by the claimant subcontractor (“the Claimant”) and provided to the respondent
head contractor (“the Respondent”) on or about 24 November 2010. The principal under
the head contract was the Gold Coast City Council (“GCCC”).
3. The contract provided for a lump sum in the amount of $256,948.00 excluding GST.
4. The parties have at least once before been involved in the adjudication process whereby
the Claimant sought the recovery of monies allegedly owing under the Contract. On 27
July 2011, Adjudicator Ms MacKenzie decided that the Claimant was entitled to the sum
of $73,469.79 including GST from the claimed amount of $158,003.92 including GST in
Decision No. 1161637_182. For the sake of clarity, I shall refer to Ms MacKenzie’s
adjudication decision as “the previous adjudication decision”.
5. On the face of the material, it is unclear what date the parties entered into the Contract,
although I note that in paragraph 2 of the previous adjudication decision the contract was
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 3 | P a g e Andrew Wallace J47895
said to have been entered into on or before 3 January 2011. Nothing turns on that
however.
6. The Claimant in the Payment Claim the subject of this Application sought payment in the
sum of $68,810.16 including GST. The Respondent valued the claim at zero.
Procedural history and jurisdiction
7. I accept the following information details the procedural history of this application and
find that there is jurisdiction for making a decision pursuant to the Act.
8. The details of the timing of the issue of the relevant documents and work are:
8.1. A valid Payment Claim dated 2 August 2011 was served on the Respondent on or
about 3 August 2011 by email. The precise dates of actual service of relevant
documentation in this Application is relatively unclear. I shall return to this issue
below. The Payment Claim was in the sum of $68,810.16 (including GST) (“the
claimed amount”).
8.2. The Respondent served a Payment Schedule on the Claimant in accordance with
the requirements of s.18(4)(b)(ii) of the Act (“the Payment Schedule”) on 17 August
2011. It provided a scheduled amount of zero.
8.3. The Claimant made an application for adjudication (“the Application”) on 31 August
2011 to a Registered Authorised Nominating Authority, Able Adjudication. This is
within the required 10 business days after the Claimant received the Payment
Schedule.1
8.4. I am satisfied that the Claimant also served a copy of the Application on the
Respondent on 25 August 2011 as identified in paragraph 1 of the Adjudication
Response. Although it is uncommon for the Respondent to have been served with
the Adjudication Response before it was filed with the ANA, nothing turns on this
issue. There is some background regarding the service of documents which I shall
return to in my reasons below.
9. In reaching my decision I have considered:
9.1. The requirements of the Act;
9.2. The contract between the parties;
9.3. The Payment Claim and the Application, together with properly made submissions
and documents provided therein;
1 Section 21(3)(c)(i) of the Act
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 4 | P a g e Andrew Wallace J47895
9.4. The Payment Schedule and the Adjudication Response together with properly
made submissions and documents provided therein.
Reasons for the Decision Preliminary Matters – Service of Documents
10. The Payment Claim was dated 1 August 2011. On the second page of the Application,
the Claimant was invited by way of the ANA’s pro forma document to state the date on
which the Payment Claim was served.
11. Although the Claimant acknowledges that the Payment Claim was dated 1 August 2011,
in respect to the date on which it was served on the Respondent, the Claimant stated
“Unknown” in the email section for its date of service. On page 1 of its Application
submissions, the Claimant submitted that the Payment Claim was served “on or about 1
August 2011”. In the circumstances there is some degree of uncertainty as to when the
Claimant actually served the Payment Claim on the Respondent.
12. I note that in Attachment “B” of the Application there is an email from Bryan Hastings to
Steve Diessel who is a Director of the Respondent. The email purports to attach the
Payment Claim and is date stamped “Tuesday, 2 August 2011 1:01 PM”.
13. Ordinarily I would have accepted a submission from the Claimant had it been made, that
the email, in the absence of contradictory evidence, was sufficient evidence to establish
that the Payment Claim was served on 2 August 2011. It is clear that email
communications have been used extensively by the parties and there is no express term
of the contract which excludes that form of communication for the service of documents.
As I say however, that submission regarding the date of its service was not put by the
Claimant, rather the Claimant for reasons known only to itself could not state when the
Payment Claim had been served.
14. The Respondent alleges that it was served with the Payment Claim on 3 August 2011.2
However, there is some background that must first be explored before I can address the
issue of when the Payment Claim was actually served.
15. In correspondence dated 9 August 2011, the Claimant received a document written by
Rudkin Hitchcock Lawyers entitled:
“TRAFFIC SYSTEMS TECHNOLOGY PTY LTD & CIVELEC CONTRACT NO.
LG314/254/10/061 – PAYMENT SCHEDULE”
2 See p.1 of the Payment Schedule dated 16 August 2011 but served on 17 August 2011
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 5 | P a g e Andrew Wallace J47895
16. Rudkin Hitchcock commences the correspondence by writing:
“We act for Traffic Systems Technologist (sic) Pty Ltd in respect of the contract for the
supply and installation of traffic control signals at the intersection of Napper Road and
Chichester Drive and are instructed to respond as follows to your Monthly Progress
Payment Claim dated 1 August 2011 in the sum of $68,810.16, made as a payment
claim, by way of a Payment Schedule issued by the Principal pursuant to Section 18 of
the Building & Construction Industry Payments Act:‖
17. Rudkin Hitchcock then proceed to state their “instructions” in the “Payment Schedule”.
18. The Respondent then by facsimile on 17 August 2011 served the Claimant with a further
payment schedule dated 16 August 2011 which gave reasons for a zero scheduled
amount. I will return to those reasons below. For reasons which will become apparent, I
shall refer to this document dated 16 August 2011 but served on 17 August 2011 as “the
Payment Schedule”.
19. The Payment Schedule stated that the Payment Claim was served on 3 August 2011.
No further explanation was afforded by the Respondent. The date of service of the
Payment Claim was not directly challenged by the Claimant in the Application, or if it was
challenged, it was not pressed in any forceful manner. As I previously suggested, at
best the Claimant in the Application stated that the Payment Claim was served “on or
about 1 August 2011”. In light of the uncertainty surrounding the date of its service and
in the absence of any clear evidence, I am prepared to give the Respondent the benefit
of the doubt. In the premises, I am satisfied that the Payment Claim was served on 3
August 2011.
20. In what can best be described as a bizarre set of circumstances, by letter dated 24
August 2011 addressed to the Claimant, Rudkin Hitchcock stated:
―We prepared and filed a letter in response to your payment claim dated 9 August
2011. Our client was also instructing a preparation of material from a Quantity
Surveyor to deal with your Payment Claim.
Due to miscommunication between ourselves and our client, Traffic Systems
Technology Pty Ltd, we confirm that we did not have authority to serve a payment
schedule on our client’s behalf and accordingly the letter purporting to be a payment
schedule dated 9 August 2011 is hereby withdrawn.‖
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 6 | P a g e Andrew Wallace J47895
21. At first glance it is unclear how Rudkin & Hitchcock could have been said to be acting on
their client’s instructions, only to later reveal that the contents of its purported payment
schedule were not in fact and in truth made on their client’s instructions at all. Assuming
that Rudkin Hitchcock did not proceed on a frolic of their own, one would have thought
that its letter dated 9 August 2011 would have had the imprimatur of their client.
22. The Claimant in the Application rejects the validity of the Payment Schedule. On page 1
of the Application (the page after the cover page), the Claimant stated that it “found a
second Payment Summary (sic) allegedly dated 16 August 2011 and allegedly faxed to it
by the respondent on 17 August 2011. Claimant cannot tell if this second Payment
Summary is as well as, or in place of the first Payment Summary.‖
23. The Claimant did not elaborate on the circumstances as to how it came to “find” the
Payment Schedule on 23 August 2011. The Applicant does not assert, rightly in my
view, that service ought to be taken as the date it “found” the Payment Schedule.
Clearly on the face of the Claimant’s own evidence, the Claimant must have been
provided with some documentary evidence that the Payment Schedule was in fact
served by fax on 17 August 2011. In the premises, I am prepared to accept that the
Payment Schedule was in fact served on 17 August 2011 by facsimile.
24. I accept the Claimant’s submissions that it would have been confused as to which
document it needed to respond to in the Application. This confusion would have
occurred because the Payment Schedule did not refer to the earlier document dated 9
August 2011. But in my view, that only lends weight to the Respondent’s submission
that the confusion regarding the serving of two payment schedules was due to a
miscommunication between the Respondent and its solicitors and the Respondent and
its Quantity Surveyor. Due to that miscommunication, it appears that the Respondent
had two independent parties preparing its payment schedule. It would appear that each
of those representatives (the solicitors and the Quantity Surveyor) may have been
unaware of the other’s efforts although there is no evidence to support that.
25. I do not accept the Claimant’s submission that these rather unusual circumstances led to
it suffering some form of disadvantage. The Claimant asserts that it was disadvantaged
because in having to deal with the deadlines of the first payment schedule, it was also
attempting to deal with the reasons stated in the second Payment Schedule.
26. If I accepted the Claimant’s submissions that the purported payment schedule dated 9
August 2011 was the only valid payment schedule, then I would have to find that the
Application itself was also invalid because as the purported payment schedule was
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 7 | P a g e Andrew Wallace J47895
served on 9 August 2011, the Claimant would have to have filed the Application on the
ANA in accordance with s.21(3)(c)(i) of the Act on or before 23 August 2011.
27. The Claimant did attempt to file an Adjudication Application on the ANA on 23 August
2011 as stated in the ANA’s Adjudication and Referral Notice dated 29 August 2011.
However, I accept in these particular circumstances that the Application was itself
incomplete because one of the email attachments said to form part of the Application
appears to have been corrupted and was not able to be opened. The corrupted file was
said to be Part 1 of 3 parts to the Application. Therefore it is possible, if not likely that
Part 1 contained a substantial part of the Application. In the premises, I am not prepared
to find that the purported application filed on the ANA on 23 August 2011 was a valid
application under the Act.
28. As stated above, the day after the Claimant filed the purported application on 23 August
2011, Rudkin & Hitchcock faxed its’ withdrawal of the purported payment schedule dated
9 August 2011.
29. The end result of this cacophony of errors was that whilst having received the Payment
Schedule on 17 August 2011 and having been advised on 24 August 2011 that the
purported payment schedule was withdrawn, the Claimant pursuant to s.21(3)(c)(i) of the
Act, had until 31 August 2011 to file its Adjudication Application. There was in my view,
no material disadvantage to the Claimant because as demonstrated in the Application, it
dealt with the issues contained in both the purported payment schedule and those
contained in the Payment Schedule, many of which appear to have overlapped one
another. Further, although the parties appear to have done their level best to complicate
the issues, the matter is a relatively straight forward dispute involving only a modest sum
of money and only 7 variations plus retentions. In the broader scheme of things, it is not,
or at least it ought not have been a complex matter.
30. I accept that the Application was filed with the ANA in hard copy format on the last
available day, being 31 August 20113 and I also accept that the Application in hard copy
format was served on the Respondent on or about 25 August 20114. I also accept that
the Adjudication Response was provided to the ANA on 1 September 20115 in
accordance with s.24(1)(a) of the Act. I am also satisfied that the Adjudication
3 See the letter of the ANA’s Queensland Agent to the ANA dated 2 September 2011
4 See paragraph 1 of the Adjudication Response
5 See the letter of the ANA’s Queensland Agent to the ANA dated 2 September 2011
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 8 | P a g e Andrew Wallace J47895
Response was served on the Claimant pursuant to s.24(5) of the Act on 1 September
2011.6
31. In all respects, based on my findings outlined herein, I am satisfied that all of the
requisite provisions as to timing under the Act have been complied with and that the
Payment Claim, the Payment Schedule, the Application and the Adjudication Response
have been served in time and are otherwise valid.
Issue Estoppel & Abuse of Process
32. The Respondent in paragraph 15 of the Adjudication Response stated:
―For the most part the claimant’s claims are plainly and simply re-agitation of claims
already considered and decided on their merits in the Adjudication 1161637_182 by
adjudicator Aleisha Jane MacKenzie and accordingly should be rejected in their
entirety as being subject to legal principles of issue estoppel and/or abuse of process.‖
33. The Respondent further argues that the Claimant is prevented from re-agitating claims
that have already been decided and prevented from “fabricating” new claims which have
been previously decided but disguised as new ones.
34. The Respondent relies upon the following authorities to support its submissions:
34.1. Dualcorp Pty Ltd v Remo Constructions Pty Ltd [2009] NSWCA 69;
34.2. AE & E Australia Pty Ltd v Stowe Australia Pty Ltd [2010] QSC 135;
34.3. Perform (NSW) Pty Ltd v Mev-Aus Pty Ltd [2009] NSWSC 416;
34.4. Urban Traders Pty Ltd v Paul Michael [2009] NSWSC 1072;
34.5. Watpac Constructions (NSW) Pty Ltd v Austin Corp Pty Ltd [2010] NSWSC 168;
34.6. Spankie & Ors v James Trowse Constructions Pty Ltd [2010] QCA 355;
34.7. John Holland Pty Ltd v Schneider Electrical Building Australia Pty Ltd [2010] QSC
159.
35. I accept in principle the Respondent’s submission that the re-submission or re-agitation
of claims which have already been considered and decided in a valid prior adjudication
is impermissible. In Dualcorp at paragraphs [69] to [72], Macfarlane JA with whom
Handley AJA agreed, said:
“69 As pointed out in Kuligowski, for the principle of issue estoppel to apply, the same issue must
6 See the Statutory Declaration of Stephen Diessel declared 3 September 2011
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 9 | P a g e Andrew Wallace J47895
have been earlier determined as is later sought to be reagitated (at [40]). Thus, if a progress
claim were rejected by an adjudicator because it was premature by reason of the date stipulated
for payment by the contract, a later claim made on a timely basis would not be precluded.
However (to take as an example the issue which was before McDougall J in John Goss Projects)
if a progress claim were rejected because it was not made in accordance with express
requirements of the contract, that determination would be binding on a subsequent adjudicator
before whom the same issue arose. Similarly, it would be an abuse of process for the claimant to
rely upon a later progress claim in response to which no Payment Schedule was served to obtain
judgment on a basis conflicting with issues resolved in the earlier determination.
70 I thus disagree with the view ultimately arrived at by McDougall J in John Goss Projects that
s 22(4) defines the extent to which an adjudicator is bound by an earlier adjudication. The view
that the claimant once disappointed by an adjudicator can seek a different determination from
another, or indeed from a succession of others, until a favourable decision is reached would in
my view conflict with the policy of the Act to render adjudicators’ determinations final on issues
which they resolved, subject only to provisions of the Act conferring limited rights of correction
of determinations.
71 Dualcorp asserts that this approach could produce unfair outcomes where a claim has not
been the subject of adjudication on the merits but has been rejected for want of evidence. It was
submitted that because of the unfairness that would flow from precluding a claimant bolstering its
evidence on another adjudication, it cannot have been intended that adjudications would be
conclusive.
72 I do not agree. It is not at all unusual that persons seeking remedies in courts or other forums
have a once only opportunity to bring forward evidence and submissions in support of their
claim. This is in fact the usual situation and is consistent with what the High Court in D’Orta
referred to as the “central and pervading tenet of the judicial system … that controversies, once
resolved, are not to be reopened except in a few, narrowly defined, circumstances” (at [34]).
36. The Qld Court of Appeal in Spankie per Fraser JA at [25] – [27] with whom Holmes and
Chesterman JJA agreed, adopted the approach of the New South Wales Court of
Appeal in Dualcorp.
37. It is important to note that the decision in Dualcorp also denies a claimant’s entitlement
to serve a subsequent payment claim when a previous adjudicator has dismissed or
rejected that claim for want of evidence. Macfarlane JA was satisfied that there was a
“Once only opportunity” for the claimant to put its evidence forward and if it tried to do so
again the principle of issue estoppel would prevent it from doing so.
38. As I have said, as a matter of principle, I accept these submissions. However, I am not
able to apply these principles in a vacuum, but must assess their application to each of
the variations claimed on a case by case, item by item basis.
Invalid Payment Claim
39. The Respondent in the Adjudication Response submits that the Payment Claim is also
invalid because the claim in respect to Variation # 19 does not comply with s.17(2)(a) of
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 10 | P a g e Andrew Wallace J47895
the Act because it allegedly fails to identify the dates when the demobilisation and
remobilsation occurred.
40. I shall address the merits of the complaint against Variation # 19 below. However, I am
able to deal with the substance of the submission at this point. If I were to accept that
Variation #19 was insufficiently particularised, then I would reject that discrete aspect of
the claim only. However that would not mean that the balance of the claim did not
properly identify the construction work performed. In principle therefore, I reject the
Respondent’s submission.
Contract ―Back to Back‖ with Head Contract
41. The Respondent asserts in the Adjudication Response that the Contract was subject to
the same terms and conditions as the head contract entered into by the Respondent with
the GCCC. This submission was supported by a very brief Statutory Declaration of
Steve Diessel dated 1 September 2011.
42. The Respondent also submits in the Adjudication Response that Ms MacKenzie
“discounted the discussions and agreement between the parties as forming the terms
and conditions of contract between the parties.” The Respondent asserts that I am not
bound by the findings of Ms MacKenzie regarding contractual matters, other than in
relation to findings of value pursuant to s.27 of the Act.
43. There are a number of difficulties I have with the Respondent’s submissions.
44. Firstly, it appears that the Respondent did not raise these issues in the Payment
Schedule and is therefore, precluded from doing so in the Adjudication Response
pursuant to s.24(4) of the Act.
45. Secondly, the parties have not addressed this issue in any detail whatsoever in the
material before me, which given my first concern is hardly surprising from the Claimant’s
point of view. Having read the decision of Ms Mackenzie, it appears that she received
detailed submissions in relation to the relevant terms of the contract, both written and
oral, express and implied. She devoted 5 full pages in her decision to this issue. Her
reasoning appears well considered and logical.
46. Thirdly, the Statutory Declaration of Mr Diessel is so lacking in content that it is all but
meaningless. Mr Diessel does not attest to the basis of his understanding that the
Contract was to be “back to back” other than to say that all previous subcontracts were
treated similarly. He does not provide any evidence of what those subcontracts were
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 11 | P a g e Andrew Wallace J47895
nor how many previous subcontracts there were. It is impossible to establish the
purported term in the absence of this evidence in my view.
47. I do however accept that pursuant to s.27 of the Act, I am bound by any valuations
ascribed by Ms MacKenzie, unless I am satisfied that the value of the work has changed
since the previous decision.
48. Given the concerns I have raised, notwithstanding the Statutory Declaration of Mr
Diessel, I am unwilling to accept the Respondent’s submission that the terms of the head
contract were imputed into the Contract.
Item 1: 101/9001.01 – Preparation of existing substrate surface
49. The Claimant seeks payment for this item in the sum of $3,355.44 including GST. It is
said to be constituted by the preparation of 254.2 m2 of road surface area calculated at
the tendered rate of $12.00 per m2.
50. The Respondent in the Payment Schedule rejects the claim and values it at nil. It
argues that the work was not performed and the Claimant has provided no credible
evidence to support the claim. In the alternative, the Respondent argues that this aspect
of the claim was determined in the previous adjudication decision and valued at nil and
that pursuant to s.27 of the Act, I must also value the work at nil.
51. The Claimant in the Application argues that Ms Mackenzie at paragraph 82 of the
previous Adjudication Decision found that the item was a “provisional sum subject to
remeasure”.
52. It appears from the Respondent’s previous submissions to Ms MacKenzie that it
accepted that “it is a provisional quantity which pursuant to the terms of the contract is
subject to re measure once the final quantity is known.”
53. I am satisfied that Ms MacKenzie did not value the work at nil. A close reading of her
reasons at [82] to [90] reveals that she formed the view that because the Claimant had
supplied insufficient evidence to quantify the square metreage of preparation, the
Claimant was not entitled to claim for the item. That is distinct from her valuing the work
at a nil dollar value.
54. However, essentially Ms MacKenzie was unable to value the claim for want of evidence.
Based on the reasons stated by Macfarlane JA in Dualcorp at [70]-[72] (extracted above
in paragraph 35), I am of the view that the Claimant cannot overcome the lack of
evidence in the first adjudication application by providing further evidence before me. I
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 12 | P a g e Andrew Wallace J47895
am satisfied that the Respondent has made out its argument in respect of Issue
Estoppel and is not required to pay any part of this aspect of the claim.
Item 2 – Variation # 14 – weekend work
55. The Claimant seeks payment for this item in the sum of $5,708.00 excluding GST being
for the provision of its services during weekends. It argued that the tender excluded the
provision of weekend work “by qualification” referring to its comments in the email dated
24 November 2010 which annexed the Claimant’s quotation to perform the works.
56. The Respondent in the Payment Schedule valued this item at nil. It argued that the
Claimant was not given any verbal or written direction to perform weekend work. It relied
upon an email dated 4 August 2011 from what appears to be a representative of the
Principal’s Superintendent wherein Nathan McMahon denied giving either the Claimant
or the Respondent any direction to “compress” the works. In the alternative, the
Respondent argues that the claim is excessive and cannot be substantiated. It argues
that during the six week construction period, the Claimant was not on site for eleven
days, which had they been, would have negated the requirement to perform the work on
weekends.
57. I accept that the rainfall records contained within Attachment “J” of the Application
evidences that there was significant rainfall during the relevant construction period. I
also accept that the Claimant was advised on numerous occasions that the works were
to be completed by the end of the school holidays. Whilst this was not a direction to
compress the works, clearly given the state of the weather in particular, the works did
need to be compressed.
58. I do not accept the Respondent’s submissions that just because a project manager may
be on wages, although there is no evidence to support that, that there is no additional
cost if that person works over weekends. There is no evidence to otherwise support the
estimates provided by the Respondent at Attachment 10 to the Adjudication Response.
59. There appears to be no challenge by the Respondent to the rate of 50% claimed on top
of the week-day rate, although I concede the Respondent principally submits it shouldn’t
have to pay any additional sum. On balance, in my view the Claimant is entitled to the
week-day rate plus 50% for the works performed on weekends. In the premises, I am
satisfied that the Claimant is entitled to its alternative claim in the sum of $2,560.00
excluding GST as calculated in Attachment L to the Application.
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 13 | P a g e Andrew Wallace J47895
Item 3 – Variation # 15 – Demobilisation – Survey/Set-out
60. The Claimant seeks payment for this item in the sum of $3,405.00 excluding GST being
for the demobilisation of its workforce on 10 February 2011 arising out of an alleged
survey error on the part of the Respondent.
61. The Respondent in the payment schedule denied that the Claimant was unable to
perform any other work on the site and says that other works were available to be
performed. In addition, the Respondent argues that the delay was caused by a simply
typographical error that a reasonably competent person should have been able to
discern and remedy.
62. The Respondent makes two alternative submissions. Firstly, it states that the traffic
control was on site on 10 February 2011 and I assume the Respondent means the
Claimant has been paid for this work within its contract amount. Secondly, the
Respondent argues that I am bound by s.27(2) of the Act because the Claimant has not
performed any further work on the project since the reference date in respect of its
payment claim the subject of the previous adjudication decision. I shall refer to this
submission and others like it as “the Respondent’s s.27(2) argument”.
63. I accept the Claimant’s submissions that it was not responsible for the set-out of the
works and that such was the responsibility of either the Respondent or the Principal. I
am not satisfied that the email of Nathan McMahon dated 4 August 2011 at Attachment
11 of the Adjudication Response constitutes sufficient evidence to support the
Respondent’s submission that a reasonably competent contractor should have been
able to identify the error and work around it. Equally, there is no evidence that there was
other work available to the Claimant to perform. I accept the Claimant’s submission
querying why it would have mobilised its workforce to attend the site, when it only
intended to go to another.
64. I accept that the Respondent may have paid the Claimant for traffic control on 10
February 2011 as part of the contract, but assumedly there would have been some work
performed by the Claimant in order for it identify the problematic set-out. In order to
identify those problems, traffic control would have been necessary in my view. This is
not a valid reason for withholding payment.
65. In respect to the Respondent’s s.27(2) argument I am of the view that none of the
authorities upon which it relied supports the contention that the Claimant is prevented
from claiming for further works which were not previously claimed in a prior adjudication
application. The Claimant’s entitlement to payment for this item appears not to have
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 14 | P a g e Andrew Wallace J47895
been previously agitated. The Respondent’s submission may have some force if there
were a written contract which set out specific reference dates and the contract provided
for a “final claim” which had been previously adjudicated upon, but that does not appear
to be the case here. In any event it is unnecessary for me to form a final view on this
point.
66. In the absence of any contractual restriction on the number of payment claims which
may be issued, the statutory position prevails. That is, provided that the Payment Claim
was served from each reference date7, calculated in accordance with Schedule 2 of the
Act to be the last day of each month, up to a period of 12 months from when the work
was last carried out, the Payment Claim would be valid.8 It is not the case that the work
claimed in the Payment Claim shared the same reference date for the works claimed
under the previous adjudication decision. The payment claim the subject of the previous
adjudication decision was served on 9 June 2011. Therefore it is reasonable to assume
that its reference date was 31 May 2011. The Payment Claim was served on 3 August
2011. Assumedly, its reference date was 31 July 2011. Therefore, s.17(5) of the Act
which prohibits multiple payment claims in respect to the one reference date, has no
application, nor does s.27(2) of the Act. In the premises, I reject the Respondent’s
submissions.
67. For the reasons expressed and in the absence of any contradictory evidence regarding
the reasonableness of the quantum of the claim, I am satisfied that the Claimant is
entitled to the claimed amount in the sum of $3,405.00 excluding GST.
Item # 4 – Variation # 16 – Surfacing Traffic Control
68. The Claimant seeks payment for this item in the sum of $2,000.00 excluding GST for the
costs associated with traffic control during the surfacing of the works.
69. The Respondent values the item at nil arguing that the Claimant should have
incorporated the costs of traffic control in its contract sum and that any failure to do so
should not prejudice the Respondent. In the alternative the Respondent’s s.27(2)
argument is maintained.
70. In respect of the first of the Respondent’s submissions, I accept the Claimant’s
submission that the accompanying email dated 24 November 2010 which was provided
with the tender stated in part:
7 See s.12 of the Act and Schedule 2 for the definition of “Reference Date”
8 See s.17(4)(b) of the Act
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 15 | P a g e Andrew Wallace J47895
“Can you add an extra $2000 for the traffic control for the surfacing”.
Therefore, I accept that the Claimant communicated to the Respondent that this was
additional work and cost to the tender price. It must be remembered that there was no
formal written contract with the usual “Entire Agreement Clauses” which ordinarily bind
the parties to the terms of the written contract and nothing else. In the absence of
evidence to the contrary, I accept that the Respondent at some point in time accepted
the terms of the tender and any other qualifications which were attached to it, such as
those contained in the Claimant’s email dated 24 November 2010.
71. In respect to the Respondent’s s.27(2) argument, in this case I am of the view that it has
merit. Having considered the comments of Ms MacKenzie where she carefully outlined
the submissions of the parties in respect to Variations 003, 009 and 011 it is clear that
the issue of traffic control was agitated before her. What is unclear is whether traffic
control in respect to surfacing was agitated before her.
72. Whether it was or was not, I am satisfied that in general the costs of traffic control was
argued and determined. Claimants ought not be given the opportunity to re-open
arguments which they ought to have brought before a previous adjudicator. In my view,
it is too fine a distinction between general traffic control costs and traffic control costs
associated during road surfacing to argue that the Claimant should be given “another
bite of the cherry”. In reaching this conclusion I have relied upon Macfarlane JA’s
reasoning in Dualcorp at [72] where he spoke of a “once only opportunity” to argue one’s
case. This approach should be distinguished from the situation where no claim is made
by the Claimant in respect to a particular piece or type of work. But when a claimant has
claimed for such work and has not performed any other works since that work was
previously adjudicated, in my view a respondent is entitled to consider that it will not face
any further claims in respect to it and that any attempt to so by the Claimant is akin to an
abuse of process.
73. In the premises, in respect to this item, I prefer the submissions of the Respondent and I
value the item at nil.
Item 5 – Variation # 17 – Three weeks traffic control
74. The Claimant seeks payment for this item in the sum of $15,428.64 including GST being
for traffic control between the period of 23 January to 16 February 2011.
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 16 | P a g e Andrew Wallace J47895
75. The Respondent rejects the Claimant’s entitlement to this aspect of the claim arguing
that the Claimant was never directed to accelerate the works. The Respondent’s s.27(2)
argument is also raised to support the Respondent’s assertions.
76. The Claimant submits that it is irrelevant who ordered the compression of the work.
Whilst I do not necessarily agree with that submission, I have previously found that the
works were compressed by virtue of the requirement to complete the works by the end
of the school holidays. This is not a valid reason for withholding payment.
77. However, in respect to the Respondent’s s.27(2) argument, for the reasons I have
expressed in relation to Variation 16 above, I am of the view that the Claimant ought to
have claimed for the traffic control costs in the adjudication application before Ms
MacKenzie. In the premises, I do not consider that the Claimant has the entitlement to
re-agitate this issue now before me and I value the item at nil.
Item 7 – Variation # 18 – Additional Traffic Controllers
78. The Claimant seeks payment for this item in the sum of $16,784.22 excluding GST for
additional traffic controllers said to have been required between 5 January and 14 April
2011, amounting to an additional 28.5 days of labour.
79. The Respondent challenges the Claimant’s entitlement on the basis that the Claimant
was never directed to provide more traffic controllers and that the number of traffic
controllers it employed, was a matter for the Claimant. It also argues that the
Respondent is attempting to disguise the work the subject of this variation as new work
whereas it had been included in previous variations. The Respondent also maintains its
s.27(2) argument.
80. The Respondent’s principle submission has substance in my view. The Claimant was
responsible for supplying appropriate traffic control for the works to be performed. I
accept that the Claimant’s email dated 24 November 2010 which attached the tender
sought to qualify the number of controllers to one, but absent a direction from the
Respondent to increase the number of traffic controllers in my view, the Claimant is
responsible for those additional costs.
81. If I am wrong in relation to the contractual entitlement to claim for the additional traffic
controller then in my view, for the reasons I have already expressed in relation to
Variations 16 and 17, I am of the view that the Claimant ought not be permitted to re-
agitate its entitlement to claim for traffic control. In the premises, I value this tem at nil.
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 17 | P a g e Andrew Wallace J47895
Item 8 – Variation # 19 – Demobilsation and remobilsation
82. The Claimant seeks payment for this item in the sum of $6,000.00 excluding GST for the
purported demobilisation and remobilisation of men caused by GCCC design error and
the stand down of work pending its redesign.
83. The Respondent rejects the Claimant’s entitlement to this aspect of the claim on the
basis that the Payment Claim does not comply with s.17(2)(a) of the Act because the
Respondent says, it fails to identify the dates when the demobilisation and remobilisation
are alleged to have occurred.
84. In the alternative, the Respondent relies upon its s.27(2) argument.
85. I am unconvinced that the Payment Claim did not sufficiently identify this aspect of the
Payment Claim. It appears that the issue has been well ventilated in the past, however
that leads to the difficulties of the Respondent’s s.27(2) argument.
86. The Claimant in the Application concedes that this item was dealt with by Ms MacKenzie
in the previous adjudication decision and that she determined that no payment was
allowed because insufficient evidence had been provided9. Ms MacKenzie said:
―143. I accept that this a (sic) variation as it was for work not part of the Lump Sum price,
however I cannot value the claim on the evidence before me.
144. Absent further evidence such as site diaries, or a Statutory Declaration of those
persons who attended such meetings, I am unable to value the variation and accordingly
I allow $0.00 for V006.‖
The Claimant submits that “Nothing prevents resubmission of this claim with better
details”.
87. I reject the Claimant’s submissions. Ms MacKenzie clearly rejected the Claimant’s
entitlement to the amount claimed which I note was only for $1,620.00 for project
management costs arising out of the demobilisation and remobilisation for want of
evidence. I have previously rejected the Claimant’s attempt to re-litigate such matters
on the strength of Macfarlane JA’s views in Dualcorp at [70] – [72]. I can see no good
reason why in relation to this item I ought to come to any different conclusion. I note that
the previous claim was restricted to the claim for project management and that the claim
9 See paragraphs 143-4 of the previous adjudication decision
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 18 | P a g e Andrew Wallace J47895
before me is broader in that it deals with various other employees and contractors of the
Claimant, but that does not enable the Claimant to escape from its obligations under
what His Honour referred to as the Claimant’s “once only opportunity” obligations.
88. In the premises, I value this aspect of the claim at nil.
Retentions
89. The Claimant in the Payment Claim sought the release of retention monies held by the
Respondent in the purported sum of $11,196.27.
90. The Respondent denied that it was withholding the amount claimed. Rather the
Respondent asserted that it was holding in retention the sum of $6,157.94 including
GST. The Respondent further argued that retention has been applied to the progress
payments in accordance with the understanding between the parties in relation to this
project as it had done on other projects.
91. The Claimant in the Application accepts that the Respondent is in fact only withholding
retentions in the sum of $6,157.95 but makes no mention of whether it agreed to the
Respondent withholding that money or not, or the terms on which it may be released.
92. In the premises, I simply do not know whether the Claimant maintains its entitlement to
the release of the retention. Neither party has provided me with any details of the
contractual entitlement for the Respondent to withhold the monies or how those monies
are to be distributed and when. In the premises, I am unable to value this aspect of the
claim.
Amount Determined
93. As detailed in Schedule A, attached hereto, I am satisfied that the Claimant was entitled
to receive payment on account of performing the works in the sum of $6,561.50
including GST (“the adjudicated amount”).
Due date for payment and Interest
94. Pursuant to s.26(1)(b) of the Act, I must determine when the adjudicated amount is
payable by the Respondent pursuant to s.15 of the Act.
95. Neither party made any submissions on the matter and there is no evidence as to the
mechanism for determining the due date under the Contract. In the premises, I am
satisfied that the statutory default period under s.15(1)(b) applies, namely 10 business
days after the Payment Claim was served.
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 19 | P a g e Andrew Wallace J47895
96. I am satisfied that the Payment Claim was served on 3 August 2011. Therefore the due
date for payment was 17 August 2011.
97. Section 26(1)(c) of the Act provides that I must also decide the rate of interest payable
on any amount.
98. When determining the rate of interest payable on the unpaid amount of a progress
payment that has become payable, reference must be had to s.15(2) and where
applicable s.15(3) of the Act.
99. Those provisions provide:
―(2) Subject to subsection (3), interest for a construction Contract is payable on the unpaid amount of a progress payment that has become payable at the greater of the following rates—
(a) the rate prescribed under the Supreme Court Act 1995, section 48(1) for debts under a judgment or order;
(b) the rate specified under the Contract.
(3) For a construction Contract to which Queensland Building Services Authority Act 1991, section 67P applies because it is a building Contract, interest is payable at the penalty rate under that section.‖
100. Neither party made any submissions regarding the applicable rate of interest payable.
101. In the premises, I am satisfied that the statutory default provisions should apply, namely
that the rate of interest should be calculated under s.48(1) of the Supreme Court Act
1995 for debts under a judgment or order.
Costs
102. Pursuant to s.34(3)(a) of the Act, the Claimant and Respondent are jointly and severally
liable to pay the fees of the ANA.
103. Pursuant to s.34(3)(b) of the Act, each party is liable to contribute to the payment of the
ANA’s fees in equal proportions unless otherwise decided by me.
104. Pursuant to s. 35(2) of the Act, the Claimant and Respondent are jointly and severally
liable to pay the adjudicator’s fees and expenses.
105. Pursuant to s.35(3) of the Act, the Claimant and Respondent are each liable to
contribute to the payment of the adjudicator’s fees and expenses in equal proportions
unless otherwise decided by me.
Claimant: Civelec Pty Ltd
Respondent: Traffic Systems Technology Pty Ltd
Authorised Nominating Authority: Able Adjudication
Adjudication Application: 1161637_187 20 | P a g e Andrew Wallace J47895
106. Therefore, ss.34(3)(b) and 35(3) of the Act provide me with a discretion to decide the
proportion that the Claimant and the Respondent are liable to contribute to the payment
of the ANA’s fees and my fees and expenses.
107. It is difficult to imagine how two parties could have more successfully complicated this
dispute. It is little wonder that the parties’ communications appear to have broken down
when there was no actual written contract setting out the parties’ rights and obligations.
Each of them are equally to blame in that regard.
108. Whilst the Respondent has been successful in defending much of the claim, the
Claimant has enjoyed some, albeit minor success. I have taken into consideration the
very disjointed manner in which the Respondent has conducted its affairs throughout this
adjudication process and I am of the view that this should have some bearing on the
apportionment of the adjudication costs because of the additional work it required me to
perform.
109. On balance, I believe this is not an appropriate matter for me to exercise my discretion. I
decide that the Claimant and the Respondent are equally liable for the payment of the
ANA’s fees and the Adjudicator’s fees and expenses pursuant to ss.34 and 35 of the
Act.
Mr Andrew Wallace
Adjudicator
15 September 2011
SCHEDULE A
ITEM
DESCRIPTION
CLAIMED
AMOUNT
SCHEDULED
AMOUNT
ADJUDICATED
AMOUNT
ITEM 101 $3,050.40 $0.00 $0.00
VARIATION # 14 $5,708.00 $0.00 $2,560.00
VARIATION # 15 $3,405.00 $0.00 $3,405.00
VARIATION # 16 $2,000.00 $0.00 $0.00
VARIATION # 17 $15,428.64 $0.00 $0.00
VARIATION # 18 $16,784.22 $0.00 $0.00
VARIATION # 19 $6,000.00 $0.00 $0.00
RETENTIONS $11,196.27 $0.00 $0.00
Sub-Total $63,572.53 $0.00 $5,965.00
GST $5,237.63 $596.50
Total Amount $68,810.16 $0.00 $6,561.50