ESTABLISHMENT OF POWER GENERATION PLANT AT ZERVANY … · Establishment of Power Generation Plant for Zervany Camp 20 March 2017 Page 3 1.0 PROJECT DESCRIPTION 1. PROJECT SYNOPSIS

STATEMENT OF WORK

FOR

ESTABLISHMENT OF POWER GENERATION PLANT AT ZERVANY CAMP GENERAL CONSTRUCTION SERVICES

U. S. CONSULATE GENERAL ERBIL, IRAQ

14 APRIL 2017

Establishment of Power Generation Plant for Zervany Camp 20 March 2017 Page 2

TABLE OF CONTENTS

1.0 Project Description .............................................................................................................. 3

2.0 General Conditions ............................................................................................................... 4 3.0 Bid Form.……………………………………………………...……………………………………….5

4.0 Scope of Work ....................................................................................................................... .6

5.0 Closeout ................................................................................................................................ 26

6.0 Safety ...................................................................................................................................... 27 7.0 Project Schedule ................................................................................................................ 27

8.0 Responsibilities and Project Management .............................................................. 28


1.0 PROJECT DESCRIPTION

1. PROJECT SYNOPSIS

The project is described as Supply and installation of a 120 KVA Cummins or equivalent diesel generator set. The work includes connecting the system with the national grid (city power); supply and install switchgear, ATS, MDB, cables, wiring, poles, tools and complete civil works to ensure a proper connection and installation. Connect the proposed system with each building, CHU’s and fixtures inside the Zeravany camp using cables, conduits, panels, breakers, junctions, switches, etc., to delivering the power to each facility inside the Zeravany camp.

2. BACKGROUND

At present Zeravany camp does not have sufficient power source and the electrical connection does not meet safety standards.

3. SOLUTION

Improve the electrical power and electrical connection conditions by supplying and installing a 120 KVA diesel generator set, connecting the proposed system with each building, CHU’s and fixtures inside the Zeravany camp using cables, conduits, panels, breakers junctions and switches, etc., to deliver power for each facility inside the Zeravany camp.

2.0 GENERAL CONDITIONS

1. Fixed-Price Proposal. The Contractor shall provide one fixed-priced Proposal for the complete Project that includes every aspect of the Work.

2. Specifications. The Work shall be governed by the U. S. Consulate General, Erbil, Iraq. International Codes include the National Fire Prevention Association (NFPA), International Building Code, International Mechanical Code, International Plumbing Code, and the National Electric Code (NEC). Should there be a discrepancy between the U. S. Consulate General Specifications and the applicable Building Code, the more stringent of the two shall govern.

The Contractor is responsible for compliance with all Building Codes; Work not in compliance with the Codes shall be deemed to be unacceptable.

3. Execution. The Work shall be executed in a diligent and workmanlike manner in accordance with the negotiated fixed-price, this Scope of Work, the Project Schedule, International Building Codes, and the laws of the City of Erbil where applicable.

4. Work Hours. Unless otherwise agreed with COR, the Work shall be executed during normal Consulate work hours. Night, weekend or holiday work shall not be permitted except as arranged in advance with the COR. U. S. Consulate General holiday schedule is available from the COR.

5. Safety. The Contractor shall be responsible for conducting the work in a manner that ensures the safety of residents, employees and visitors to the compound, and the Contractor’s employees.


6. Workforce. The contractor shall provide all supervision, skilled and unskilled labor needed to

perform the work. The contractor shall comply with the U. S. Consulate General security policy by providing approved escorts. Contractor provided escorts shall be in quantity sufficient to comply with RSO escort ratios for number of workers on the project. The contractor shall prepare requests to RSO for vetting of employees to get escort badges. The Contractor or government may request for workers to be badged for unescorted U. S. Consulate General access by going through the RSO vetting process.

7. Subcontractors. Contractor shall be responsible for the conduct and workmanship of Subcontractors engaged in the Project, and for Subcontractors compliance with the terms of this Statement of Work. The Contractor is responsible for the behavior and workmanship of Subcontractors while on Consulate property.

8. Modification to Contract. The Contractor shall not incur any costs beyond those described in this SOW unless directed otherwise in writing by the Contracting Officer. Any work performed by the Contractor beyond this SOW without written direction from the Contracting Officer will be at the Contractor’s own risk and at no cost to the Consulate.

9. Stop Work. At any time during the Project, the Contracting Officer reserves the right to Stop Work for protection of employees or visitors, security, or any other reason at his/her discretion.

10. Submittals. The contractor is responsible to submit shop drawings prior to fabrication and release of any materials for the Facility Manager and COR Review and approval. The review, however, does not relieve the contractor of responsibility to engineer the work to provide a complete working system.

11. Excavation and Utilities. The contractor is responsible to locate all existing utility lines prior to any excavation. Prior to disconnecting any existing utility services, the contractor is responsible to provide 48-hour advance notice to the COR so an outage can be mutually scheduled.

12. Close-out. Prior to final acceptance, the contractor is to submit to the COR marked up drawings (As-Built) reflecting the work as constructed. The drawings shall be digitally submitted on a CD-ROM in both AutoCAD and PDF format and provide one hard copy size A3.

13. Housekeeping. The contractor is responsible to clean up daily before departing the Consulate Compound. At the completion of the work, the Contractor shall clean any impacted areas to a condition equal to original condition. Contractor tools and equipment will be secured when not in use.


3.0 BID FORM

Establishment of Power Generation Plant for Zervany Camp at U. S. Consulate General Erbil, Erbil, Iraq

No Description Unit Qty Unit Price

ID Total Price ID

1 Administration A Mobilization / Demobilization LS

B Submittals – product data and shop drawings

LS 0 0

Administration Sub-Total 2 Construction Work 0 A Architectural LS B Mechanical-Plumbing LS C Electrical LS E Close-out LS 0 Construction Sub-Total

3 DBA Insurance 0

A

Contractor shall cover each of its workers at the site with DBA Workers’ Compensation coverage, and require its subcontractors to do the same. Contractor must furnish certificate evidencing this coverage to the COR prior to starting work.

LS

DBA Insurance Sub-Total Items 1 thru 3 Sub-Total G and A Sub-Total Profit

4 Basic Bid - Contract

Cost

A Bid - Contract

Cost

NOTE: LIST ANY ASSUMPTIONS IN COST ESTIMATE IN WRITING FOR CONSIDERATION UNDER THE BID PROPOSAL REVIEW. ALL REQUESTS FOR INFORMATION MUST BE PROVIDED IN WRITING AND SUBMITTED TO CONTRACTING OFFICER PRIOR TO PROPOSAL DEADLINE DATE AS STATED IN THE ADVERTISED ANNOUNCEMENT.


4.0 SCOPE OF WORK: Establishment of Power Generation Plant for Zeravany Camp, the contractor shall provide all materials, tools and equipment, labor, transportation and supervision and ensure the work is completed safely and properly.

A. General Requirements

1. Within 3 days of Notice to Proceed (NTP), the contractor shall provide the COR a project schedule showing start to completion dates including significant milestones. 2. Within 3 days of NTP, the Contractor shall provide the COR with details of the proposed installation utilizing written description or sketches or both.

3. The contractor is responsible to properly remove and dispose of all debris related to their work, including, but not limited to electrical, mechanical, sanitary accessories, soils, rock excavation, packing materials and scrap steel, uninstalled materials and/or environmental waste. 4. The contractor is responsible to properly layout and prepare for the renovation based on locations provided by the COR, or Facility Manager, if the COR is unavailable.

5. When pursuing the work, the contractor is to take extra care not to damage existing structures. Contractor is responsible to repair any damage caused as the result of their work.

6. When pursuing the work, the contractor is to implement safety measures to protect from damage existing structures not designated as part of scope of work. The limits of construction will be clearly identified and marked to deter unauthorized personnel access.

7. All work shall be according to attached drawings and specifications, Codes (listed below), OBO

program office, OPS/SHEM requirements. If there is a conflict between codes, drawings or

specifications the more stringent will apply.

8. Storage of “Useful" and uninstalled materials will be in a location as directed by the COR.

9. Contractor is responsible to field verify measurements. 10. At completion of work, the Contractor shall clean any impacted areas to a condition equal to

original condition.

11. Contractor will warranty all construction work for a minimum of one (1) year and provide

manufacturer warranties and equipment manuals for all equipment installed to the COR.

12. All construction work will be in conformance with the following Codes:

a. International Building Code, 2009 Edition plus the 2011 OBO International Code Supplement. b. International Plumbing Code, 2009 Edition plus the 2011 OBO International Code

Supplement.


c. International Mechanical Code, 2009 Edition plus the 2011 OBO International Code Supplement.

d. International Fire Code, 2009 Edition plus the 2011 OBO International Code Supplement. e. National Electric Code, 2011 Edition plus the 2011 OBO International Code Supplement. f. International Residential Code 2009 Edition plus the 2011 OBO International Code

Supplement. g. National Fire Protection Association, NFPA 101 and NFPA 58 h. ICC/ANSI A117.1-98 Accessible and Usable Buildings and Facilities i. NECA 90 Recommended Practice for Commissioning Building Electrical Systems (ANSI) j. NECA 1-2010 Standard Practice of Good Workmanship in Electrical Construction (ANSI) k. IEEE C2-2012 National Electrical Safety Code (NESC) l. EM 385-1-1 U.S. Army Corp of Engineers Safety and Health Requirements m. ASTM C150, C33, C260 American Society for Testing and Materials. n. ACI American Concrete Institute. o. AASHTO M 147 American Association of State Highway and Transportation Officials

B. Work Requirements:

Contractor shall provide complete design and construction services, to include all coordination,

supervision, and management necessary to meet the requirements of this contract.

Connecting the proposed system with each building, CHU’s and fixtures inside the Zeravany camp

using cables, conduits, panels, breakers junctions and switches, etc., to complete delivering the power

for each facility inside the Zeravany camp safely and properly

Provide and install cables with high bearing and capacity, cables shall be type THHN/THWN, 90

degree C, copper.

Conduits shall be Electrical PVC or Metallic Tubing for exposed conduits and schedule 40 rigid steel

conduits when encased in concrete.

The generator set and the ancillary equipment shall be installed in the area allocated for the generator

as it will be identified to the venders during the site visit. Vendors shall check and confirm that the

space available is sufficient for installation and proper functioning of the generator. Vendors may

propose alternative arrangements. Allow for costs of supply including port and transport charges,

testing and commissioning.

Cable shall pass in a truss trench/conduit inside the generator room.

The Main Work items will be according to the following Bill of Quantities:

No. Item Description Unit Qty.

1 Modify Existing Generator Room: - -

1.a Modify and extend the existing generator space and concrete pad to

accommodate the proposed (120) KVA new generator, the space shall be

designed and constructed to match with new generator, cables, switchgear and

fuel tank sizes.

LS 1


The work includes:

Casting at least 30 cm thickness of RC, C30 above the existing, concrete

pad, the proposed concrete pad dimensions must match the new

generators dimension, switchgear and fuel tank system sizes.

Construct open channel floor drains as an easy way to dispose of floor

cleaning or other wastes inside the generator room, the open channels

shall be connected with nearest city sewer line or septic tank.

Clean the site; remove any existing cables, materials, furniture and any

other existing materials to prepare the space to the new equipment.

The work includes restoring the floor surfaces to previous status.

All works shall be completed safely and properly according to NEC and OBO program office, CFSM/PDCS, PDCS/DE/E, EB, OPS/SHEM requirements.

1.b Remove and Restoration of Existing Generator Room Roof: The contractor will be responsible of remove the existing roof in the generator room for the purpose of installing the fuel tank and the proposed generator. After the installation the contractor will be responsible of restoration the roof using new materials from the same specifications of existing materials.

LS 1

2.b Underground Utilities: The contractor is responsible to locate all underground

utilities and their depth and location prior to start of work. All utilities shall be

shifted and traced and marked prior to any removal or demolition of work. A

pre-demolition meeting shall be held with the COR and Facility Manager for

locating the utilities, planning the related directions, and confirm removal or re-

routing of existing utilities prior to the commencement of demolition activities.

Contractor shall be responsible for the repair and rehabilitation of any damaged

utility as a result of the excavation process.

LS 1

2 Diesel Generating Set Supply: Test at manufacturers workshop, supply to site and install (120) KVA (prime) Cummins or equivalent generator set, the system shall be according to below:

3 phase and neutral, 50 Hz, 415/240V, 150 C. Emergency prime power (ESP), 1500 rpm, 0.8 Power Factor. Engine air cleaner – duty rating: normal duty – dry replaceable

element with restriction indicator. Silencer container 87 DB at 7 meters. Exhaust system accessories: Flexible, system fixing kit (must be up to

the standers in length and direction). Cooling system design: Air to air charge cooled. Cooling ration: 50% ethylene glycol; 50% water. Auto start diesel engine driven generator set including sound

attenuating canopy, exhaust pipe (standard length). Muffler/Exhaust:

Critical grade fully insulated muffler with its exhaust furnished with a rain cap.

Flex and mounting brackets to install brackets to install the fully insulated muffler.

Insulation blankets for the flex assemble and elbow assembly (exhaust).

No. 1


Battery charger: provide dealer supplied battery charger (input 220 VAC, output VDC adjustable to 27 VDC).

Digital/electronic voltage regulator, latest model. Integral seismic vibration isolators mounted between generator and

base frame. Install R vibration isolators between floor and generator base.

All necessary accessories as specified in the technical specifications will be required.

2.a Control Panel and Alarms: Supply and install control panel complete for the above diesel generator, as specified. All required relays, instruments, meters, cabling (excluding main power cables from the diesel generator) shall be provided. The control panel shall have lighting with a light switch with alarm test and reset switch and digital meter. The generator shall have the following alarms and control push buttons and switches to be located in the control panel :

Strat: Auto/Manual switch. Stop Push Button or switch.

Emergency Push button.

Voltage Adjustment.

Speed Adjustment.

Shutdown Alarm : Over crank. Over speed. Low oil pressure. High-high coolant level. Low-low coolant level. Emergency push button (EPM).

Cautionary Alarms: Battery charger failure pre-wired from the battery charger to the

control panel. Low coolant level. High coolant temperature. Low fuel level.

Digital meter to provide: Frequency. RPM. Operating hours. Oil pressure. Coolant temperature. L-L volts, phase amps, Hz.

No. 1

3 Cables: Provide cables with high bearing and capacity, cables shall be type THHN/THWN, 90 degree C, copper. Work shall be according to below:

Note -


3.a Provide all materials, manpower and resources to connect with the electrical sources (municipality and generator ), connect the ATS board with the MDB, connect the MDB with exiting CHU’s mainboards inside the Zeravany compound.. Cables shall be running according to below:

Cables inside generator room shall runs in UPVC Conduits. Cables outside generator room shall run underground, supply and

install underground ducts and utility structure for cables from new generators/switchgear to the CHU’s and building. The job includes manholes with covers, necks, frames and covers, con-seal, ground rods, PVC conduit, PVC bends, PVC couplings, tie-wraps, conduit spacers, PVC adhesive, concrete, select backfill, pull ropes, pre-cast switchgear pads, etc..

Number of manholes shall be determined by the length of underground cable line, number of CHUs (each building, kitchen, bathroom/facility and CHUs shall have an out-put manhole.

Duct banks are to be installed in PVC conduits, at least 60 cm below ground according to OBO standards.

For underground ducted conduit, provide and install manufactured spacers listed for underground electrical conduit use. Install per manufacturer – Carlon brand or equivalent.

Cables between transformer and AST shall run overhead using electrical poles with complete accessories.

Total length and shall be calculated by the contractor according to space dimensions and load calculation.

The size of the cable between MDB and ATS shall be 3 x 120 + 95 mm. The size of the cables between ATS and each CHU shall be 3 x 10 mm.

Supply and install: XLPE insulated, PVC sheathed, steel wire armored, 4- core, copper conductor cable/buss bars suited with existing switch room panel board for connection in between generator, municipality power grid and excising main buss bars, any other materials or accessories are required when needed according to the IEC and OBO standards and the work completion requirements.

LS 1

4 Conduit: Conduits shall be electrical PVC tubing for exposed and underground conduits and schedule 40 rigid steel conduits when encased in concrete. Work shall be according to below:

Note -


4.a Schedule 80 Conduit & Elbows: PVC rigid nonmetallic conduit (extra heavy wall EPC-80) Listed for use in above ground and below ground applications including

areas subject to physical damage. Rated for use with 90°C conductors Superior weathering characteristics Identified for use in areas subject to physical damage in accordance to

352.12(C), 494* Series. 6 or 8 inch standard radius and special radius elbows. NEMA TC-2 NEC 352 ETL Listed to UL651. Length and location of conduits shall be calculated depending on work

requirement and NEC standards.

LS 1

5 Generator Fuel System (Gravity Fuel system): The contractor will shall supply and install new fuel system and prepare drawings of generator fuel system. The new fuel tank shall feed the new generator by using 3/4 inch black iron pipe and valves. The requirement and the item details will be according to the below:

Note -

5.a On ground Fuel Tank Double Wall/ metal tank cylindrical: Supply and installation double wall/ metal tank (capacity 3,000 L) with

the metal containment dike, containment dike shall have drainage system.

RC foundation, the elevations must be considered. Fittings required and associated civil works. The fuel tank must include level probe (Echotouch-LU20). Fuel filters between the fuel tank and the generator taking in

consideration to install manual valve before the filter. Atmospheric vent (OPW-23 series). Locate fuel point to fill the tank. Confirm location and all details with

COR. Provide quick connect valve, lockable enclosure and identification sign.

Spill containment basin per approved drawing provided by contractor (as listed above).

The fuel tank height should be higher than the generator to guaranty the flowing for the fuel to the generator depending on the gravity (1 M – 1.20 cm higher than the generator).

Install fitting for refilling the tank and ability to connect to the tanker hose.

Fuel tank must have drain valve to clean the tank when needed.

All civil works including excavation and backfilling, concreting etc. shall be included. The contractor must provide a sample to the COR before the provision, the sample must be approve before the product provision.

LS 1

5.b Fuel Pipes and Valves: Supply and install all the required pipes, valves and other accessories from the main fuel tank to the diesel engine, the work include the fuel return pipe with all the required valves, fuel filters and fittings, details drawings shall be submitted for COR approval. All pipes and fittings for the fuel system should be black iron with size ¾ inch.

LS 1


6 Generator Switchgear:

6.a Supply and install switchgear, 4 pole molded case circuit breaker (MCCB) or air circuit breaker (ACB) with adjustable overload, short-circuit and other specified protections, and with adjustable tripping timing, for the protection of generator.

LS 1

6.b Supply and install surge diverters for three phases and neutral. LS 1

6.c Automatic Transfer Switch Panel (ATS): Supply and install (connecting to main bus bars, bus bar size inside the ATS should be according to the calculation of the load) of Automatic Transfer Switch Panel, 4 pole circuit breaker panel for diesel generator incoming complete with automatic mains failure (AMF) and automatic load transfer switch (ATS) switch for automatic transfer of load from national electricity power NEP supply to diesel generator supply and visa-versa. The work must include:

Supply and install new waterproof cabinet; the cabin shall include ABB brand circuit breaker 150 Amp for generator line and another circuit breaker 150 Amp for the utility power. Dimension of cabin must be 150 cm high, 80 cm wide.

The contractor is responsible to provide and install new change-over and transfer switches brand ABB Model OTM630E3CM230C motorized c/o switch. (200-250) amps.

The ATS and breakers shall be ABB brand or equivalent. The cabinet should include ATS with interlock to prevent closing both

breakers at the same time. Provide and install timer for each breaker to control the closing time. The bus bar thickness inside the ATS should be according to the

calculation of the load. Install multi meters at the cabinet (current, voltage, frequency). Install and connect the cables between the generator and the ATS. Install and connect the cables between the utility end point and the ATS. The circuit breaker should be interlocked with the existing national

electricity power incoming breaker not only electrically but also mechanically.

Circuit breaker panel shall be made as the existing panels by keeping provision to connect existing main bus bar and 2 mm sheet steel and electrostatically powder coated.

Detection of mains failure and availability shall be automatic. The cable should copper single core with size 3X120X95 mm for each

phase. Light bulbs for indicating phases

All required control circuits, control cables, contactors, relays etc. shall be included.

LS 1

7 Grounding system: Provide and install grounding system for both generator and ATS and fuel system using copper rods (2.45 m or more). Grounding will be approved by the COR when the contractor test the Ω reading (not more 15 in winter and not more than 20 in summer season). Number of rods will be determined by the reading.

LS 1


8 Lightning protection system: Supply and install lightning protection system, the work includes a network of air terminals, bonding conductors, and ground electrodes designed to provide a low impedance path to ground for potential strikes.

LS 1

9 Miscellaneous: 9.a Training and Commissioning: The contractor shall provide a training course

to the technicians with submitting all catalogs. The work include commissioning and testing the system; test performance inspection of the generator is required prior to delivery.

LS 1

5.0 Closeout.

Prior to Final Acceptance the Contractor shall submit to the Contracting Officer Representative marked up drawings (As-Built), one A3 hard copy and one soft AutoCAD, reflecting the work as constructed.

6.0 Safety (FAR 52.236-13 Accident Prevention).

1. The Contractor shall provide and maintain work environments and procedures which will:

(a) Safeguard the public and Government personnel, property, materials, supplies, and equipment

exposed to Contractor operations and activities.

(b) Avoid interruptions of Government operations and delays in project completion dates.

(c) Control costs in the performance of this contract.

2. For these purposes on contracts for construction or dismantling, demolition, or removal of

improvements, the Contractor shall-

(a) Provide appropriate safety barricades, signs, and signal lights

(b) Comply with the standards issued by the Secretary of Labor at 29 CFR part 1926 and 29 CFR part

1910

(c) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary

for the purposes are taken.

3. Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of

Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation

4. Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any

condition which poses a serious or imminent danger to the health or safety of the public or Government

personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and

request immediate initiation of corrective action. This notice, when delivered to the Contractor or the

Contractor's representative at the work site, shall be deemed sufficient notice of the noncompliance and

that corrective action is required. After receiving the notice, the Contractor shall immediately take

corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting

Officer may issue an order stopping all or part of the work until satisfactory corrective action has been

taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension

of the performance schedule on any stop work order issued under this clause.

7.0 PROJECT SCHEDULE

A. Approximate dates of pre-award activities


Pre-Bid Site Survey o/a Bids Due o/a Contract Award o/a Notice to Precede (NTP) o/a B. Construction Milestones, from Notice to Proceed Notice to Proceed (NTP) 2 days from NTP Project Schedule to OBO 1 Project Design Notes / Sketches 1 FAC Review 2 Procurement, Shipping 1 Fabrication 2 Construction Completion 75 Project Acceptance 75 C. Deliverables Construction Schedule 2 days from NTP Project Design Notes / Sketches 2 Submittals for Major Equipment 2 Manufacturer’s Literature 75 As-Built, Warranties 75 D. Commencement, Prosecution, and Completion of Work The Contractor shall be required to (a) commence work under this contract within one (2) calendar days after

the date the Contractor receives the Notice to Proceed, (b) prosecute the work diligently, and (c) complete the

entire work ready for use “Completion Date Including punch list” not later than (75) calendar days after NTP.

The time stated for completion shall include final cleanup of the premises. 8.0 RESPONSIBILITIES AND PROJECT MANAGEMENT

A. COR. A Contracting Officers Representative (COR) will be assigned to ensure quality assurance goals are met. The Contractor shall provide the COR access to the site at all times. B. Point of Contact. The COR shall be the main point of contact for this Project. The Contractor shall report to the COR on (a) status of the Project, (b) changes in Schedule, (c) accidents and safety issues, (d) disruptions to utility services; and all other important information pertaining to the Project. C. Management Personnel. The Contractor shall staff the site, full-time, with a competent senior manager who shall perform project management. Remote project management is not an option. This individual shall keep a detailed written history of the project and shall update the Government on daily bases. D. Site Security. The Contractor is responsible for on-site security as necessary to ensure no unauthorized access to their work sites. The Contractor is 100% responsible for securing their working


materials and equipment. Any damage to facilities or infrastructure, which happens due to a lack of security, will be the responsibility of the Contractor to correct. E. Contractor’s Temporary Work Center. The Contractor will be permitted to use a designated area within the contract limits for operation of his construction equipment and office if warranted. If directed by the Contracting Officer, the Contractor shall not receive additional compensation to relocate his operations. The Contractor is responsible for obtaining any required additional mobilization area above that designated. On completion of the contract, all facilities shall be removed from the mobilization area within 5 days of final acceptance by the Contractor and shall be disposed of in accordance with applicable host government laws and regulations. The site shall be cleared of construction debris and other materials and the area restored to its final grade. The Contractor is responsible for maintaining this area in a clear orderly manner. F. Health and Safety. The Contractor shall be solely responsible for risk assessments, managing health, and safety issues associated with this project. The Contractor must provide cold water to all workers at the job sites. Based on hazard assessments, Contractors shall provide or afford each affected employee personal protective equipment (PPE) that will protect the employee from hazards. At a minimum PPE shall consist of eye protection, hard hats, and closed toe shoes. If the workers arrive on-site with sandals or athletic shoes, the Contractor is expected to provide rubber boots to them or send them home. All construction workers and management personnel must wear hard hats at all times on the construction sites. Contractor provided rubber boots and rubber gloves shall be worn when working around concrete placement. Other PPE such as gloves, dust masks, air respirators (sewage work) are also recommended. These items must be provided at the Contractor’s expense. Workers may use discretion if they feel unsafe in using the equipment in a hostile environment. Any worker at an elevated location above 4 meters, with the exception of a portable ladder, must be provided and utilize a safety harness. G. Progress Payments. If the contract awarder expects to receive more than one (1) progress payment, the Contractor must submit a broken out Cost Proposal with a Schedule of Values in order to properly calculate the percentage of contract completion.

Documents

ESTABLISHMENT OF POWER GENERATION PLANT AT ZERVANY … · Establishment of Power Generation Plant for Zervany Camp 20 March 2017 Page 3 1.0 PROJECT DESCRIPTION 1. PROJECT SYNOPSIS