DALLAS AREA RAPID TRANSITDALLAS AREA RAPID TRANSIT DALLAS, TEXAS
AMENDMENT OF SOLICITATION 1. SOLICITATION NO.:
B-1020803
3. EFFECTIVE DATE:
August 5, 2011
4. BRIEF SOLICITATION DESCRIPTION: Deck Cracking Repair for TRE Grade Separation Bridge
5. REVISED OFFER SUBMISSION DUE DATE AND TIME: (Note: Unless identified below, this solicitation amendment does not change the Offer Submission Date and Time.) The date and/or time specified for receipt of offers is changed as follows: DATE:
TIME: 6. REVISED PRE-BID/PROPOSAL CONFERENCE: (Note: Unless identified below, this solicitation amendment does not change the Pre-Bid/Proposal Conference, if a conference is scheduled.) The scheduled pre-bid/proposal conference: DATE: TIME: LOCATION: 7. AMENDMENT OF SOLICITATION:
The Solicitation identified in Block 1, above, is hereby amended as described in Block 11, below. Except as provided herein, all other provisions of the solicitation, or as heretofore amended, remain unchanged and in full force and effect.
8. REQUIREMENT TO ACKNOWLEDGE AMENDMENT: Offerors must acknowledge receipt of this amendment prior to the deadline specified in the solicitation for receipt of offers by one of the following methods: a. By signing this amendment in Block 9, below, and returning one signed copy; b. By acknowledging receipt of this amendment on the Solicitation, Offer and Award form; or, c. By separate letter or telegram that includes a reference to this solicitation and amendment number.
WARNING: Failure of an Offeror to acknowledge receipt of this Amendment, as described herein, may result in REJECTION OF THE OFFER. NOTE: For Invitations for Bids the terms "Offer" and Offeror" shall mean "Bid" and "Bidder", respectively; and for Requests for Proposals the terms "Bid" and "Bidder" shall mean "Offer" and "Offeror", respectively, in this solicitation and any associated exhibits.
9. OFFEROR'S ACKNOWLEDGEMENT OF AMENDMENT: Name & Title: ____________________________________ Signed Acknowledgment: ____________________________ (Print/Type) Offeror:__________________________________________ Date Acknowledged: _____/_____/_____ 10. FOR FURTHER INFORMATION CALL: Name: Cedric D. Seay, Contracts Specialist Telephone No.: (214) 749-2807
11. DESCRIPTION OF AMENDMENT:
1. List of Firms that Requested the Specifications 2. Attendees List from the Pre-Bid Conference 3. PowerPoint Presentation from the Pre-Bid Conference 4. Revised Exhibit D 5. Revised Exhibit J (Drawings) 6. Responses to Exhibit O, Solicitation Question Submission Form
Page 1 of 1
B-1020803: Deck Cracking Repair for TRE Grade Separation Bridge Amendment No. 3
Changes
To Page Descriptive Changes
Exhibit D 2 2 The date was changed from “September 15, 2011” to “August 25, 2011” within the provision entitled “Contract Award”. Remove page 2 and replace with “Amendment 3, Exhibit D page 2”.
Exhibit D 3 3 Language was added as subparagraph (a)(5) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Exhibit D 3 3 Language was added as subparagraph (f) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”..
Exhibit D 3 3 Language was added as subparagraphs (g)(1) and (g)(2) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Exhibit D 3 3 Language (3rd sentence) has been added within the provision entitled “Contractor Staging Areas”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Exhibit J - Drawings Sheet 7a Sheet 7a This sheet is provided as “for information only” in supplement to Sheet 7. Add “Amendment 3, Exhibit J – Drawings, Sheet 7a”.
Exhibit J - Drawings Sheet 9a Sheet 9a This sheet is provided as “for information only” in supplement to Note 3 of Sheet 9. Add “Amendment 3, Exhibit J – Drawings, Sheet 9a”.
Exhibit J - Drawings Sheet 9b Sheet 9b This sheet is provided as “for information only” in supplement to Note 3 of Sheet 9. Add “Amendment 3, Exhibit J – Drawings, Sheet 9b”.
CONTACT NAME COMPANY NAME PRIME BIDDER OR 
SUB? MBE, WBE, DBE??? CONTACT # EMAIL
1 PAM DAVIS GIBSON & ASSOCIATES PRIME 972.557.1199 PamD@gibsonassoc.net
2 TREY MEADOR GIBSON & ASSOCIATES PRIME 972.557.1199 TreyM@gibsonassoc.net
3 CATHY GALINA RAM CONSTRUCTION SERVICES OF MICHIGAN 734.437.6282 cgallina@ramservices.com
4 HAROLD HALL BELZONA PRIME 877.432.6730 hhall@belzona.org
5 MICKEY WHALEN SOUTHWEST CONSTRUCTION SERVICES PRIME 214.879.9948 mwhalen@swconstruction.com
B1020803: Deck Cracking Repair for TRE Grade Separation Bridge
LIST of FIRMS that REQUESTED the SPECIFICATIONS
DALLAS AREA RAPID TRANSIT
5 MICKEY WHALEN SOUTHWEST CONSTRUCTION SERVICES PRIME 214.879.9948 mwhalen@sw construction.com
6 VIOLET LEE iSqFt and AGC/TEXO plan room PLAN ROOM 800.364.2059  x8304 vlee@ISQFT.com
7 WALT JOHNSTON BRAZOS RESTRORATION & WATERPROOFING PRIME 972.935.1177 brazores@flash.net
8 JOHN DURANT/BRISA BUENO JOHN DURANT'S CONSTRUCTION SERVICES 214.710.4468 johndurant28@yahoo.com
9 BREA PLUM CONSTRUCTION DATA COMPANY PLAN ROOM 800.872.7878 x2445 BPlum@cdcnews.com
10 BRETT BAKER TEXAS CONCRETE RESTORATION, INC. PRIME 972.291.8254 brettb@texconrest.com
11 PETE HAVERON TEXAS CONCRETE RESTORATION, INC. PRIME peteh@texconrest.com
12 CHRISTIAN HALL ALPHA INSULATION AND WATERPROOFING 972.446.2600 CHall@alphaiwp.com
13 TELISSA TOWNSEND VENDIGM COMPANIES PRIME 817.496.5220  ttownsend@vendigm.com
14 JOHN BONE SR. VENDIGM COMPANIES PRIME 817.496.5220  jbonesr@vendigm.com
CONTACT NAME COMPANY NAME PRIME BIDDER
OR INDICATE TRADE? MBE, WBE,  OR DBE??? CONTACT # EMAIL
1 WALTER JOHNSON BRAZOS RESTORATION & WATERPROOFING PRIME 972.935.1177 brazores@flash.net
2 MICKEY WHALEN SOUTHWEST CONSTRUCTION SERVICES PRIME 214.879.9948 mwhalen@swconstruction.com
3 JOHN BONE VENDIGM COMPANIES PRIME 817.718.1095 jbone@vendigm.com
4 JOHN BONE SR. VENDIGM COMPANIES PRIME 817.929.3508 jbonesr@vendigm.com
5 STEVEN HALLMAN VENDIGM COMPANIES PRIME 214.546.1755 schallman@vendigm.com
6 HAROLD HALL BELZONA PRIME 972.365.2656 hhall@belzona.org
7 RANDLE HOWARD R.D. HOWARD CONSTRUCTION PRIME MBE, DBE, HUB 817.921.1401 rhoward@thinkhoward.com
B1020803: Deck Cracking Repair for TRE Grade Separation Bridge
PREBID CONFERENCE   AUGUST 3, 2011
DALLAS AREA RAPID TRANSIT
9 BRETT BAKER TEXAS CONCRETE RESTORATION, INC. PRIME 972.291.8254 bbaker@texconrest.com
10 CEDRIC D. SEAY DALLAS AREA RAPID TRANSIT 214.749.2807 cseay@dart.org
11 GERARD GRIGSBY DALLAS AREA RAPID TRANSIT
12 JEFF HAYNES DALLAS AREA RAPID TRANSIT
13 JOHN GAULT DALLAS AREA RAPID TRANSIT
14 JORGE ESPINOSA DALLAS AREA RAPID TRANSIT 214.749.2978 jespinos@dart.org
15 NERY ARMBRUSTER DALLAS AREA RAPID TRANSIT
16 PATRICK POWERS DALLAS AREA RAPID TRANSIT
17 ALI RABIEE DALLAS AREA RAPID TRANSIT
18 WILLIAM STINSON DALLAS AREA RAPID TRANSIT
19 JOHN HORNEY TRINITY RAILWAY EXPRESS
Solicitation Number B-1020803 August 3, 2011
Welcome to the Pre-Bid
Conference for the Deck
Grade Separation Bridge
Pre-Bid Conference Agenda
• Project Overview
• Risk Management - Nery Armbruster, Risk Management Analyst
• Environmental Compliance - Jeff Haynes, Environ. Compl. Project Manager
• DEO (Goals) - Gerard Grigsby, Economic Opportunity Specialist
• Quality Control - Patrick Powers, Manager of Quality Assurance
• Review of Solicitation Documents - Cedric Seay / Jorge Espinosa, Contract
Specialists
• Questions
Purpose
identify potential problems concerning this solicitation.
Instructions
• Please sign the attendance sheet.
• If you need a copy of a solicitation package, you must
register as a DART vendor in the Vendor business
Center. If you do not register, you will not receive critical
future information such as amendments.
• Questions, answers, statements made during the conference shall not change or modify the solicitation unless they are issued as a written amendment to the solicitation.
Instructions (continued)
that need more research may be answered in a future
amendment to this solicitation.
the exhibit/paragraph/page.
Project Overview
• 8,236-foot long double track bridge.
• Active TRE and freight railroad service over bridge.
• Work includes (but not limited to):
• Application of specified sealant materials to the deck, haunch, walkway and parapet areas for the purpose of sealing cracks.
• Remove efflorescence from concrete. • Stain concrete. • Remove ballast retainer.
• Access is currently limited to only the east end of the bridge.
• Complete coordinated work on bridge to facilitate operations of both tracks.
• First Milestone no later than October 30, 2011 to allow for track installation on Main 1 by track contractor.
approx. 53 weekday TRE trains approx. 23 Saturday TRE trains
no Sunday service
Bridge Components
Exterior of Bridge
Exterior of Bridge
Exterior of Bridge
Safety 1) Drug Testing: 5-Panel (Non-DOT, Urinalysis) required within 10 business days before accessing TRE property. Provide DART Name of Individual, Date Tested, Laboratory tested at, and Specimen ID Number.
2) Roadway Worker Protection (RWP): Must be trained before starting project. Or have completed RWP training within last year.
3) TRE "Flagger" must be on-site and give "Job Briefing" before beginning work..each day
4) PPE: Hard Hat, Steeled Toed Boots, Orange Safety Vest, Safety Glasses,
5) Project Safety "Submittals", (See Exhibit M, Section 2,2 ,Work Preparation)
6) Project Designated "Safety Supervisor": Need Résumé to verify qualifications
Risk Management - Contract Insurance
Requirements General Liability - $1MM per occurrence, $2MM aggregate. DART,
The T, Railroads and Herzog Transit need to be listed as additional insureds.
Automobile Liability - $1MM per occurrence. DART and other entities need to be listed as additional insureds.
Workers Compensation - Statutory benefits and $500K Employers Liability. Employer Indemnity type policies will NOT be accepted. Required from Prime & Subcontractors working on site. Waiver of subrogation in favor of DART and other entities.
Umbrella Liability - $4MM per occurrence.
Railroad Protective - $2MM/$6MM
Copies of endorsements are required. Certificate alone is not sufficient.
Only the successful offeror will be required to submit evidence of insurance.
Environmental Compliance
• Submit a Environmental Compliance Manager that meets the
requirements of Specification 01561.
duties.
• No use of asbestos containing products in accordance with 25 TAC
Part 1 Chapter 295.34 (i)
Project Goals
• Goals for this solicitation are 16% MBE and 8% WBE as
shown in Exhibit C.
• Specification for this project is 01451 Quality Control for Small
Projects
• Quality Control Plan Define and document in writing how you plan to communicate,
implement and control the work of your organization as well as
your subcontractors and suppliers, including procedures for
correcting and controlling nonconforming work
Quality Program Requirements
construction prevalent for the contract
Experience shall include two years managing a quality
assurance/ quality control program similar to this project.
• Alternate (CQCR) 3 yrs verifiable construction experience in the type of
construction prevalent for the contract
• Contractor’s Testing Facilities ASTM E 329 or AASHTO R-18
Review of the Solicitation Documents
• Solicitation, Offer, and Award Form
This form must be returned with your bid.
• Schedule
Schedule needs to be signed, dated and returned with bid.
• Exhibit A – Representations and Certifications
Exhibit needs to be completed in full and returned with your bid.
• Exhibit B – Special Solicitation, Instructions and Conditions
Ensure that bids are submitted in sealed envelopes cartons, clearly marked.
Review of Solicitation Documents
*Goals for this project can be found in this exhibit.
• Exhibit D – Special Provisions *Complete Main 1 (North side) no later than October 30, 2011.
*Access to Main 2 (South side) no later than February 1, 2012.
*Complete construction no later than March 30, 2012.
• Exhibit F – General Provisions
• Exhibit G – MBE/WBE Program
Review of Solicitation Documents
• Exhibit J – Drawings
Are available e-mailing Cedric Seay at cseay@dart.org.
• Exhibit L – Pre-Award Survey Documents Needs to be returned with your bid, this questionnaire will be used to verify
responsibility with financial bank and business references submitted.
• Exhibit M – Safety Program
Safety Programs can be found in Exhibit M. This program requires drug
testing of all employees.
Review of Solicitation Documents
Needs to be submitted when requesting clarifications.
• Exhibit P – Bid Bond
• Exhibit Q – Payment Bond
• Exhibit R – Performance Bond
Review of Solicitation Documents
• Exhibit V – Prospective Contractor Employee Information Report Needs to be returned with your bid.
• Wage Rates
This is not a federally funded project therefore, Department of Labor Wage
Rates do not apply to this solicitation.
• Invoicing and Payment Format
Bid Submission
• There will be a public bid opening on the due date.
• Bids are due on August 11, 2011 at 2:00 PM
Questions?
Solicitation No. B-1020803
33.D p. 2 of 10 Amendment #3
notice to and consent by the Contracting Officer. The Contractor shall, if requested by the Authority, remove or reassign any personnel not acceptable to the Authority The Contractor shall designate a primary and an alternate contact for notification of emergency work. The Contracting Officer shall furnish appropriate phone numbers for contacting these individual 24 hours a day via beepers, answering service or other approved means
(b) Authority Representatives
The Authority's Contracting Officer shall appoint, in writing, a Contracting Officer's Representative (COR). This person shall handle all matters of a technical nature arising under the performance of the work.
4. Contract Award Contract Award is anticipated on or around August 25, 2011. 5. Contract Milestones (a) The Contractor shall not proceed with any work required under this contract without a written Notice to Proceed (NTP) from the Authority. Any work performed or expense incurred by the Contractor prior to the Contractor's receipt of NTP shall be entirely at the Contractor's risk. The Contractor shall commence performance of the work under this contract within five (5) calendar days from the date the Contractor receives NTP. The Contractor shall prosecute the work diligently so as to meet the following milestones:
(1) Completion Main 1 (North Side): Complete all work on Main 1 (North Side), not including exterior of structure or removal of ballast retainer. Work to complete includes but is not limited to all work related to Main 1 deck, haunch, walkway, and parapet wall, to allow full and unobstructed access to follow-on track contractor, no later than October 30, 2011.
(2) Construction Completion Access for Main 2 will be granted after Authority’s track contractor completes all work on Main 1 and rail traffic is shifted from Main 2 to Main 1. Access shall be granted no later than February 1, 2012. Complete all construction work required under this contract no later than March 30, 2012.
(b) Not withstanding any other provisions in this contract, the Contractor shall reach a point of Final Acceptance as provided for in the General Provisions entitled "Final Acceptance" no later than June 1, 2012. (c) The Contractor shall not be entitled to compensation for delay unless and only to the extent it is delayed by the Authority in completing beyond the contract completion date. (d) If the Contractor submits a schedule showing a completion of any or all milestones before the scheduled dates, the Authority shall have the unilateral right to modify the contract changing the milestone dates in accordance with the schedule submitted by the Contractor with no equitable adjustment being made. 6. Construction Planning Construction shall be planned and carried out in accordance with the following information: (a) Site Access
(1) Contractor shall not have access to any location where there is active rail traffic.
(2) Contractor access to Main 1 shall be granted upon Notice to Proceed and such access shall
terminate upon completion of Main 1. Contractor shall be granted access to Main 2 by written notification from the Authority after rail traffic has been shifted to Main 1.
(3) Contractor shall not have access to Main 1 while Authority track contractor is performing work on Main 1. Authority track work is anticipated to take up to 60 days to perform.
Solicitation No. B-1020803
33.D p. 3 of 10 Amendment #3
(4) Contractor shall request access from the Authority prior to removal of ballast retainer. Ballast retainer may not be removed until all track work is complete.
(5) The Authority will allow the Contractor to install temporary access to the west end of the bridge that is acceptable to the TRE. The access cannot encroach upon adjacent property not owned by the Authority and cannot interfere with train traffic within the corridor. The Contractor is responsible for all aspects of the access including cost.
(b) Work required on outside of bridge shall not be performed until after completion of the sealing processes on the corresponding inside areas of bridge.
(c) Availability of Authority-furnished Property for Contractor Installation: There is no Authority-furnished Property for this contract.
(d) The Contractor shall stay within the identified construction limits, and shall neither disturb nor alter the designated adjacent property outside the limits of construction. (e) The Contractor shall adhere to the following work hours:
Work hours shall be per the requirements of the specifications, Division 1 "General Requirements" and the City of Irving ordinances unless otherwise extended hours are requested by Contractor and pre-approved and pre- authorized by City of Irving and the Authority. However, notwithstanding the applicable ordinances, any Saturday work adjacent to residential areas shall not start until 9:00 a.m.
(f) The Contractor is advised that in reference to the statement made on Drawing Plan Sheet 7 of 9, Note #2, which reads in part, "...0.3 miles down the ROW...", this 0.3 miles (to the delivery site for the ballast retainer) is over an unpaved, unimproved dirt vehicle path along the north side of the TRE ROW. (g) Submittals
(1)To assist the Contractor with submittals, the Authority has examples of Quality Control and Safety plans that can be made available to the Contractor. The Authority will provide reasonable guidance to the Contractor in preparing such submittals. While the minimum review time allotted for the Authority to review and disposition submittals is 21 days, the Authority will make every reasonable effort to expedite submittal review and disposition within 5 to 10 business days from their receipt.
(2) Submittals are not required for materials that are pre-approved by TxDOT; however, evidence of TxDOT pre-
approval is required prior to beginning work with that product. Pre-approval of products does not relieve the contractor from meeting the requirements of the approved plans and specifications.
7. Contractor Staging Areas The Contractor may use a portion of the DART facility described as western half of the West Irving Station Parking Lot as a staging area for staging and storage area(s). The Contractor will be responsible for all security and maintenance of the staging and storage area(s). The staging area adjacent to the ROW on Drawing Sheet 2 is the property of the City of Irving, and the Contractor is responsible for any & all required negotiations and payments to the City of Irving prior to its use."
8. Coordination With Other Contracts (a) In accordance with the General Provision, entitled "Other Contracts," the Contractor should expect, at a minimum, to interface with the following contractors, agencies and property owners:
(1) TRE's Operation and Maintenance workers and contractors; (2) Authority track contractor completing ballast and rail installation on Main 1; (3) Private utility contractors; (4) Franchise Utility Companies and their contractors; (5) City of Irving; (6) Authority representatives and inspectors.
(b) It is the express obligation and duty of the Contractor under this contract to coordinate its work with the work of other contractors and entities. The Contractor shall not unreasonably impede, hinder or delay the Authority or any other contractor in performance of their work. It is the Contractor's duty under this contract to communicate with any contractor who will be performing work which may connect, complement or interfere with the Contractor's work, and to resolve any disputes or coordination problems with such contractor or entity. 9. Work Adjacent to Active Railroads (D-400.30C, FEB 02) (a) Compliance with Laws and Regulations.
The Contractor shall abide by governing railroad rules, regulations, policies and operating procedures established by the Trinity Railway Express (TRE) and other applicable railroad regulating bodies, including but not limited to the Federal Railroad Administration, Code of Federal Regulations (i.e. 49 CFR 214, Roadway Worker Protection On-Track Safety Program - Exhibit V) and DART Construction Safety Program - Exhibit M. If any failure by the Contractor to comply with any such laws, regulations, and enactments shall result in any fine, penalty, cost or charge being assessed, imposed or levied against the railroad, the Contractor shall reimburse and indemnify the railroad for such fine, penalty, cost or charge, including without limitation attorney's fees, court costs and expenses. The Contractor shall, in the event of any such actions and upon notice thereof being provided by the railroad, defend such action free of cost, charge, or expense to the railroad.
(b) Notification. The Contractor shall provide written notice to the TRE representative (Mr. John Horney, Chief Engineering Officer, Trinity Railway Express, Commuter 214-749-5810) at least fourteen (14) days in advance of commencing any work in which any person or equipment will be within twenty-five (25)
Deck Cracking Repair for TRE Grade Separation Bridge
EXHIBIT O QUESTIONS/CLARIFICATIONS
AMENDMENT NO. 3 B-1020803
NO. SOLICITATION REFERENCE COMMENTS / QUESTIONS RESPONSE 1 General Are the MBE/WBE percentages for the solicitation a
requirement? Refer to subparagraphs (c) and (d) of the provision "Minority and Woman-Owned Business Enterprise (M/WBE) Participation" within Exhibit C. This language makes it clear that these percentages are a requirement, and that it "…is considered by the Authority a matter of the offeror's responsibility" and "DART will only award contracts to offerors deemed to be responsible".
2 Schedule [Bid Schedule], Item 1D Are offerors required to bid the option "Remove Ballast Retainer" listed on the Schedule [Bid Schedule]?
Refer to subparagraph (c) of the provision "Preparation of Bids" within Exhibit C which states that "All blanks on the bid form shall be filled in…". Also, refer to subparagraph (g) of the provision "Estimated Quantities, Evaluation and Basis of Award" which states that "... option pricing will be included in the evaluation for award purposes".
1 of 1 8/4/2011 6:28 PM
01B-1020803 Amendment #3
Descriptive
Changes
The date was changed from “September 15, 2011” to “August 25, 2011” within the provision entitled “Contract Award”. Remove page 2 and replace with “Amendment 3, Exhibit D page 2”.
Language was added as subparagraph (a)(5) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Language was added as subparagraph (f) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”..
Language was added as subparagraphs (g)(1) and (g)(2) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Language (3rd sentence) has been added within the provision entitled “Contractor Staging Areas”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
This sheet is provided as “for information only” in supplement to Sheet 7. Add “Amendment 3, Exhibit J – Drawings, Sheet 7a”.
This sheet is provided as “for information only” in supplement to Note 3 of Sheet 9. Add “Amendment 3, Exhibit J – Drawings, Sheet 9a”.
This sheet is provided as “for information only” in supplement to Note 3 of Sheet 9. Add “Amendment 3, Exhibit J – Drawings, Sheet 9b”.
Firms request Specs
ATTENDEES for PRE-BID
Sheet 7A Temporary Ballast Retainer
Sheet 9A Staining From Sheet 263
Sheet 9B Staining From Sheet 264
AMENDMENT 3 Q&A
02B-1020803 Amendment 3 (changes)
Descriptive
Changes
The date was changed from “September 15, 2011” to “August 25, 2011” within the provision entitled “Contract Award”. Remove page 2 and replace with “Amendment 3, Exhibit D page 2”.
Language was added as subparagraph (a)(5) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Language was added as subparagraph (f) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”..
Language was added as subparagraphs (g)(1) and (g)(2) for the provision entitled “Construction Planning”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
Language (3rd sentence) has been added within the provision entitled “Contractor Staging Areas”. Remove page 3 and replace with “Amendment 3, Exhibit D page 3”.
This sheet is provided as “for information only” in supplement to Sheet 7. Add “Amendment 3, Exhibit J – Drawings, Sheet 7a”.
This sheet is provided as “for information only” in supplement to Note 3 of Sheet 9. Add “Amendment 3, Exhibit J – Drawings, Sheet 9a”.
This sheet is provided as “for information only” in supplement to Note 3 of Sheet 9. Add “Amendment 3, Exhibit J – Drawings, Sheet 9b”.
03Firms request Specs
04ATTENDEES for PRE-BID
08Sheet 7A Temporary Ballast Retainer
09Sheet 9A Staining From Sheet 263
10Sheet 9B Staining From Sheet 264
11AMENDMENT 3 Q&A