Upload
others
View
1
Download
0
Embed Size (px)
Citation preview
20ih SEP 26 AM
IIIIIIII 2014
IIIIIIII 0926-0 0
IIIIIIIIIIII 80117
US E P A RECORDS CENTER REGION 5
Mary Hoilinrake P:1/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL 476538
ACCESS AND ENFORCEMENT EASEMENT
This transfer is exempt from County and State transfer taxes pursuant to MCL 207.505(a) and MCL 207.526(a), respectively.
Butterworth Landfill Superfund Site, Kent County, Michigan U.S. EPA Site ID Number MID062222997 MDEQ Site No. 41000008 MDEQ Reference No. RC-RRD-201-13-10
This Access and Enforcement Easement ("Easement") is made on September "23, 2014 by the Grantor, the City of Grand Rapids, whose address is 300 Monroe Avenue, Grand Rapids, Michigan 49503 for the benefit of The United States of America, care of the Regional Administrator of the United States Environmental Protection Agency Region 5 ("U.S. EPA"), whose address is 77 West Jackson Avenue, Chicago, Illinois 60604; The State of Michigan, care of the Michigan Department of Environmental Quality ("MDEQ"), whose address is Constitution Hall, 525 West Allegan Street, P.O. Box 30473, Lansing, Michigan 48909-7973 and The Settling Parties identified on Exhibit 1 to this Easement (collectively "Grantees").
RECITALS
i. The Grantor is the title holder of the real property located in Kent County, Michigan and legally described and shown in the survey in Exhibit 2 attached hereto ("Property"),
ii. The purpose of this Easement is to create restrictions that run with the land in the Grantor's real property rights; to protect the public health, safety, and welfare, and the environment; to prohibit or restrict activities that could result in unacceptable exposure to environmental contamination present at the Property; and to grant access to the Grantees to monitor and implement response activities on the Property required under the Consent Decree between The United States and City of Grand Rapids, et al. lodged on May 21, 1999 ("Decree").
iii. The Property comprises part of the Butterworth Landfill Superfund Site, located on Butterworth Avenue in Grand Rapids, Michigan ("the Site"). The Site encompasses approximately 170 acres, and its approximate boundaries are the Grand River on the south, Interstate 196 on the west, Butterworth Street on the north, and the Consumers Energy Company substation on the east, and is depicted generally on Exhibit 3 to this Declaration. The Site was the subject of an enforcement action by the U.S. E P A under the Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended, 42 U.S.C. §
iNiiiDiiniiiiiiiiiiiiiiii 40926-0080117
Mary HoUinrake P:2/120 11:57fiM Kent Cnty MI Rgstr09/25/2014 SEAL
9601, et seq. ("CERCLA"). U.S. E P A has determined that the Site contains hazardous substances and is a "facility" under C E R C L A . The MDEQ has determined that the Property is a "facility" as defined by Michigan's Natural Resources and Environmental Protection Act's (NREPA) Part 201, Environmental Remediation, 1994 PA 451, MCL 324.20101 et seq. Contaminants of concern in Site soils include arsenic, beryllium, chromium, polynuclear aromatic hydrocarbons, polychlorinated biphenyls ("PCBs") and dieldrin; contaminants of concern in Site groundwater are antimony, arsenic, 1,1-dichloroethane, vinyl chloride, bis (2-ethyl hexyl) phthalate and PCBs . In 1983, U.S. E P A listed the Site on the National Priorities List which it promulgated pursuant to Section 105 of C E R C L A .
iv. Certain of the Settling Parties completed a Remedial Investigation and Feasibility Study to determine the nature and extent of any environmental impact at the Site and to evaluate remedial action alternatives. In September 1992, the U.S. E P A issued a Record of Decision ("ROD") for the Site in which the U.S. E P A selected the remedy for the Site. In 1999, the Settling Parties and others entered into the Decree with U.S. E P A for the performance of the remedy selected by U.S. E P A for the Site. The Decree was lodged on May 21, 1999, with the United States District Court for the Western District of Michigan, Southern Division, in the case of United States of America v. City of Grand Rapids, et al., Civil Action No. 1:99-CV-388. Under Section VI ofthe Decree, the Settling Parties were required to perform the remedy as defined by the Decree (the "Work"), which included the placement of a soil cover on the Property. Under Paragraphs 13 and 17 of the Decree, U.S. E P A has reserved the right to modify the Work and has retained the authority to select and require performance of further response actions at the Site. The Decree is attached as Exhibit 4 to this Easement.
v. The restrictions contained in this Easement are based upon information available at the time the Easement was issued. Future changes in the environmental condition of the Property or changes in the applicable cleanup criteria; the discovery of new environmental conditions at the Property or the use of the Property in a manner inconsistent with the restrictions described herein may result in this Easement not being protective of public health, safety, and welfare, and the environment. Information pertaining to the environmental conditions at the Property and Response Activities undertaken at the Site is on file with the U.S. EPA.
vi. Prospective purchasers of the Property should undertake appropriate due diligence prior to acquiring or using this Property, and undertake appropriate actions to comply with the applicable requirements of Section 20107a of Part 201, MCL 324.20107a.
DECLARATION
For valuable consideration of less than $100.00, the receipt of which is hereby acknowledged, the Grantor, on behalf of itself, its successors and assigns declares that the Property shall be subject to the restrictions set forth below, for the benefit of the Grantees, and grants and conveys to the Grantees, and their assigns and representatives, the perpetual right to enforce said restrictions. The Grantor further, on behalf of itself, its successors and assigns does grant and convey to the Grantees and their representatives a right of access ofthe nature, character, and purposes set forth below with respect to the Property, and the right to enforce said right of access.
2
Restrictions on Land Use.
IIII illlllil :| 111'llil' 20140926-0080117
Mary Hoilinrake P:3/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
1. The Property shall not be used for residential purposes, and may only be used in a manner that has received the U.S. EPA 's prior approval.
2. Prohibited activity at the Property includes any activity that may interfere with or adversely affect the integrity or protection of the Work or any other remedial action, operation and maintenance, monitoring, or other measures undertaken by any party at the direction of U.S. EPA .
3. The following activities are also prohibited on the Property:
(a) In addition to the prohibitions recited in City of Grand Rapids Ordinance No. 2002-28, groundwater well installation and groundwater use within the Property boundary for all domestic, commercial, and industrial uses, except groundwater monitoring wells necessary to implement the Work, as approved by U.S. E P A in accordance with Section XI of the Decree.
(b) Construction of groundwater-fed impoundments within the Property boundary.
(c) The excavation of soil on the Property beyond the top eighteen (18) inches within the limits of waste, unless approved by U.S. E P A in accordance with Section XI of the Decree and personnel are properly trained according to 29 C F R 1910.120. When excavation penetrates the cap and occurs within the limits of waste, Grantor shall require the cap to be restored to its original specifications within 72 hours of Grantor's receipt of actual notice of the excavation, unless U.S. E P A or its successor identifies a longer period. . Excavation within the Property boundary and outside the limits of waste will be limited to the unsaturated zone. Excavation outside the limits of waste and within the saturated zone are prohibited unless U.S. E P A first approves a workplan and schedule for such excavation in accordance with Section XI of the Decree, and personnel are properly trained according to 29 C F R 1910.120.
(d) Installation, construction, removal or use of any buildings, wells, pipes, roads, ditches or any other structures within the Property boundary except as necessary to implement the Work or otherwise approved by the U.S. EPA. in accordance with procedures contained in Section XI of the Decree. In the event Grantor needs to perform emergency work on the Property, including but not limited to work to address electric line damage, grantor shall, where practicable, provide EPA with verbal advance notice of the Work, and provide U.S. E P A with written follow-up notice of the Work within 72 hours of completion of the Work.
(e) With respect to its activities on the Property, the Grantor shall manage all soils, media and/or debris located on the Property in accordance with the applicable requirements of Section 20120c of Part 201, MCL 324.20120c and Part 111, Hazardous Waste Management, of the NREPA, MCL 324.11101 et seq.; the Resource Conservation and Recovery Act, 42 U.S.C. Section 6901 et seq.; the administrative rules promulgated thereunder; and all other relevant state and federal laws and regulations.
0 • I l
409 IIIIIIII 26-0 0
IIIIIIIIIIII 80117
B. Right of Access. Mary HoUinrake P.-4/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
1. Right of Access. Grantor grants and conveys to Grantees and their agents, consultants and contractors, subject to the notice and purpose requirements and for the activities set forth below, an access easement on, over, under and across the Property.
2. Scope of Access. Subject to Section 104(a) and (b) of C E R C L A (42 U.S.C. § 9604 (a)-(b), the scope of this access right shall include the right to enter and traverse the Property, upon a minimum of seventy-two (72) hours advance notice to Grantor, for the purpose of conducting activity required by the Decree, including without limitation, the following activities:
(a) Implementing, operating or maintaining the Work.;
(b) Monitoring the Work;
(c) Verifying any data or information submitted to the United States;
(d) Conducting investigations relating to contamination at or near the Site;
(e) Obtaining samples;
(f) Assessing the need for, planning, or implementing additional response actions at or near the Site;
(g) Inspecting and copying records, operating logs, contracts, or other documents maintained or generated by the Settling Parties or their agents, consistent with Section XXIV (Access to Information);
(h) Assessing the Settling Parties' compliance with the Decree;
(i) Determining whether the Site or other Property is being used in a manner that is prohibited or restricted, or that may need to be prohibited or restricted, by or pursuant to the Decree; and
G) Other activities reasonably necessary and incidental to the implementation of the foregoing activities.
C. Term. This Easement shall run with the land and shall be binding on the Grantor and successors in title.
D. Enforcement. Grantees may enforce the restrictions and right of access set forth in this Easement by legal action in a court of competent jurisdiction. Notwithstanding any provision in this Easement, the U.S. E P A and the State of Michigan retain any access authorities and rights, any rights to require different land and water use restrictions, including enforcement related thereto, that may exist under C E R C L A , the Resource Conservation and Recovery Act ("RCRA"), 42 U.S.C. § 6901 et seq., Michigan Part 201, and any other applicable state or federal law or regulation.
E. Modification/Release/Rescission. The Grantor may request in writing to the U.S. EPA, with a copy to MDEQ, modifications to, or release or rescission of, this Easement. This Easement may be modified, released, or rescinded only with the written approval of the
4
IIIIIIIIIIII iiniiiiiiiiuiiiiii 20140926-0080117
Mary HoUinrake P:5/120 11:57AM ' Kent Cnty MI Rgstr 09/26/2014 SEAL
Grantees. Any approved modification to, or release or rescission of, this Easement shall be filed with the appropriate county Register of Deeds by the Grantor and a certified copy shall be returned to the U.S. EPA, with a copy to MDEQ and the Settling Parties.
F. Notification of Recording. Grantor shall provide a copy of this Easement to Grantees within 60 days of the return of a stamped copy of the easement to Grantor from the Kent County Register of Deeds.
G. Transfer of Interest. The Grantor shall provide notice at the addresses provided in this document to the U.S. EPA, the MDEQ and the Settling Parties of the Grantor's intent to transfer any interest in the Property, or any portion thereof, at least fourteen (14) business days prior to consummating the conveyance. A conveyance of title, easement, or other interest in the Property shall not be consummated by the Grantor without adequate and complete provision for compliance with the terms and conditions of this Easement, the applicable provisions of the Decree, and the applicable provisions of Section 20116 of Part 201, MCL 324.20116.
H. Notices. Any notice, demand, request, consent, approval, or communication that is required to be made or obtained under this Easement shall be made in writing; include a statement that the notice is being made pursuant to the requirements of this Easement; include the MDEQ Site ID number and reference number; and shall be served either personally, or sent via first class mail, postage prepaid, as follows:
Forthe U.S. E P A :
Richard Karl Director Superfund Division (SR-6J) U.S. Environmental Protection Agency, Region 5 77 West Jackson Blvd. Chicago, IL 60604
with a copy to:
Thomas M. Williams Office of Regional Counsel (C-14J) U.S. Environmental Protection Agency, Region 5 77 West Jackson Blvd. Chicago, IL 60604
Forthe MDEQ:
Robert Wagner Chief Remediation and Redevelopment Division Michigan Department of Environmental Quality P.O. Box 30426 Lansing, Ml 48909-7926
For the Settling Parties:
| IlllilfllllllUI IIIIIIIIIIII 20140926-0080117
Mary Hollinrake P:6/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
Dennis J . Donohue Warner Norcross & Judd LLP 900 Fifth Third Building 111 Lyon Street, NW Grand Rapids, Ml 49503
John A. Ferroli Dykema Gossett PLLC 300 Ottawa Avenue, NW Suite 700 Grand Rapids, Ml 49503
I. Miscellaneous.
(a) Controlling Law. The interpretation and performance of this Easement shall be governed by the laws of the United States as to the obligations referred to in the Decree and by the laws and regulations of the State of Michigan for all other purposes hereunder (without reference to choice of laws and principles thereof). The right to enforce the conditions and restrictions in this Easement are in addition to other rights and remedies that may be available, including, but not limited to, administrative and judicial remedies under C E R C L A or Part 201 of the NREPA.
(b) Construction. Any general rule of construction to the contrary notwithstanding, this Easement shall be liberally construed to achieve the purpose of this Easement and the policy and purpose of C E R C L A and the land use restrictions and prospective limitations required by Part 201. If any provision of this Easement is found to be ambiguous, an interpretation consistent with the purpose of this Easement that would render the provision valid shall be favored over any interpretation that would render it invalid.
(c) Severability. If any provision of this Easement is held to be invalid by any court of competent jurisdiction, the invalidity of such provision shall not affect the validity of any other provision hereof, and all other provisions shall continue unimpaired and in full force and effect.
(d) Entire Agreement This Easement and its attachments and appendices supersedes all prior discussions, negotiations, understandings, or agreements between the undersigned relating to the matters addressed herein, all of which are merged herein.
(e) Successors. A conveyance of title, easement, or other interest in the Property shall not be consummated by the Owner without adequate and complete provision for compliance with the terms of this Easement. A copy of this Easement shall be provided to all future owners, heirs, successors, lessees, easement holders, assigns, and transferees by the person transferring the interest. The Easements, terms, conditions and restrictions in this Declaration shall be binding upon, and inure to the benefit of, the Grantor and Grantees and their agents, successors, lessees and assigns and any subsequent title holders, occupants or other persons acquiring an interest in the Property or some relevant sub-portion of the Property, and their respective agents, successors and assigns. The rights, but not the obligations or authorities, ofthe U.S. E P A are freely assignable to any public entity, subject to the notice to the
6
IIIIIIII IIHIIIllllllllUIIIII 20140926-0080117
Mary HoUinrake P:7/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
Grantor, its successors and assigns, as their interests appear in the public title records kept and maintained by the Kent County Register of Deeds.
J. Exhibits. The following exhibits are incorporated into this Easement:
Exhibit 1 - List of Settling Parties
Exhibit 2 - Legal description of Property and Survey
Exhibit 3 - General Depiction of Butterworth Landfill Site
Exhibit 4 - Consent Decree
K. Authority to Execute Restrictive Easement and Right of Access. The undersigned person executing this Easement represents and certifies that he or she is duly authorized and has been empowered to execute this Easement.
IN WITNESS W H E R E O F , the parties hereto have set their hands thereto as of the day first above written. ,
By:
Attest: /^.fO!/W Darlene O'Neal, City Clerk
7
mil 20
IIIII 40926
Illllllllll 00801
IIII 17
STATE OF MICHIGAN
COUNTY OF KENT
Mary HoUinrake P:8/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
) SS.
)
On this ^ 3 day of S-ep4cw\b-er , 2014, before me, a Notary Public in and for said County, personally appeared the above named George K. Heartwell, Mayor ofthe City of Grand Rapids, to me known to be the same person described in and who executed the within instrument, and who has acknowledged the same to be his free act and deed.
Notary Public, My commission expires:
County, Michigan
JANE BUSH Notary Public, State of MiShigift
County of Kent I My Commission Expires July 30, ZQZO
This Document Prepared By: Dennis J . Donohue Warner Norcross & Judd LLP 111 Lyon Street, N.W. 900 Fifth Third Building Grand Rapids, Michigan 49503 616-752-2192
11242772
8
111! 20
IIIIII1II 26-00801' 409
III Mary HoUinrake P:9/120 11:57PM Kent Cnty MI Rgstr09/26/2014 SEAL
EXHIBIT 1
Allied Waste Systems, Inc.
City of Grand Rapids, Michigan
Consumers Energy Company
C S X Transportation, Inc.
Metromedia International, Inc.
Pactiv Corporation
Steelcase Inc.
Waste Management of Michigan, Inc.
ElectroLux Home Products, Inc.
Wolverine World Wide, Inc.
IIII 201
llllllllllllllllllllllllllllll 40926-0080
Mary HoUinrake P: 10/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEfiL
EXHIBIT 2
Parcel 1:
A parcel of land 208.8 feet East and West by 626.4 feet North and South in the Northwest corner of that part of the East 5/8 of the East 1/2 of the Northwest 1/4 of Section 35, Town 7 North, Range 12 West, City of Grand Rapids, Kent County, Michigan, lying South ofthe railroad right of way of The Penn Central Corporation, excepting therefrom that part thereof lying Northerly of the Southerly line of Lot 2 of Cusick Bros & Thomasma Addition to the City of Grand Rapids, as said Southerly line of said Lot is extended in a Westerly direction to the West line of said above described land.
Parcel 2:
That part ofthe West 1155 feet ofthe Northwest fractional 1/4 of Section 35, Town 7 North, Range 12 West, City of Grand Rapids, Kent County, Michigan, tying Southerly of a line 66 feet Southerly of and parallel with the Southerly line of L.S. & M.S. Railroad Co. right-of-way and Easterly ofthe Easterly right-of-way line of Highway M-21 and Northerly of a line described as follows: Commencing at a point on the West line of said Section which is 510.58 feet South of the Northwest corner of said Section, running thence S 62 degrees 22 minutes 45 seconds E to a point on the East line of said West 1155 feet of the Northwest fractional 1/4.
Parcel 3;
East 1/2 of East 1/2 of Northwest fractional 1/4 of Section 35, Town 7 North, Range 12 West, City of Grand Rapids, Kent County, Michigan, except the North 1560 feet thereof, also except commencing at a point on West line of East 1/4 of East 1/2 of Northwest fractional 1/4 of said Section, 1560 feet South of North line of said Section, thence West parallel with said North line of Section 330 feet to a point 33 feet Northerly of Northeast comer of Lot 98, Cusick Brothers and Thomasma Addition, thence Southerly along East line of said Addition 417.42 feet, thence East parallel with said North line of Section 35, 417.42 feet, thence Northerly 417.42 feet to a point 87.42 feet East of beginning, thence West 87.42 feet to beginning.
Parcel 4:
That part ofthe West 1155 feet ofthe Northwest fractional 1/4 of Section 35, Town 7 North, Range 12 West, City of Grand Rapids, Kent County, Michigan, lying Easterly ofthe Easterly Right-Of-Way line of Highway M-21 and Southerly of a line described as follows: Commencing at a point on the West line of said Section which is 659.51 feet South of the Northwest corner of said section, running thence S 62 degrees 22 minutes 45 seconds E to a point on the East line of said West 1155 feet of the Northwest fractional 1/4. Also, that part of the Southwest fractional 1/4 of Section 35, Town 7 North, Range 12 West, lying North ofthe Grand River. Except the West 2 rods thereof.
Parcel 5;
The W 1/2 of E 1/2 of W 1/2 of E 1/2 of NW Fractional 1/4 of Sec. 35, T7N, R12W, City of Grand Rapids, Kent County, Michigan and W 1/2 of W 1/2 of E 1/2 of NW Fr'l 1/4 of Sec. 35, T7N, R12W, also E 1/4 of E 1/2 of W 1/2 of NW Fr'l 1/4 of Sec. 35, T7N, R12W, except that part lying N of a line 132 feet S of S'ly line, LS & MSRR Co's Right of Way (34 acres). Except part of NW 1/4 of Sec. 35, T7N, R12W, commencing at NW corner of said section, thence S 659.61 feet along W line of said section, thence S 62 degrees 22 minutes 45 seconds E 1,315.88 feet to a point on W line of E 1/8 of W 1/2 of NW 1/4 of said section to the point of
IIIIII IIIIIIIIIIII IIIIIIIIIIII 20140926-0080117
Mary HoUinrake PM1/120 11:57RM Kent Cnty MI Rgstr09/26/2014 SEAL
EXHIBIT 2
beginning of this description; thence continuing S 62 degrees 22 minutes 45 seconds E 646.34 feet, thence S 88 degrees 33 minutes 15 seconds E 100 feet to a point on W'ly line of Cusick Bros & Thomasma Addition, said point being 1,527 feet S'ly of N line of said section and measured along W'ly line of said Plat, thence N 1 degree 1 minute 7 seconds W along W'ly line of said Plat 132 feet, thence N 88 degrees 33 minutes 15 seconds W 63.57 feet, thence N 62 degrees 22 minutes 45 seconds W 686.53 feet to a point on W line of E 1/8 of W 1/2 of NW 1/4 of said section, thence S 0 degrees 38 minutes 25 seconds E along said W line of E 1/8 of W 1/2 of NW 1/4 of said section 149.8 feet to beginning.
Together with easements reserved in Liber 1927, Page 1234.
Parcel 6:
Lots 106 through 110, Cusick Bros. & Thomasma Addition to the City of Grand Rapids, Kent County, Michigan, as recorded in Liber 19 of Plats, Page 31, including that portion of vacated Ives Avenue located to the West of and adjacent to Lot 106 through Lot 110 extended.
Together with the easement reserved in Liber 1932, Page 1024.
EXHIBIT 4
IN T H E UNITED S T A T E S DISTRICT C O U R T F O R T H E W E S T E R N DISTRICT OF M I C H I G A N
S O U T H E R N DIVISION
UNITED S T A T E S OF A M E R I C A ,
Plaintiff,
v.
A L L I E D W A S T E S Y S T E M S , INC., et al.,
Defendants.
II 201 40
IllllllUIIWif 926-0080117
Mary HoUinrake P: 14/120 Kent Cnty MI Rgstr09/26/2014 SEAL
C I V I L A C T I O N N O .
C O N S E N T D E C R E E
United States v. Allied Waste Systems, et.al.
Butterworth #2 Landfill Superfund Site
CONSENT DECREE
IIIIIIIIIIII IIIIIIIIII 20140926-0080 17
Mary HoUinrake PM5/120 11-.57AM Kent Cnty MI Rgstr09/26/2014 SEAL
T A B L E OF CONTENTS
BUTTERWORTH #2 L A N D F I L L R A CONSENT DECREE
I. B A C K G R O U N D
II. JURISDICTION
III. PARTIES BOUND
IV. DEFINITIONS
V. G E N E R A L PROVISIONS
VI. PERFORMANCE OF THE W O R K B Y SETTLING DEFENDANTS . .
VII. R E M E D Y REVIEW
VIII. OUALITY ASSURANCE. SAMPLING, and D A T A A N A L Y S I S
IX. ACCESS A N D INSTITUTIONAL CONTROLS
X . REPORTING REQUIREMENTS
XI . EPA A P P R O V A L OF PLANS A N D OTHER SUBMISSIONS
XII. PROJECT COORDINATORS
XIII. A S S U R A N C E OF ABILITY TO COMPLETE WORK
XIV. CERTIFICATION OF COMPLETION
X V . ' E M E R G E N C Y RESPONSE
X V I . P A Y M E N T OF RESPONSE COSTS
XVII. INDEMNIFICATION AND INSURANCE
x v i n . FORCE M A J E U R E
XIX. DISPUTE RESOLUTION :
16
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE
XXI
X X I .
XXII .
XXIII.
X X I V .
X X V .
X X V I .
X X V I I .
XXVIII .
X X I X .
X X X .
X X X I .
X X X I I .
XXXIII .
niiiiiiiiiiiiiiiiiuiiiiiwiiiiiiiiiiii 20140926-0080117
Mary HoUinrake P; 16/120 11:57RM Kent Cnty MI Rgstr09/26/2014 SEAL
STIPULATED PENALTIES ..". . . . . . . . .".
COVENANTS NOT TO SUE B Y PLAINTIFF-
COVENANTS B Y SETTLING DEFENDANTS
-59
-64
-68
EFFECT OF SETTLEMENT: CONTRIBUTION PROTECTION - 7 0 -
ACCESS TO INFORMATION - 72 -
RETENTION OF RECORDS - 73 -
NOTICES A N D SUBMISSIONS - 7 5 -
EFFECTIVE DATE . 7 7 .
RETENTION OF JURISDICTION . 7 7 .
APPENDICES - 77 .
COMMUNITY RELATIONS . 78 -
MODIFICATION - 7 8 -
LODGING A N D OPPORTUNITY FOR PUBLIC C O M M E N T - 79 -
SIGNATORIES/SERVICE .79 .
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE
Illlllllllllllllllllllllll 20140926-0080117
Nary HoUinrake P:17/120 11:57fiM Kent Cnty MI Rgstr09/26/2014 SEAL
IN THE UNITED STATES DISTRICT COURT FOR THE WESTERN DISTRICT OF MICHIGAN
SOUTHERN DIVISION
UNITED STATES OF A M E R I C A Plaintiff,
v.
ALLIED WASTE SYSTEMS, INC., et al.,
Defendants.
CIVIL ACTION NO.
CONSENT DECREE FOR CONDUCTING R E M E D I A L ACTION
I. B A C K G R O U N D
The United States of America ("United States"), on behalf of the Administrator of the
United States Environmental Protection Agency ("EPA"), filed a complaint in this matter
pursuant to Sections 106 and 107 ofthe Comprehensive Environmental Response,
Compensation, and Liability Act ("CERCLA"), 42 U.S.C. §§ 9606, 9607.
A . The United States in its complaint seeks, inter alia, the performance of studies
and response work by the defendants at the Site consistent with the National Contingency Plan,
40 C.F.R. Part 300 (as amended) ("NCP").
B. In accordance with the NCP and Section 121(f)(1)(F) of C E R C L A , 42 U.S.C.
§ 9621(f)(1)(F), EPA notified the State of Michigan (the "State") on December 12, 1997 of
negotiations with potentially responsible parties regarding the implementation ofthe remedial
action for the Site, and EPA has provided the State with an opportunity to participate in such
negotiations and be a party to this Consent Decree.
HuiiiiiiiiiiiiiiiiiiiiNinii 20140926-00801 17
Mary HoUinrake PM8/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
C. In accordance with Section 122(j)(T) of CERCLA, 42 U.S.C. § 9622(j)(l), EPA
notified the Federal Natural Resource Trustee prior to negotiations with potentially responsible
parties regarding the release of hazardous substances that may have resulted in injury to the
natural resources under Federal trusteeship and encouraged the trustee(s) to participate in the
negotiation of this Consent Decree.
D. The Defendants that have entered into this Consent Decree do not admit any
liability to the Plaintiff arising out ofthe transactions or occurrences alleged in the complaint,
nor do they acknowledge that the release or threatened release of hazardous substances at or from
the Site constitutes an imminent or substantial endangerrnent to the public health or welfare or
the environment.
E. Pursuant to Section 105 of C E R C L A , 42 U.S.C. § 9605, E P A placed the Site on
the National Priorities List, set forth at 40 C.F.R. Part 300, Appendix B, by publication in the
Federal Register on December 30, 1982.
F. In response to a release or a substantial threat of a release of hazardous
substances at and from the Site, on June 27, 198.6 E P A entered into a Consent Decree with five
PRPs, the City of Grand Rapids, General Motors Corporation, Michigan Waste Systems, Wickes
Manufacturing Company and Organic Chemicals Inc., to conduct a Remedial Investigation and
Feasibility Study ("RI/FS") pursuant to 40 C.F.R. § 300.430. The RI/FS was completed in
December 1991.
G. Pursuant to Section 117 of C E R C L A , 42 U.S.C. § 9617, E P A published notice of
the completion of the FS and of the proposed plan for remedial action in May 1992, in a major
Dili ted States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE 2 -
niiiiiiniiiiiiuiiiiniiiininiiiiuiii 20' 40926-0080117
Mary HoUinrake P: 19/120 11:57AM Kent Cnty MI Rgstr09/26/2O14 SEAL
local newspaper of general circulation. EPA provided an opportunity for written and oral
comments from the public on the proposed plan for remedial action. A copy of the transcript of
the public meeting is available to the public as part of the administrative record upon which the
Regional Administrator based the selection of the response action.
H. In 1988 the surface soil/test pit assay conducted during the Remedial Investigation
("RI") identified the existence of polychlormated biphenyls ("PCBs") at levels of 800 mg/kg and
chromium at levels of 43,000 mg/kg at one location at the Site. Consequently, on October 26,
1989, EPA entered into an Administrative Order by Consent with Michigan Waste Systems, the
City of Grand Rapids, General Motors Corporation, Wickes Manufacturing Company and
Consumers Power Company to remove approximately 1100 tons of PCB contaminated soils and
material. The PCB contaminated soils were disposed of off-site in accordance with applicable
state and federal laws. The removal action was completed in June 1990.
I. The decision by E P A on the remedial action to be implemented at the Site is
embodied in a final Record of Decision ("ROD"), executed in September, 1992, which the State
had a reasonable opportunity to review and comment. Notice of the final plan was published in
accordance with Section 117(b) of C E R C L A , 42 U.S.C. § 9617.
J. Pursuant to an Administrative Order on Consent dated February 1993, the same
five PRPs who conducted the removal action also drafted the Remedial Design for the
implementation of the ROD remedy.
K. These same five PRPs also stockpiled cover material on the Site to be used in
constructing the cap required by the ROD.
Uni ted' States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 3
. IIIIII III iiuiiiiiiiiniw IIII 20140926-0080117
Mary HoUinrake P:20/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
L. On October 23, 1998, EPA issued an Explanation of Significant Differences
("ESD") to the ROD amending the Remedial Action ("RA") by incorporating State mixing zone-
based groundwater-surface water interface ("GSI") criteria as Alternate Concentrate Limits
("ACLs") for groundwater and providing for the construction of a soil cap in the Radio Tower
and Station Building Area ("RTSBA"). An amendment to the ESD was issued on December 23,
1998. Notice of the ESD has been published in local newspapers and has been made a part of the
administrative record.
M . Based on the information presently available to EPA, EPA believes that the. Work
will be properly and promptly conducted by the Settling Defendants if conducted in accordance
with the requirements of this Consent Decree and its appendices.
N . Solely for the purposes of Section 1130 of C E R C L A , the R A selected by the
ROD and the Work to be performed by the Settling Defendants shall constitute a response action
taken or ordered by the President.
0. • EPA issued Special Notice letters to 81 PRPs on January 20, 1998 and
April 16, 1998 requesting them to perform the R A .
P. As a result of extended negotiations, EPA has agreed to "carve out" a portion of
the Remedial Action amounting to a minimum of $2 million of activities that would otherwise be
part of the Work required to be undertaken by the Settling Work Defendants.
Q. EPA presently intends that the carve out activities will be performed by those
parties who received Special Notice Letters from EPA and are not participating in this Consent
Decree and that those parties will also reimburse EPA for Future Response Costs.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 4 -
IIIIIIIIIIII iiNiiiiiHiiiiNiiiini 20140926-0080117
Mary HoUinrake P:21/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
R.' The participating parties to the 1986 Consent Decree for the RI/FS and the 1990
A O C for the Design, have paid past response costs incurred by the United States through
December 1995.
S. The Parties recognize, and the Court by entering this Consent Decree finds, that this
Consent Decree has been negotiated by the Parties in good faith and implementation of this
Consent Decree will expedite the cleanup of the Site and will avoid prolonged and complicated
litigation between the Parties, and that this Consent Decree is fair, reasonable, and in the public
interest.
II. JURISDICTION
1. This Court has jurisdiction over the subject matter of this action pursuant to
28 U.S.C. §§ 1331 and 1345, and 42 U.S.C. §§ 9606, 9607, and 9613(b). This Court also has
personal jurisdiction over the Settling Defendants. Solely for the purposes of this Consent
Decree and the underlying complaint, Settling Defendants waive all objections and defenses that
they may have to jurisdiction of the Court or to venue in this District. Settling Defendants shall
not challenge the terms of this Consent Decree or this Court's jurisdiction to enter and enforce
this Consent Decree.
III. PARTIES BOUND
2. This Consent Decree applies to and is binding upon the United States and upon
Settling Defendants and their successors and assigns. Any change in ownership or corporate
status of a Settling Defendant including, but not limited to, any transfer of assets or real or
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 5 -
Illlllllllllllllllilfi 20140926-0080117
personal property, shall in no way alter such Settling Defendant's responsibilities under this
Consent Decree.
3. Settling Work Defendants shall'provide a copy of this Consent Decree to each
contractor hired to perform the Work required by this Consent Decree and to each person
representing any Settling Defendant with respect to the Site or the Work and shall condition all
contracts entered into hereunder upon performance of the Work in conformity with the terms of
this Consent Decree. Settling Work Defendants or their contractors shall provide written notice
ofthe Consent Decree to all subcontractors hired to perform any portion of the Work required by
this Consent Decree. Settling Work Defendants shall nonetheless be responsible for ensuring
that their contractors and subcontractors perform the Work contemplated herein in accordance
with this Consent Decree. With regard to the activities undertaken pursuant to this Consent
Decree, each contractor and subcontractor shall be deemed to be in a contractual relationship
with the Settling Work Defendants within the meaning of Section 107(b)(3) of C E R C L A , 42
U.S.C. § 9607(b)(3).
IV. DEFINITIONS
4. Unless otherwise expressly provided herein, terms used in this Consent Decree
which are defined in C E R C L A or in regulations promulgated under C E R C L A shall have the
meaning assigned to them in C E R C L A or in such regulations. Whenever terms listed below are
used in this Consent Decree or in the appendices attached hereto and incorporated hereunder, the
following definitions shall apply:
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE - 6 -
IIIIIIII 20140926-0080117
Mary HoUinrake P-.23/120 11'-5™? Kent Cnty MI Rgstr09/26/2014 SEAL
" C E R C L A " shall mean the Comprehensive Environmental Response, Compensation, and
Liability Act of 1980, as amended, 42 U.S.C. §§ 9601 et seq.
"Consent Decree" shall mean this Decree and all appendices attached hereto (listed in
Section XXIX) . In the event of conflict between this Decree and any appendix, this Decree shall
control.
"Day" shall mean a calendar day unless expressly stated to be a working day. "Working
day" shall mean a day other than a Saturday, Sunday, or Federal holiday. In computing any
period of time under this Consent Decree, where the last day would fall on a Saturday, Sunday,
or Federal holiday, the period shall run until the close of business of the next working day.
"EPA" shall mean the United States Environmental Protection Agency and any successor
departments or agencies of the United States.
"ESD" shall mean the Explanation of Significant Differences approved by and issued by
E P A on October 23, 1998, and as amended on December 23, 1998, allowing the implementation
in the Remedial Action ofthe State mixing zone-based GSI criteria as the A C L s for groundwater
and the construction of a soil cap over the 33-acre portion of the Site know as the Radio Tower
and Station Building Area (RTSB)T The ESD is attached as Appendix C.
"Future Response Costs" shall mean all costs, including, but not limited to, direct and
indirect costs, that the United States incurs in reviewing or'developing plans, reports and other
items pursuant to this Consent Decree, verifying the Work, or otherwise implementing,
overseeing, or enforcing this Consent Decree, including, but not limited to, payroll costs,
contractor costs, travel costs, laboratory costs, the costs incurred pursuant to Sections VII, IX
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 7
40926-0080117 0 Mary HoUinrake P:24/120 11-57QM Kent Cnty MI Rgstr09/26/2014SEAL
(including, but not limited to, the cost of attorney time and any monies paid to secure access
and/or to secure or implement institutional controls including, but not limited to, the amount of
just compensation), X V , and Paragraph 85 of Section X X I .
"Interest," shall mean interest at the rate specified for interest on investments of the
Hazardous Substance Superfund established under Subchapter A of Chapter 98 of Title 26 of the
U.S. Code, compounded on October 1 of each year, in accordance with 42 U.S.C. § 9607(a).
"Matters Addressed" in this settlement are all response actions taken or to be taken and all
response costs incurred'or to be incurred by the United States or any other person with respect to
the Site. The "matters addressed" in this settlement do not include those response costs or
response actions as to which the United States has reserved its rights under this Consent Decree
(except for claims for failure to comply with this Decree), in the event that the United States
asserts rights against Settling Defendants coming within the scope of such reservations.
"MDEQ" shall mean the Michigan Department of Environmental Quality and any
successor departments or agencies ofthe State.
"Municipal Sewage Sludge" shall mean any solid, semi-solid, or liquid residue removed
during the treatment of municipal waste water or domestic sewage, and may include residue
removed, all or in part, during the treatment of wastewater from manufacturing or processing
operations, provided that such residue has essentially the same characteristics as residue removed
during the treatment of domestic sewage.
"Municipal Solid Waste" shall mean household waste and solid waste collected from non
residential sources that is essentially the same as household waste. While the composition of
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 8
wiiiiniiiniiiiiiiiiiwiiiii 20140926-0080117
Mary HoUinrake P:25/120 11-.57P.M Kent Cnty MI Rgstr09/26/2014 SEftL
such wastes may vary considerably, municipal solid waste generally is composed of large
volumes of non-hazardous substances (e.g. yard waste, food waste, glass, and aluminum) and can
contain small amounts of other wastes as typically may be accepted in R C R A Subtitle D
landfills.
"National Contingency Plan" or "NCP" shall mean the National Oil and Hazardous
Substances Pollution Contingency Plan promulgated pursuant to Section 105 of C E R C L A ,
42 U.S.C. § 9605, codified at 40 C.F.R. Part 300, and any amendments thereto.
"Operation and Maintenance" or "O & M " shall mean all activities required to maintain
the effectiveness of the Remedial Action as required under the Operation and Maintenance Plan
approved or developed by EPA pursuant to this Consent Decree and the Statement of Work
(SOW).
"Paragraph" shall mean a portion of this Consent Decree identified by an Arabic numeral
or an upper case letter.
"Parties" shall mean the United States and the Settling Defendants.
"Performance Standards" shall mean the cleanup standards and other measures of
achievement of the goals of the Remedial Action, set forth in the "Selected Remedy" Section of
the ROD and Section II ofthe SOW.
"Plaintiff shall mean the United States.
"RCRA" shall mean the Solid Waste Disposal Act, as amended, 42 U.S.C.
§§ 6901 et seq. (also known as the Resource Conservation and Recovery Act).
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE 9 -
IIIIIIIIII IIIIIIIIII Hill 20140926-0080117
Mary HoUinrake P:26/120 11:57P,M Kent Cnty MI Rgstr0S726/2014 SEAL
"Record of Decision" or "ROD" shall mean the EPA Record of Decision relating to the
Butterworth Landfill Site signed in September of 1992, by the Regional Administrator, EPA
Region 5, or his/her delegate, as modified by the October 23, 1998 ESD (as amended on
December 23, 1998), and all attachments thereto. The ROD is attached as Appendices A and C.
"Remedial Action" or "RA" shall mean those activities, except for Operation and
Maintenance, to be undertaken by the Settling Defendants to implement the ROD, the SOW, and
the final Remedial Design and Remedial Action Workplan and other plans approved by EPA.
"Remedial Action Workplan" or "RA Work Plan" shall mean the document developed
pursuant to Paragraph 12 of this Consent Decree and approved by EPA, and any amendments
thereto.
"Remedial Design" shall mean, the Amended Remedial Design Project Plan ("ARDPP")
and any modifications made to the ARDPP in accordance with the ESD and this Consent Decree.
"Section" shall mean a portion of this Consent Decree identified by a Roman numeral.
"Settling Cash Defendants" shall mean those potentially responsible parties listed on
Appendix E.1.
"Settling Defendants" shall mean Settling Work Defendants, Settling Owner Defendants
and Settling Cash Defendants.
"Settling Owner Defendants" shall mean those Settling Defendants listed in
Appendix E.2.
"Settling Work Defendants" shall mean those Settling Defendants listed in Appendix E.3.
United States v. Allied Waste Systems, . et. a l .
Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 10 -
IIIIIIIIIIII IIIIIIIIII 111 llil 20140926-0080117
Mary HoUinrake P:27/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
"Site" shall mean the Butterworth #2 Landfill Superfund Site, encompassing
approximately 180 acres, and its approximate boundaries are the Grand River on the south,
Interstate 196 on the west, Butterworth Street on the north and a Consumers Power substation on
the east, in Grand Rapids, Michigan and depicted generally on the map attached as Appendix D.
"State" shall mean the State of Michigan.
"Statement of Work" or "SOW" shall mean the statement of work for implementation of
the Remedial Action, and Operation and Maintenance at the Site, as set forth in Appendix B to
this Consent Decree and any modifications made in accordance with this Consent Decree.
"Supervising Contractor" shall mean the principal contractor retained by the Settling
Defendants to supervise and direct the implementation ofthe Work under this Consent Decree,
"United States" shall mean the United States of America.
"Waste Material" shall mean (1) any "hazardous substance" under Section 101(14) of
CERCLA, 42 U.S.C. § 9601(14); (2) any pollutant or contaminant under Section 101(33), 42
U.S:C. § 9601(33); (3) any "solid waste" under Section 1004(27) of RCRA, 42 U.S.C.
§ 6903(27); and (4) any "hazardous substance" under Part 201, Section 101(l)(t) of Michigan
Act 451, MCL § 324.20101(l)(t).
"Work" shall mean all activities Settling Work Defendants are required to perform under
this Consent Decree, except those required by Section X X V (Retention of Records) and those
portions of the construction and O & M of the R A that EPA determines shall be performed by
non-settling PRPs in accordance with Paragraph 12.c. However, as set forth in Paragraph 6(c),
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 11
iiwi i i i f i l l l f 20140926-0080117
Marv HoUinrake P:28/120 1>:5JflM . Kent Cnty «I Rgstr 09/26/2014 SEAL
in the event this portion of the R A is not performed by the non-settling PRPs, E P A reserves the
right to require Settling Work Defendants to complete it. Should EPA require Settling Work
Defendants to perform this portion ofthe RA, Settling Work Defendants shall complete it as
Work they are required to perform under the Consent Decree.
V . GENERAL PROVISIONS
5. Objectives of the Parties
The objectives ofthe Parties in entering into this Consent Decree are to protect public
health, welfare and the environment at the Site by the design and implementation of response
actions at the Site by the Settling Defendants and to resolve the claims of Plaintiff against
Settling Defendants as provided in this Consent Decree.
6. Commitments by Settling Defendants
a. Settling Cash Defendants shall make payments to Settling Work
Defendants in accordance with Section X V I of this Consent Decree in contribution toward
Settling Work Defendants' performance of the Work, and are subject to those provisions and
requirements that reference Settling Cash Defendants, including Section X X V (Retention of
Records); Subparagraph 71.e of Section XX(Stipulated Penalties); Subparagraph 54.a of Section
X V I (Payment of Response Costs); and Section X X I (Covenant Not to Sue by Plaintiff).
b. Settling Work Defendants shall finance and perform the Work in
accordance with this Consent Decree, the ROD, the SOW, the Remedial Design and all work
plans and the standards, specifications, and schedules set forth therein or developed by Settling
Work Defendants and approved by EPA pursuant to this Consent Decree.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 12 -
I IIIIIII IIIIIIIIII I1IIHIII 20140926-8080117
Mary HoUinrake P:29/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
c. Settling Work Defendants wi l l hot be required to perform that portion of
the R A designated by the United States pursuant to Paragraph 12.c. unless non-settling PRPs fail
toperform the designated portion of the RA. In that event, EPA reserves the right to require
Settling Work Defendants to complete all such requirements. This provision shall not be subject
to Section XIX, "Dispute Resolution."
d. The obligations of Settling Work Defendants to finance and perform the
Work under this Consent Decree are joint and several. In the event of the insolvency or other
failure of any one or more Settling Work Defendants to implement the requirements of this
Consent Decree, the remaining Settling Work Defendants shall complete all such requirements.
7. Compliance With Applicable Law
AH activities undertaken by Settling Work Defendants pursuant to this Consent Decree
shall be performed in accordance with the requirements of all applicable federal and state laws
and regulations. Settling Work Defendants must also comply with all applicable or relevant and
appropriate requirements of all Federal and state environmental laws as set forth in the ROD,
SOW and Remedial Design. The activities conducted pursuant to this Consent Decree, i f
approved by EPA, shall be considered to be consistent with the NCP.
8. Permits
a. As provided in Section 121 (e) of C E R C L A and Section 300.400(e) ofthe
NCP, no permit shall be required for any portion of the Work conducted entirely on-site
(i.e.. within the areal extent of contamination or in very close proximity to the contamination and
necessary for implementation of the Work). Where any portion of the Work that is not on-site
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 13 -
: IIIIIIIIIIII l l l l l l l l l l l l l l l l l l l l l 20140926-0080117
Mary HoUinrake P:30/120 11;57P,M Kent Cnty MI Rgstr09/26/2014 SEAL
requires a federal or state permit or approval, Settling Work Defendants shall submit timely and
complete applications and take all other actions necessary to obtain all such permits or approvals.
b. The Settling Work Defendants may seek relief under the provisions of
Section XVIII (Force Majeure) of this Consent Decree for any delay in the performance of the
Work resulting from a failure to obtain, or a delay in obtaining, any permit required for the
Work.
c. This Consent Decree is not, and shall not be construed to be, a permit
issued pursuant to any federal or state statute or regulation.
9. Notice to Successors-in-Title.
a. With respect to any property owned or controlled by Settling Owner
Defendants that is located within the Site, within 30 days after the entry of this Consent Decree,
the Settling Owner Defendant shall submit to EPA for review and approval a notice to be filed
with the Kent County Register of Deeds, State of Michigan, which shall provide notice to all
successors-in-tifle that the property is part of the Site, that E P A selected a remedy for the Site in
September 1992, and that potentially responsible parties have entered into a Consent Decree
requiring implementation ofthe remedy. Such notice shall identify the United States District
Court in which the Consent Decree was filed, the name and civil action number of this case, and
the date the Consent Decree was entered by the Court. The Settling Owner Defendant shall
record the notice within 30 days of EPA's approval of the notice. The Settling Owner Defendant
shall provide EPA with a certified copy of the recorded notice within 30 days of recording such
notice.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 14
11IIII1 II11II III .IIIIII! 11 17 20140926-0080"
Mary HoUinrake P:31/120 11:57AM ' Kent Cnty I'll Rgstr 09/26/2014 SEftL
b. At least 30 days prior to the conveyance of any interest in property located
within the Site including, but not limited to, fee interests, leasehold interests, and mortgage
interests, the Settling Owner Defendant conveying the interest shall give the grantee written
notice of (i) this Consent Decree, (ii) any instrument by which an interest in real property has
been conveyed that confers a right of access to the Site (hereinafter referred to as "access
easements") pursuant to Section IX (Access and Institutional Controls), and (iii) any instrument
by which an interest in real property has been conveyed that confers a right to enforce restrictions
on the use of such property (hereinafter referred to as "restrictive easements") pursuant to Section
IX (Access and Institutional Controls). At least 30 days prior to such conveyance, the Settling
Owner Defendant conveying the interest shall also give written notice to E P A and the State of
the proposed conveyance, including the name and address of the grantee, and the date on which
notice of the Consent Decree, access easements, and/or restrictive easements was given to the
grantee.
c. In the event of any such conveyance, Settling Owner Defendant's
obligations under this Consent Decree, including, but not limited to, its obligation to provide or
secure access and institutional controls, as well as to abide by such institutional controls,
pursuant to Section IX (Access and Institutional Controls) of this Consent Decree, shall continue
to be met by the Settling Owner Defendant.. In no event shall the conveyance release or
otherwise affect the liability of the Settling Owner Defendant to comply with all provisions of
this Consent Decree, absent the prior written consent of EPA. If the United States approves, the
grantee may perform some or all of the Work under this Consent Decree.
United' SCates v. Allied Waste Systems, e t . a l . Butterworth. #2 Landfill Superfund Site
CONSENT DECREE - 15
llllINillllllllllllllll 20 40926-0080117
Mary Hollinrake P:32/120 11:57AM ' Kent Cnty MI Rgstr09/26/2014 SEAL
VI. PERFORMANCE OF THE W O R K B Y SETTLING WORK DEFENDANTS
10. Selection of Supervising Contractor.
a. A l l aspects of the Work to be performed by Settling Work Defendants
pursuant to Sections VI (Performance of the Work by Settling Work Defendants), VII (Remedy
Review), VIII (Quality Assurance, Sampling and Data Analysis), and X V (Emergency Response)
of this Consent Decree shall be under the direction and supervision of the Supervising
Contractor, the selection of which shall be subject to disapproval by EPA. Within 30 days after
the lodging of this Consent Decree, Settling Work Defendants shall notify EPA in writing of the
name, title, and qualifications of any contractor proposed to be the Supervising Contractor. EPA
will issue a notice of disapproval or an authorization to proceed. If at any time thereafter,
Settling Work Defendants propose to change a Supervising Contractor, Settling Work
Defendants shall give such notice to EPA and must obtain an authorization to proceed from EPA
before the new Supervising Contractor performs, directs, or supervises any Work under this
Consent Decree.
b. If EPA disapproves a proposed Supervising Contractor, EPA will notify
Settling Work Defendants in writing. Settling Work Defendants shall submit to E P A a list of
contractors, including the qualifications of each contractor, that would be acceptable to them
within 30 days of receipt of EPA's disapproval of the contractor previously proposed. EPA will
provide written notice of the names of any contractor(s) that it disapproves and an authorization
to proceed with respect to any ofthe other contractors. Settling Work Defendants may select any
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 16
IIIIIIIIII iiuiiiiiiiiiiiiwiiu mi 20140926-0080117
Mary HoUinrake P:33/120 11:57AM Kent Cnty MI^Rgstr09/26/2014SEflL
contractor from that list that is not disapproved and shall notify EPA of the name of the
contractor selected within 21 days of EPA's authorization to proceed.
c. If EPA fails to provide written notice of its authorization to proceed or
disapproval as provided in this Paragraph and this failure prevents the Settling Work Defendants
from meeting one or more deadlines in a plan approved by the EPA pursuant to this Consent
Decree, Settling Work Defendants may seek relief under the provisions of Section XVIII
(Force Majeure) hereof.
11. Remedial Design.
The Remedial Design for the remedy set forth in the ROD was completed pursuant to the
Remedial Design A O C and was approved by the E P A on February 3, 1998. In accordance with
the SOW, Settling Work Defendants are required to submit a draft ARDPP for approval by E P A
within 10 days of the lodging of the decree. Within 20 days ofthe receipt of EPA's comments
on the draft ARDPP, Settling Work Defendants shall issue a final ARDPP. The ARDPP is
incorporated into and is an enforceable part of this Consent Decree.
12. Remedial Action
a. Within 45 days of the date of lodging of this Consent Decree, Settling
Work Defendants shall submit to EPA a draft work plan for the performance of the Remedial
Action at the Site. The Remedial Action Work Plan shall provide for construction and
implementation ofthe remedy set forth in the ROD and achievement of the Performance
Standards, in accordance with this Consent Decree, the ROD, the SOW, the ARDPP, and the
design plans and specifications approved by EPA. . Upon its approval by EPA, the R A Work Plan
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 17 -
lllllllllllllllllllll 20140926-0080 17
Mary Hollirtraka P:34/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEfiU
shall be incorporated into and become enforceable under this Consent Decree. Within 20 days of
receipt of EPA comments on the draft RA Work Plan, Settling Work Defendants shall submit to
E P A a final R A Work Plan.
b. The Remedial Action Work Plan shall include the following:
(1) a description ofthe strategy for completing the construction activities, (2) a bar chart
schedule for completing the construction activities, (3) a description of the strategy for
implementing the operation, maintenance, and monitoring activities, (4) a schedule for
implementing the operation, maintenance, and monitoring activities, (5) the schedule for
deliverables and other project milestones, as contained in Section V of the SOW, (6)
identification of any substantive permit requirements needed to implement the remedial action
and the schedule for addressing these requirements, (7) preliminary identification of the R A
project team, (8) delineation of the area around the landfill in which water supply well
installation will be prohibited and (9) an A C L performance monitoring plan including, at a
minimum, (10) installation and sampling and analysis procedures for all new
groundwater/surface water interface (GSI) wells, including the 17 A C L well locations and the
two to five additional GSI wells south of the RTSB area, (11) installation and sampling and
analysis procedures for three leachate monitoring wells in the RTSB area, (12) a list of the
mixing zone based GSI criteria (i.e. the ACLs) that have been established for the Butterworth
Site by the State of Michigan, (13) a data evaluation plan to assess compliance with the A C L s
and to evaluate the adequacy of the soil cover over the RTSB area, (14) an operation and
maintenance plan for the groundwater and leachate monitoring wells, (15) a contingency
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - If
IIIIII lllllfllillf 20140926-0080117
response plan, as described above, to address exceedances of the ACLs , and (16) a corrective
action plan to mitigate exceedances of the ACLs .
c. Upon approval of the Remedial Action Work Plan by EPA and after an
opportunity for EPA to consult with the State, Settling Work Defendants shall implement the
activities required under the Remedial Action Work Plan except for the following portion of
Work to be undertaken by non-settling PRPs, which includes: the excavation, loading and
transport of rooting zone material required for the construction of the east side portion of the cap
to be performed in the year 2000 and O & M consisting of clay cover repair, rooting zone and
topsoil repair, mowing, reseeding, fertilizing, fence maintenance, erosion and sediment control,
landfill gas monitoring, and remedial action reporting to commence within one year of the
completion of construction ofthe cap and continue through the year 2029. The Settling Work
Defendants shall submit to E P A all plans, submittals, or other deliverables required under the
approved Remedial Action Work Plan in accordance with the approved schedule for review and
approval pursuant to Section X I (EPA Approval of Plans and Other Submissions). Unless
otherwise directed by EPA, Settling Work Defendants shall not commence physical Remedial
Action activities at the Site prior to approval of the Remedial Action Work Plan.
d. Settling Work Defendants shall continue to implement the Remedial
Action and O & M until the Performance Standards are achieved and for so long thereafter as is
otherwise required under this Consent Decree.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE - 19 -
IIIIII IIII IIIIIIIIIIIII IIIIIIIIII 20140926-0080117
Mary HoUinrake P.-3S/120 11:57AM ' Kent Cnty MI Rgstr09/26/2014 SEAL
13. Modification of the Remedial Design or Related Work Plans.
a. If EPA determines that modification to the work specified in the Remedial
Design and/or in work plans developed pursuant to the Remedial Design is necessary to achieve
and maintain the Performance Standards or to carry out and maintain the effectiveness of the
remedy set forth in the ROD, EPA may require that such modification be incorporated in the
Remedial Design and/or such work plans. Provided, however, that a modification may only be
required pursuant to this Paragraph to the extent that it is consistent with the scope of the remedy
selected in the ROD, as modified by the ESD.
b. For the purposes of this Paragraph 13 and Paragraphs 49,50, and 51 only,
the "scope of the remedy selected in the ROD" is: to prohibit the installation of water supply
wells within an area around the site to be defined at a later date in consultation with E P A and the
State of Michigan; to establish alternative concentration limits; to construct a new landfill cover,
including a clay capping layer, freeze-thaw layer, topsoil layer, revegetation, slope requirement
and flood protection; to remove and dispose of drums either concurrently exposed or uncovered
during activities conducted as part of the Remedial Action.
c. If Settling Work Defendants object to any modification determined by
EPA to be necessary pursuant to this Paragraph, they may seek dispute resolution pursuant to
Section XIX (Dispute Resolution), Paragraph 67 (record review). The ARDPP and/or related
work plans shall be modified in accordance with final resolution of the dispute.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 20 -
IIIIIIIIIIII IIIIIIIIIIII 20140926-0080117
Mary HoUinrake P:37/12Q 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
d. Settling Work Defendants shall implement any work required by any
modifications incorporated in the ARDPP and/or in work plans developed pursuant to the
ARDPP in accordance with this Paragraph.
e. Nothing in this Paragraph shall be construed to limit EPA's authority to
require performance of further response actions as otherwise provided in this Consent Decree.
14. Settling Work Defendants acknowledge and agree that nothing in this Consent
Decree, or the Remedial Design or Remedial Action documents constitutes a warranty or
representation of any kind by Plaintiff that compliance with the work requirements set forth in
those documents will achieve the Performance Standards.
15. Settling Work Defendants shall, prior to any off-Site shipment of Waste Material
from the Site to an out-of-state waste management facility, provide written notification to the
appropriate state environmental official in the receiving facility's state and to the E P A Project
Coordinator of such shipment of Waste Material. However, this notification requirement shall
not apply to any off-Site shipments when the total volume of all such shipments will not exceed
10 cubic yards,
a. The Settling Work Defendants shall include in the written notification the
following information, where available: (1) the name and location of the facility to which the
Waste Material are to be shipped; (2) the type and quantity of the Waste Material to be shipped;
(3) the expected.schedule for the shipment of the Waste Material; and (4) the method of
transportation. The Settling Work Defendants shall notify the state in which the planned
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 21
20140926-0080117
receiving facility is located of major changes in the shipment plan, such as a decision to ship the
Waste Material to another facility within the same state, or to a facility in another state.
b. The identity of the receiving facility and state will be determined by the
Settling Work Defendants following the award of the contract for Remedial Action construction.
The Settling Work Defendants shall provide the information required by Paragraph 15.a as soon
as practicable after the award of the contract and before the Waste Material is actually shipped.
VII. R E M E D Y REVIEW •
16. Periodic Review. Settling Work Defendants shall conduct any studies and
investigations as requested by EPA, in order to permit E P A to conduct reviews of whether the
Remedial Action is protective of human health and the environment at least every five years as
required by Section 121(c) of C E R C L A and any applicable regulations.
17. EPA Selection of Further Response Actions. If E P A determines, at any time, that
the Remedial Action is not protective of human health and the environment, EPA may select
further response actions for the Site in accordance with the requirements of C E R C L A and the
NCP.
18. Opportunity To Comment. Settling Work Defendants and, i f required by Sections
113(k)(2) or 117 of C E R C L A , the public, will be provided with an opportunity to comment on
any further response actions proposed by EPA as a result of the review conducted pursuant to
Section 121(c) of C E R C L A and to submit written comments for the record during the comment
period.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE - 2 2
IIIIIIII II, 11 I'll'llil 1111 III JT 20140926-0080117
Mary HoUinrake P:39/120 11:57AM Kent Cnty MI Rgstr 09/26/2014_SEfll_
19. Settling Work Defendants' Obligation To Perform" Further Response Actions. If
E P A selects further response actions for the Site, the Settling Work Defendants shall undertake
such further response actions to the extent that the reopener conditions in Paragraph 81 or
Paragraph 82 (United States' reservations of liability based on unknown conditions or new
information) are satisfied. Settling Work Defendants may invoke the procedures set forth in
Section X I X (Dispute Resolution) to dispute (1) EPA's determination that the reopener
conditions of Paragraph 81 or Paragraph 82 of Section X X I (Covenants Not To Sue by Plaintiff)
are satisfied,-(2) EPA's determination that the Remedial Action is not protective of human health
and the environment, or (3) EPA's selection of the further response actions. Disputes pertaining
to whether the Remedial Action is protective or to EPA's selection of further response actions
shall be resolved pursuant to Paragraph 67 (record review).
20. Submissions of Plans. If Settling Work Defendants are required to perform the
further response actions pursuant to Paragraph 19, they shall submit a plan for such work to E P A
for approval in accordance with the procedures set forth in Section VI (Performance of the Work
by Settling Work Defendants) and shall implement the plan approved by EPA in accordance with
the provisions of this Decree.
VIII. QUALITY A S S U R A N C E . SAMPLING, and D A T A A N A L Y S I S
21. Settling Work Defendants shall use quality assurance, quality control, and chain .
of custody procedures for all treatability, design, compliance and monitoring samples in
accordance with "EPA Requirements for Quality Assurance Project Plans for Environmental
Data Operation," (EPA QA/R5; "Preparing Perfect Project Plans," (EPA/600/9-88/087), and
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 23 -
i i i i i in i; iiiiiii.ii ii iiiii 20140926-0080117
Mary HoUinrake P:40/120 11:57AM Kent Cnty M£ Rgstr09/26/2014 SEflL
subsequent amendments to such guidelines upon notification by EPA to Settling Work
Defendants of such amendment. Amended guidelines shall apply only to procedures conducted
after such notification. Prior to the commencement of any monitoring project under this Consent
Decree, Settling Work Defendants shall submit to EPA for approval, after consultation with the.
State, a Quality Assurance Project Plan ("QAPP") that is consistent with the SOW, the NCP and
applicable guidance documents. If relevant to the proceeding, the Parties agree that validated
sampling data generated in accordance with the QAPP(s) and reviewed and approved by EPA
shall be admissible as evidence, without objection, in any proceeding under this Decree. Settling
Work Defendants shall ensure that EPA personnel and its authorized representatives are allowed
access at reasonable times to all laboratories utilized by Settling Work Defendants in
implementing this Consent Decree. In addition, Settling Work Defendants shall ensure that such
laboratories shall analyze all samples submitted by EPA pursuant to the QAPP for quality
assurance monitoring. Settling Work Defendants shall ensure that the laboratories they utilize
for the analysis of samples taken pursuant to this Decree perform all analyses according to
accepted EPA methods. Accepted EPA methods consist of those methods which are documented
in the "Contract Lab Program Statement of Work for Inorganic Analysis" and the "Contract Lab
Program Statement of Work for Organic Analysis," dated February 1988, and any amendments
made thereto during the course ofthe implementation of this Decree. Settling Work Defendants
shall ensure that all laboratories they use for analysis of samples taken pursuant to this Consent
Decree participate in an EPA or EPA-equivalent QA/QC program. Settling Work Defendants
shall ensure that all field methodologies utilized in collecting samples for subsequent analysis
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 24
UIIIIIII IIIIIIII IIIIIIIIIIII 20140926-0080117
' Mary HoUinrake P:41/120 11:57P,M Kent Cnty MI Rgstr09/26/2014 SEAL
pursuant to this Decree will be conducted in accordance with the procedures set forth in the
QAPP approved by EPA.
22. Upon request, the Settling Work Defendants shall allow split or duplicate samples
to be taken by EPA or its authorized representatives. Settling Work Defendants shall notify EPA
not less than 14 days in advance of any sample collection activity unless shorter notice is agreed
to by EPA. In addition, EPA shall have the right to take any additional samples that EPA deems
necessary. Upon request, EPA shall allow the Settling Work Defendants to take split or
duplicate samples of any samples EPA takes as part of its oversight of the Settling Work
Defendants' implementation of the Work.
23. Settling Work Defendants shall submit to EPA 3 copies of the results of all
sampling and/or tests or' other data obtained or generated by or on behalf of Settling Work
Defendants with respect to the Site and/or the implementation of this Consent Decree unless
E P A agrees otherwise.
24. Notwithstanding any provision of this Consent Decree, the United States hereby
retains all of its information gathering and inspection authorities and rights, including
enforcement actions related thereto, under C E R C L A , R C R A and any other applicable statutes or
regulations.
IX. ACCESS A N D INSTITUTIONAL CONTROLS
25. If the Site, or any other property where access and/or land/water use restrictions
are needed to implement this Consent Decree, is owned or controlled by any of the Settling
Defendants, such Settling Defendants shall:
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE , - 2 5
II1IIIIII1IIIIIIIII1IIIIII1IIIIIIIU11II1 20 4 0926-0080 17
Mary Hollinrake P:42/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
a. commencing on the date of lodging of this Consent Decree, provide the
United States and its representatives, including EPA and its contractors, with access at all
reasonable times to the Site, or such other property, for the purpose of conducting any activity
related to this Consent Decree including, but not limited to, the following activities:
i . Monitoring the Work;
i i . Verifying any data or information submitted to the United
States;
ii i . Conducting investigations relating to contamination at or
near the Site;
iv. Obtaining samples;
v. Assessing the need for, planning, or implementing
additional response actions at or near the Site;
vi. Implementing the Work pursuant to the conditions set forth
in this Consent Decree;
vi i . Inspecting and copying records, operating logs, contracts, or other
documents maintained or generated by Settling Work Defendants
or their agents, consistent with Section X X I V (Access to
Information);
v i i i . Assessing Settling Work Defendants' compliance with this Consent
Decree; and
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 26
fflllllllllllllllllllllllll 20140926-0080117
Mary HoUinrake P-.43/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
IX. Determining whether the Site or other property is being used in a
manner that is prohibited or restricted, or that may need to be
prohibited or restricted, by of pursuant to this Consent Decree;
b. commencing on the date of lodging of this Consent Decree, refrain from
using the Site, or such other property, in any manner that would interfere with or adversely affect
the integrity or protectiveness of the remedial measures to be implemented pursuant to this
Consent Decree. Such restrictions include, but are not limited to, no consumptive or other use of
the groundwater underlying the property and no installation, construction, removal or use of any
buildings, wells, pipes, roads ditches or any other structures at the property except as approved
by EPA in accordance with the Consent Decree and the ROD; and
Michigan, an easement, running with the land, that (1) grants a right of access for the purpose of
conducting any activity related to this Consent Decree including, but not limited to, those
activities listed in Paragraph 25.a of this Consent Decree, and (2) grants the right to enforce the
land/water use restrictions listed in Paragraph 25.b of this Consent Decree, or other restrictions
that EPA determines are necessary to implement, ensure non-interference with, or ensure the
protectiveness of the remedial measures to be performed pursuant to this Consent Decree. Such
Settling Defendants shall grant the access rights and the rights to enforce the land/water use
restrictions to (1) the United States, on behalf of EPA, and its representatives, (2) the State and
its representatives, (3) the other Settling Defendants and their representatives, and/or (4) other
c. execute and record in the Register of Deeds Office for Kent County,
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 27
niiiiniiiiiiiiiiiniiiiiiiiiniiniiiimi 20" 40926-0080117
. Mary HoUinrake P:44/120 11:57011 • Kent Cnty MI Rgstr 09/26/2014 SEfiL
appropriate grantees identified by EPA. Such Settling Defendants shall, within 45 days of entry
of this Consent Decree, submit to EPA for review and approval with respect to such property:
i. a draft easement that is enforceable under the laws of the State of Michigan, free
and clear of all prior liens and encumbrances (except as approved by EPA), and
acceptable under the Attorney General's Title Regulations promulgated pursuant
to 40 U.S.C. Section 255; and
ii. a current title commitment or report prepared in accordance with the U.S.
Department of Justice Standards for the Preparation of Title Evidence in Land
Acquisitions by the United States (1970) (the "Standards").
Within 15 days of EPA's approval and acceptance of the easement, such Settling Defendants .
shall update the title search and, i f it is determined that nothing has occurred since the effective
date of the commitment or report to affect the title adversely, record the easement with the
Register of Deeds Office for Kent County, Michigan. Within 30 days of recording the easement,
such Settling Defendants shall provide EPA with final title evidence acceptable under the
Standards, and a certified copy of the original recorded easement showing the clerk's recording
stamps.
26. If the Site, or any other property where access and/or land/water use
restrictions are needed to implement this Consent Decree, is owned or controlled by persons
other than any of the Settling Defendants, Settling Work Defendants shall use best efforts to
secure from such persons:
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 2 8
a. agreement to provide access thereto for Settling Work Defendants, as
well as for the United States on behalf of EPA, and the State, as well as their representatives
(including contractors), for the purpose'of conducting any activity related to this Consent Decree
including, but not limited to, those activities listed in Paragraph 25(a) of this Consent Decree;
United States, to abide by the obligations and restrictions established by Paragraph 25(b) of this
Consent Decree, or that are otherwise necessary to implement, ensure non-interference with, or
ensure the protectiveness of the remedial measures to be performed pursuant to this Consent
Decree; and
County, Michigan, of an easement, running with the land, that (1) grants a right of access for the
purpose of conducting any activity related to this Consent Decree including, but not limited to,
those activities listed in Paragraph 25.a of this Consent Decree, and (2) grants the right to enforce
the land/water use restrictions listed in Paragraph 25.b of this Consent Decree, or other
restrictions that EPA determines are necessary to implement, ensure non-interference with, or
ensure the protectiveness of the remedial measures to be performed pursuant to this Consent
Decree. The access rights and/or rights to enforce land/water use restrictions shall be granted to
(1) the United States, on behalf of EPA, and its representatives, (2) the State and its
representatives, (3) the Settling Work Defendants and their representatives, and/or (4) other
appropriate grantees identified by EPA. If EPA so requests, within 45 days after notice of such a
b. an agreement, enforceable by the Settling Work Defendants and the
c. the execution and recordation in the Register of Deeds Office for Kent
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE - 29 -
i 20140926-0080117
request, Settling Work Defendants shall submit to EPA for review and approval with respect to
such property:
i . a draft easement that is enforceable under the laws of the State of
Michigan, free and clear of all prior liens and encumbrances (except as approved by
EPA), and acceptable under the Attorney General's Title Regulations promulgated
pursuant to 40 U.S.C. Section 255; and
i i . a current title commitment or report prepared in accordance with
the U.S. Department of Justice Standards for the Preparation of Title Evidence in Land.
Acquisitions by the United States" (1970) (the "Standards").
Within 15 days of EPA's approval and acceptance of the easement, Settling Work Defendants
shall update the title search and, i f it is determined that nothing has occurred since the effective
date of the commitment or report to affect the title adversely, the easement shall be recorded with
the Register of Deeds Office for Kent County, Michigan. Within 30 days ofthe recording of the
easement, Settling Work Defendants shall provide EPA with final title evidence acceptable under
the Standards, and a certified copy of the original recorded easement showing the clerk's
recording stamps.
27. If any access or land/water use restriction agreements required by
Paragraphs 26.a or 26.b of this Consent Decree are not obtained within 45 days of the date of
entry of this Consent Decree, or any access easements or restrictive easements required by
Paragraph 26.c of this Consent Decree are not submitted to EPA in draft form within 45 days of a
request by EPA, Settling Work Defendants shall promptly notify the United States in writing, and
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE - 3 0
: IIIIIIIIII IIIIIIIIIIII IllillllIIJII i 20140926-0080117 : Mary HoUinrake P:47/120 11 :57flH
Kent Cnty MI Rgstr09/26/2014 SEflL
shall include in that notification a summary of the steps that Settling Work Defendants have
taken to attempt to comply with Paragraph 26 of this Consent Decree. The United States may, as
it deems appropriate, assist Settling Work Defendants in obtaining access or land/water use
restrictions, either in the form of contractual agreements or in the form of easements running
with the land.
28. If EPA determines that land/water use restrictions in the form of state or local
laws, regulations, ordinances or other governmental controls are needed to implement the remedy
selected i n the ROD, as modified by the ESD, ensure the integrity and protectiveness thereof, or
ensure non-interference therewith, Settling Defendants shall cooperate with EPA's and the State's
efforts to secure such governmental controls.
29. Notwithstanding any provision of this Consent Decree, the United States and the
State retain all of their access authorities and rights, as well as all of their rights to require
land/water use restrictions, including enforcement authorities related thereto, under C E R C L A ,
R C R A and any other applicable statute or regulations.
X . REPORTING REQUIREMENTS
30. In addition to any other requirement of this Consent Decree, Settling Work
Defendants shall submit to E P A 3 copies of written monthly progress reports that: (a) describe
the actions which have been taken toward achieving compliance with this Consent Decree during
the previous month; (b) include a summary of all results of sampling and tests and all other data
received or generated by Settling Work Defendants or their contractors or agents in the previous
month; (c) identify all work plans, plans and other deliverables required by this Consent Decree
Dnited States v. Allied Waste. Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 31
||I|IIIIIWIIIIIIIIIIIII 40926-0080117 Mary HoUinrake P:48/120 11-57QM
K e n i C n t y MI Rgstr 09/26/2014SEflL
20-ary Ho 2nt Cn
completed and submitted during the previous month; (d) describe all actions, including, but not
limited to, data collection and implementation of work plans, which are scheduled for the next
month and provide other information relating to the progress of construction, including, but not
limited to, critical path diagrams, Gantt charts and Pert charts; (e) include information regarding
percentage of completion, unresolved delays encountered or anticipated that may affect the future
schedule for implementation of the Work, and a description of efforts made to mitigate those
delays or anticipated delays; (f) include any modifications to the work plans or other schedules
that Settling Work Defendants have proposed to EPA or that have been approved by EPA; and
(g) describe all activities undertaken in support of the Community Relations Plan during the
previous month and those to be undertaken in the next month. Settling Work Defendants shall
submit these progress reports to EPA by the tenth day of every month following the lodging of
this Consent Decree until EPA notifies the Settling Work Defendants pursuant to Paragraph 49.c
of Section XIV (Certification of Completion). If requested by EPA, Settling Work Defendants
shall also provide briefings for E P A to discuss the progress of the Work.
31. The Settling Work Defendants shall notify EPA of any change in the schedule
described in the monthly progress report for the performance of any activity, including, but not
limited to, data collection and implementation of work plans, no later than seven days prior to the
performance of the activity.
32. Upon the occurrence of any event during performance of the Work that Settling
Work Defendants are required to report pursuant to Section 103 of C E R C L A or Section 304 of
the Emergency Planning and Community Right-to-know Act (EPCRA), Settling Work
United States v. The City of Grand Rapids, Michigan, et al. Butterworth #2 Landfill Superfund Site CONSENT DECREE - 32 -
20 40926-00801 III
17 Mary HoUinrake P:49/120 11:57AM Kent Cnty MI Rgstr 09/26/2014 SEAL
Defendants shall within 24 hours of the onset or sucn event orally notify the EPA Project
Coordinator or the Alternate EPA Project Coordinator (in the event of the unavailability of the
EPA Project Coordinator), or, in the event that neither the EPA Project Coordinator or Alternate
EPA Project Coordinator is available, the Emergency Response Section, Region 5, United States
Environmental Protection Agency. These reporting requirements are in addition to the reporting
required by C E R C L A Section 103 or EPCRA Section 304..
33. Within 20 days of the onset of such an event, Settling Work Defendants shall
furnish to Plaintiff a written report, signed by the Settling Work Defendants' Project Coordinator,
setting forth the events which occurred and the measures taken, and to be taken, in response
thereto. Within 30 days of the conclusion of such an event, Settling Work Defendants shall
submit a report setting forth all actions taken in response thereto.
34. Settling Work Defendants shall submit 3 copies of all plans, reports, and data
required by the ARDPP or any other approved plans to EPA in accordance with the Remedial
Action Workplan. Settling Work Defendants shall simultaneously submit 3 copies of all such
plans, reports and data to the State.
35. A l l reports and other documents submitted by Settling Work Defendants to E P A
(other than the monthly progress reports referred to above) which purport to document Settling
Work Defendants' compliance with the terms of this Consent Decree shall be signed by an
authorized representative of the Settling Work Defendants.
United'States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site-
CONSENT DECREE - 33 -
IIIIIIIIIIII IIIIIIIIII IIII 20140926-0080117
' Mary HoUinrake P:50/120 11:57ftM Kent Cnty MI Rgstr09/26/2014 SEftL
XI. EPA A P P R O V A L OF PLANS A N D OTHER SUBMISSIONS
36. After review of any plan, report or other item which is required to be submitted
for approval pursuant to this Consent Decree, EPA, after consultation with the State, shall: (a)
approve, in whole or in part, the submission; (b) approve the submission upon specified
conditions; (c) modify the submission to cure the deficiencies; (d) disapprove, in whole or in
part, the submission, directing that the Settling Work Defendants modify the submission; or (e)
any combination of the above. However, EPA shall not modify a submission without first
providing Settling Work Defendants at least one notice of deficiency and an opportunity to cure
within 30 days, except where to do so would cause serious disruption to the Work or where
previous submission(s) have been disapproved due to material defects and the deficiencies in the
submission under consideration indicate a bad faith lack of effort to submit an acceptable
deliverable.
37. In the event of approval, approval upon conditions, or modification by EPA,
pursuant to Paragraph 36(a), (b), or (c), Settling Work Defendants shall proceed to take any
action required by the plan, report, or other item, as approved or modified by EPA subject only to
their right to invoke the Dispute Resolution procedures set forth in Section X I X (Dispute
Resolution) with respect to the modifications or conditions made by EPA. In the event that EPA
modifies the submission to cure the deficiencies pursuant to Paragraph 36(c) and the submission
has a material defect, EPA retains its right to seek stipulated penalties, as provided in Section X X
(Stipulated Penalties).
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 3 4
Illlllllllllllllllllllllll' 20140926-0080 17
- a T T . . r , Mary HoUinrake P:51/120 11:57flM o ^ i -
38. a. Upon receipt oi a noVKent cnty mi Rgstr09/26/20i4 SEftL ragraph 36(d), Settling
Work Defendants shall, within 30 days or such longer time as specified by EPA in such notice,
correct the deficiencies and resubmit the plan, report, or other item for approval. Any stipulated
penalties applicable to the submission, as provided in Section X X (Stipulated Penalties), shall
accrue during the 30-day period or otherwise specified period but shall not be payable unless the
resubmission is disapproved or modified due to a material defect as provided in Paragraphs 36
and 37.
b. Notwithstanding the receipt of a notice of disapproval pursuant to Paragraph
36(d), Settling Work Defendants shall proceed, at the direction of EPA, to take any action
required by any non-deficient portion ofthe submission. Implementation of any non-deficient
portion of a submission shall not relieve Settling Work Defendants of any liability for stipulated
penalties under Section X X (Stipulated Penalties).
39. In the event that a resubmitted plan, report or other item, or portion thereof, is
disapproved by EPA, EPA may again require the Settling Work Defendants to correct the
deficiencies, in accordance with the preceding Paragraphs. EPA also retains the right to modify
or develop the plan, report or other item. Settling Work Defendants shall implement any such
plan, report, or item as modified or developed by EPA, subject only to their right to invoke the
procedures set forth in Section X I X (Dispute Resolution).
40. If upon resubmission, a plan, report, or item is disapproved or modified by E P A
due to a material defect, Settling Work Defendants shall be deemed to have failed to submit such
plan, report, or item timely and adequately unless the Settling Work Defendants invoke the
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 3 5
l u i i i i i u i i i i i i n i i i i n i i i i 20' 40926-0080117
Marv HoUinrake P:52/120 11:57flM Kent Cnty MI Rgstr09/26/2314 SEAL
dispute resolution procedures set form in "section X f X (Dispute Resolution) and EPA's action is
overturned pursuant to that Section. The provisions of Section X I X (Dispute Resolution) and
Section X X (Stipulated Penalties) shall govern the implementation of the Work and accrual and
payment of any stipulated penalties during Dispute Resolution. If EPA's disapproval or
modification is upheld, stipulated penalties shall accrue for such violation from the date on which
the initial submission was originally required, as provided in Section X X (Stipulated Penalties).
41. A l l plans, reports, and other items required to be submitted to EPA under this
Consent Decree shall, upon approval or modification by EPA, be enforceable under this Consent
Decree. In the event EPA approves or modifies a portion of a plan, report, or other item required
to be submitted to EPA under this Consent Decree, the approved or modified portion shall be
enforceable under this Consent Decree.
XII. PROJECT COORDINATORS
42. Within 20 days of lodging this Consent Decree, Settling Work Defendants and
E P A wil l notify each other, in writing, of the name, address and telephone number of their
respective designated Project Coordinators and Alternate Project Coordinators. If a Project
Coordinator or Alternate Project Coordinator initially designated is changed, the identity of the
successor will be given to the other Parties at least 5 working days before the changes occur,
unless impracticable, but in no event later than the actual day the change is made. The Settling
Work Defendants' Project Coordinator shall be subject to disapproval by EPA and shall have the
technical expertise sufficient to adequately oversee all aspects of the Work. The Settling Work
Defendants' Project Coordinator shall not be an attorney for any of the Settling Work Defendants
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE 36 -
Illllillllllllllllllllllllllllllllllllllllll 201 40926-0080117
Mary HoUinrake P:53/120 11:57AM
in this matter. He or she may ass ign K 4?iJ^LL™Jsi i^ other contractors, to serve
as a Site representative for oversight of performance of daily operations during remedial
activities.
43. Plaintiff may designate other representatives, including, but not limited to, EPA
employees, and federal contractors and consultants, to observe and monitor the progress of any
activity undertaken pursuant to this Consent Decree. EPA's Project Coordinator and Alternate
Project Coordinator shall have the authority lawfully vested in a Remedial Project Manager
(RPM) and an On-Scene Coordinator (OSC) by the National Contingency Plan, 40 C.F.R. Part
300. In addition, EPA's Project Coordinator or Alternate Project Coordinator shall have
authority, consistent with the National Contingency Plan, to halt any Work required by this
Consent Decree and to take any necessary response action when s/he determines that conditions
at the Site constitute an emergency situation or may present an immediate threat to public health
or welfare or the environment due to release or threatened release of Waste Material.
44. EPA's Project Coordinator and the Settling Work Defendants' Project Coordinator
wil l meet, at a minimum, on a quarterly basis, unless a different frequency is mutually agreed to.
XIII. A S S U R A N C E OF ABILITY TO COMPLETE W O R K
45. Within 30 days of entry of this Consent Decree, Settling Work Defendants shall
establish and maintain financial security in the amount of $15,230,000 in one or more of the
following forms:
(a) A surety bond guaranteeing performance of the Work;
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 3 7
(b) One or more irrevocable letters of credit equaling the total
estimated cost of the Work; |N||1UU|I||I|IM|IIIIIII (c) v J ' Kent Cnty MI Rgstr 09/26/2014 SEAL
(d) A guarantee to perform the Work by one or more
parent corporations or subsidiaries, or by one or
more unrelated corporations that have a substantial
business relationship with at least one of the
Settling Work Defendants;
(e) A demonstration that one or more of the Settling
Work Defendants satisfy the requirements of
40C.F.R. Part 264.143(f).
46. If the Settling Work Defendants seek to demonstrate the ability to complete the
Work through a guarantee by a third party pursuant to Paragraph 45(d) of this Consent Decree,
Settling Work Defendants shall demonstrate that the guarantor satisfies the requirements of
40 C.F.R. Part 264.143(f). If Settling Work Defendants seek to demonstrate their ability to
complete the Work by means of the financial test or the corporate guarantee pursuant to
Paragraph 45(d) or (e), they shall resubmit sworn statements conveying the information required
by 40 C.F.R. Part 264.143(f) annually, on the anniversary of the effective date of this Consent
Decree. In the event that EPA, after consultation with the State, determines at any time that the
financial assurances provided pursuant to this Section are inadequate, Settling Work Defendants
shall, within 30 days of receipt of notice of EPA's determination, obtain and present to EPA for
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 38
IIIIIIII IIIIIIIIII IIBIffllllllUII approval one ofthe other forms
2 0 1 40926-00801 17 'aragraph 45 of this Consent r y Mary HoUinrake P:55/120 11:57AM ° r
Kent Cnty MI Rgstr09/26/2014 SEAL
Decree. Settling Work Defendants' inability to demonstrate financial ability to complete the
Work shall not excuse performance of any activities required under this Consent Decree.
47. If Settling Work Defendants can show that the estimated cost to complete the
remaining Work has diminished below the amount set forth in Paragraph 45 above after entry of
this Consent Decree, Settling Work Defendants may, on any anniversary date of entry , of this
Consent Decree, or at any other time agreed to by the Parties, reduce the amount of the financial
security provided under this Section to the estimated cost of the remaining work to be performed.
Settling Work Defendants shall submit a proposal for such reduction to EPA, in accordance with
the requirements of this Section, and may reduce the amount of the security upon approval by
E P A . In the event of a dispute, Settling Work Defendants may reduce the amount of the security
in accordance with the final administrative or judicial decision resolving the dispute.
48. Settling Work Defendants may change the form of financial assurance provided
under this Section at any time, upon notice to and approval by EPA, provided that the new form
of assurance meets the requirements of this Section. In the event of a dispute, Settling Work
Defendants may change the form of the financial assurance only in accordance with the final
administrative or judicial decision resolving the dispute.
XIV. CERTIFICATION OF COMPLETION
49. Completion of Construction.
a. Within 15 days after Settling Work Defendants conclude construction of
the Remedial Action as set forth in the SOW, Settling Work Defendants shall schedule and
United' States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 3 9 -
: win i mm \ni 111 mui i i c . 20140926-0080117
conduct a pre-final, pre-certificatit H oi i inrake p : 5 6 / i 2 © 11 -.57P.M ;ttling Work Defendants and Kent Cnty MI Rgstr09/26/2014 SEAL
EPA. Within 15 days after completion of the pre-final, pre-certification inspection, the Settling
Work Defendants shall submit a written report of the inspection, including a schedule for
completing any items identified during the pre-final, pre-certification inspection. Within 15 days
after completion of the work items identified in the pre-final, pre-certification inspection report,
the Settling Work Defendants shall schedule and conduct a final pre-certification inspection to be
attended by Settling Work Defendants and EPA. Within 15 days after completion of the final
pre-certification inspection, the Settling Work Defendants shall submit a written report ofthe
inspection, including a schedule for completing any items identified during the final
pre-certification inspection. If, after the final pre-certification inspection, the Settling Work
Defendants still believe that construction has been fully performed, they shall submit a written
Completion of Construction report requesting certification to EPA for approval, with a copy to
the State, pursuant to Section XI (EPA Approval of Plans and Other Submissions) within 60 days
of the final inspection. In the report, a registered professional engineer and the Settling Work
Defendants' Project Coordinator shall state that construction has been completed in full
satisfaction of the requirements of this Consent Decree. The written report shall include as-built
drawings signed and stamped by a professional engineer, and, as needed, an addendum to the
O & M Plan. The report shall contain the following statement, signed by a responsible corporate
official of a Settling Work Defendant or the Settling Work Defendants' Project Coordinator:
' To the best of my knowledge, after thorough investigation, I certify that the information contained in or accompanying this submission is true, accurate and complete. I am aware that there are significant penalties for submitting false
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 40
. . , . , • Kent Cnty MI Rgstr09/26/2014 5ERL
lnformation, including the possioinxy orTineano: imprisonment
violations.
b. If, after receipt and review of the written Completion of Construction Report,
EPA, after consultation with the State, determines that construction or any portion thereof has
not been completed in accordance with this Consent Decree, EPA will notify Settling Work
Defendants in writing of the activities that must be undertaken by Settling Work Defendants
pursuant to this Consent Decree to complete construction. Provided, however, that EPA may
only require Settling Work Defendants to perform such activities pursuant to this Paragraph to
the extent that such activities are consistent with the "scope of the remedy selected in the ROD"
as that term is defined in Paragraph 13.b. EPA will set forth in the notice a schedule for
performance of such activities consistent with the Consent Decree and the SOW or require the
Settling Work Defendants to submit a schedule to EPA for approval pursuant to Section X I (EPA
Approval of Plans and Other Submissions). Settling Work Defendants shall perform all
activities described in the notice in accordance with the specifications and schedules established
pursuant to this Paragraph, subject to their right to invoke the dispute resolution procedures set
forth in Section X I X (Dispute Resolution).
c. If EPA concludes, based on the initial or any subsequent report requesting
Certification of Completion of Construction and after consultation with the State, that
Construction has been performed in accordance with this Consent Decree, EPA will so certify in
writing to Settling Work Defendants. This certification shall constitute the Completion of
Construction for purposes of this Consent Decree, including, but not limited to, Section X X I
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 41 -
niiiiiiiiiiiiiiiiiuiiiwiiiiiiiii 20140926-0080117
Mary HoUinrake P:58/120 11:57AM Kent Cnty MI Rgstr09/26^2014 SEftL
(Covenants Not to Sue by Plaintiff). Certification of Completion of Construction shall not affect
Settling Work Defendants' other obligations under this Consent Decree.
50. Completion of the Remedial Action
a. Within 90 days after Settling Work Defendants conclude that the
Remedial Action has been fully performed and the Performance Standards have been attained,
Settling Work Defendants shall schedule and conduct a pre-certification inspection to be attended
by Settling Work Defendants and EPA. If, after the pre-certification inspection, the Settling
Work Defendants still believe that the Remedial Action has been fully performed and the
Performance Standards have been attained, they shall submit a written report requesting
certification to EPA for approval, with a copy to the State, pursuant to Section X I (EPA
Approval of Plans and Other Submissions) within 45 days of the inspection. In the report, a
registered professional engineer and the Settling Work Defendants' Project Coordinator shall
state that the Remedial Action has been completed in full satisfaction of the requirements of this
Consent Decree. The report shall contain the following statement, signed by a responsible
corporate official of a Settling Defendant or the Settling Defendants' Project Coordinator:
To the best of my knowledge, after thorough investigation, I certify that the information contained in or accompanying this submission is true, accurate and complete. I am aware that there are significant penalties for submitting false information, including the possibility of fine and imprisonment for knowing violations.
If, after completion of the pre-certification inspection and receipt and review of the
written report, EPA, after consultation with the State, determines that the Remedial Action or any
portion thereof has not been completed in accordance with this Consent Decree or that the
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 4 2
IIIII IIIIIIII IIIIII 20140926-0080117
Mary HoUinrake P:59/120 11:57P.M Kent Cnty MI Rgstr09/26/2014 SEAL
Performance Standards have not been achieved, EPA will notify Settling Work Defendants in
writing of the activities that must be undertaken by Settling Work Defendants pursuant to this
Consent Decree to complete the Remedial Action and achieve the Performance Standards.
Provided, however, that EPA may only require Settling Work Defendants to perform such
activities pursuant to this Paragraph to the extent that such activities are consistent with "scope of
the remedy selected in the ROD" as that term is defined in Paragraph 13.b. E P A will set forth in
the notice a schedule for performance of such activities consistent with the Consent Decree and
the SOW or require the Settling Work Defendants to submit a schedule to EPA for approval
pursuant to Section XI (EPA Approval of Plans and Other Submissions). Settling Work
Defendants shall perform all activities described in the notice in accordance with the
specifications and schedules established pursuant to this Paragraph, subject to their right to
invoke the dispute resolution procedures set forth in Section X I X (Dispute Resolution).
b. If EPA concludes, based on the initial or any subsequent report requesting
Certification of Completion and after consultation with the State, that the Remedial Action has
been performed in accordance with this Consent Decree and that the Performance Standards have
been achieved, EPA will so certify in writing to Settling Work Defendants. This certification
shall constitute the Certification of Completion ofthe Remedial Action for purposes of this
Consent Decree, including, but not limited to, Section X X I (Covenants Not to Sue by Plaintiff).
Certification of Completion of the Remedial Action shall not affect Settling Work Defendants'
obligations under this Consent Decree.
51. Completion of the Work
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 4 3
• IWill I IIIIIIIIII ^ J 40926-0080117
Mary HoUinrake P.-60/120 11-57P.M Kent Cnty MI Rgstr 09/26/2014 sEflL
20" iry Ho ant Cn
a. Within 90 days after Settling; Work Deiencfarrcs conclude that all phases of
the Work (including O & M), have been fully performed, Settling Work Defendants shall
schedule and conduct a pre-certification inspection to be attended by Settling Work Defendants,
EPA. If, after the pre-certification inspection, the Settling Work Defendants still believe that the
Work has been fully performed, Settling Work Defendants shall submit a written report
requesting certification to EPA for approval, with a copy to the State within 45 days of the
inspection. In the report, a registered professional engineer and the Settling Work Defendants'
Project Coordinator shall state that the Work has been completed in full satisfaction of the
requirements of this Consent Decree. The report shall contain the following statement, signed by
a responsible corporate official of a Settling Work Defendant or the Settling Work Defendants'
Project Coordinator:
"To the best of my knowledge, after thorough investigation,-1 certify that the information contained in or accompanying this submission is true, accurate and complete. I am aware that there are significant penalties for submitting false information, including the possibility of fine and imprisonment for knowing violations."
If, after review of the written report, EPA, after consultation with the State, determines
that any portion ofthe Work has not been completed in accordance with this Consent Decree,
EPA will notify Settling Work Defendants in writing of the activities that must be undertaken by
Settling Work Defendants pursuant to this Consent Decree to complete the Work. Provided,
however, that EPA may only require Settling Work Defendants to perform such activities
pursuant to this Paragraph to the extent that such activities are consistent with the "scope of the
remedy selected in the ROD" as that term is defined in Paragraph 13.b. EPA will set forth in the
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 44 -
IIIIIIII in iii II ii in 11 HI ly II 20140926-0080117
Mary HoUinrake P : 6 ^ 2 | ° 2 0 1
1
4
1 : | 7 ^ L
notice a schedule for performance of i^ll^J^IJL^^OTifmTOiri-vvi-tn-tiie Consent Decree and the
SOW or require the Settling Work Defendants to submit a schedule to EPA for approval pursuant
to Section XI (EPA Approval of Plans and Other Submissions). Settling Work Defendants shall
perform all activities described in the notice in accordance with the specifications and schedules
established therein, subject to their right to invoke the dispute resolution procedures set forth in
Section X I X (Dispute Resolution).
b. If EPA concludes, based on the initial or any subsequent request for
Certification of Completion by Settling Work Defendants and after consultation with the State,
that the Work has been performed i n accordance with this Consent Decree, EPA will so notify
the Settling Defendants in writing.
X V . E M E R G E N C Y RESPONSE
52. In the event of any action or occurrence during the performance of the Work
which causes or threatens a release of Waste Material from the Site that constitutes an emergency
situation or may present an immediate threat to public health or welfare or the environment,
Settling Work Defendants shall, subject to Paragraph 53, immediately take all appropriate action
to prevent, abate, or minimize such release or threat of release, and shall immediately notify the
EPA's Project Coordinator, or, i f the Project Coordinator is unavailable, EPA's Alternate Project
Coordinator. If neither of these persons is available, the Settling Work Defendants shall notify
the EPA Emergency Response Unit, Region 5. Settling Work Defendants shall take such
actions in consultation with EPA's Project Coordinator or other available authorized EPA officer
and in accordance with all applicable provisions of the Health and Safety Plans, the Contingency
United' States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 45 -
i i i i i i n i i n i i n i i i i i i i l l i i '2¥l 40926-0080117
' Mary HoUinrake P:62/120 11:57P1M : Kent Cnty MI Rgstr09/26/2014 SEAL
Plans, and any other applicable plans or aocuments developed pursuant to the SOW. In the event
that Settling Work Defendants fail to take appropriate response action as required by this
Section, and EPA takes such action instead, Settling Work Defendants shall reimburse EPA all
costs ofthe response action not inconsistent with the NCP pursuant to Section X V I
(Reimbursement of Response Costs).
53. Nothing in the preceding Paragraph or in this Consent Decree shall be deemed to
limit any authority of the United States a) to take all appropriate action to protect human health
. and the environment or to prevent, abate, respond to, or minimize an actual or threatened release
of Waste Material on, at, or from the Site, or b) to direct or order such action, or seek an order
from the Court, to protect human health and the environment or to prevent, abate, respond to, or
minimize an actual or threatened release of Waste Material on, at, or from the Site, subject to
Section X X I (Covenants Not to Sue by Plaintiff).
X V I . P A Y M E N T OF RESPONSE COSTS
54. a. Payments by SettlingCash Defendants: Within 30 days of the date of entry of
this Consent Decree, all funds to be paid by each Settling Cash Defendant shall be paid to the
Settling Work Defendants as established and designated by mutual agreement of the Settling
Work Defendants and Settling Cash Defendants in contribution towards the Work and fulfillment
of legal obligations related to the Site. Each Settling Cash Defendant's obligations under this
Consent Decree shall be limited to the payment of its requisite amount, except as specifically
provided in Paragraphs 6.a and 84; no Settling Cash Defendant shall be responsible for any
payment required of any other Party. The failure of any Settling Cash Defendant to satisfy its
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 4 6
I L L IIIIIIIIIIII 20140926-0080117
Mary HoUinrake P:63/120 11:57AM , , . . . . J<ent Cnty MI Rgstr09/26/2014 SEflL . _ , _ , .
payment obligation pursuant to this raragrapn snan nor aeier me obligations of the Settling
Work Defendants under this Consent Decree. The name of each Settling Cash Defendant shall be
submitted to the United States as provided in Section X X V I (Notices and Submissions) upon
execution of the Consent Decree by each Settling Cash Defendant and will subsequently be
appended to Appendix E.1 of this Consent Decree prior to entry.
b. Except as provided in subparagraph c. of this Paragraph, Settling
Defendants shall not be required to reimburse EPA for Future Response Costs; E P A may,
however, seek reimbursement of Future Response Costs from the non-settling PRPs.
c. Notwithstanding the provisions of subparagraph b. of this Paragraph, the
United States may seek reimbursement of certain Future Response Costs from Settling Work
Defendants if either (1) Settling Work Defendants are not in compliance with this Consent
Decree, or (2) EPA takes over the Work at the Site under Paragraphs 52 or 85 of this Consent
Decree. In the event EPA takes over the work pursuant to Paragraph 52 or 85, EPA may seek,
and the Settling Work Defendants shall be responsible for, any Future Response Costs incurred
pursuant to those Paragraphs. In the event Settling Work Defendants fail to comply with this
Consent Decree and EPA takes action against them to enforce its terms, EPA may seek, and the
Settling Work Defendants shall be responsible for, any Future Response Costs incurred in such
enforcement action(s). If payment is required, Settling Work Defendants shall make all
payments required by this Paragraph in the form of a certified or cashier's check or checks made
payable to "EPA Hazardous Substance Superfund" and referencing the EPA Region and
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 4 7 -
IIIIIIIIIIIIIIIIIIIIINIIIIIIIIIIIINIIII 20140926-0080117
Mary HoUinrake P:64/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEftL
Site/Spill ID #MID062222997, the DOJ case number 90-11 -3-145A, and the name and address
of the party making payment. The Settling Work Defendants shall send the check(s) to
USEPA Superfund Accounting Office P.O. Box 70753 Chicago, Illinois 60673
and shall send copies of the check(s) to the United States as specified in Section X X V I (Notices
and Submissions) and Superfund Accounting, PO Box 70753, Chicago, IL 60673.
55. Settling Work Defendants may contest payment of any Future Response Costs
• payable under Paragraph 54 if they deterrnine that the United States has made an accounting
error or if they allege that a cost item that is included represents costs that are inconsistent with
the NCP. Such objection shall be made in writing within 30 days of receipt of the bill and must
be sent to the United States, if the United States' accounting is being disputed, pursuant to
Section X X V I (Notices and Submissions). Any such objection shall specifically identify the
contested Future Response Costs and the basis for objection. In the event of an objection, the
Settling Work Defendants shall within the 30 day period pay all uncontested Future Response
Costs to the United States in the manner described in Paragraph 54.c. Simultaneously, the
Settling Work Defendants shall establish an interest-bearing escrow account in a federally-
insured bank duly chartered in the State of Michigan and remit to that escrow account funds
equivalent to the amount of the contested Future Response Costs. The Settling Work Defendants
shall send to the United States, as provided in Section X X V I (Notices and Submissions), a copy
of the transmittal letter and check paying the uncontested Future Response Costs, and a copy of
the correspondence that establishes and funds the escrow account, including, but not limited to,
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 48 -
Jlllllllll llllllllllllfflli 20140926-0080117
Mary HoUinrake P: 657120 • f . • • + i • ! . . . .Kent Cnty MI Rgstr 09/26/2014 SEAL
information containing the identity oi oanK ana oainc account under which the escrow
account is established as well as a bank statement showing the initial balance of the escrow
account. Simultaneously with establishment of the escrow account, the Settling Work
Defendants shall initiate the dispute resolution procedures in Section X I X (Dispute Resolution).
If the United States prevails in the dispute, within 5 days of the resolution of the dispute, the
Settling Work Defendants shall pay the sums due (with accrued interest) to the United States in
the manner described in Paragraph 54.c. If the Settling Work Defendants prevail concerning any
aspect of the contested costs, the Settling Work Defendants shall pay that portion of the costs
(plus associated accrued interest) for which they did not prevail to the United States in the
manner described in Paragraph 54.c; Settling Work Defendants shall be disbursed any balance of
the escrow account. The dispute resolution procedures set forth in this Paragraph in conjunction
with the procedures set forth in Section X I X (Dispute Resolution) shall be the exclusive
mechanisms for resolving disputes regarding the Settling Work Defendants' obligation to
reimburse the United States for its Future Response Costs.
56. In the event that any payments which may be required by Paragraph 54.c. are not
made within 30 days ofthe Settling Work Defendants' receipt of the bill, Settling Work
Defendants shall pay Interest on the unpaid balance. The Interest on Future Response Costs shall
begin to accrue on the date ofthe b i l l The Interest shall accrue through the date ofthe Settling
Work Defendants' payment. Payments of Interest made under this Paragraph shall be in addition
to such other remedies or sanctions available to Plaintiffs by virtue of Settling Work Defendants'
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 49
20 Illlllllllllllll
40! 26-0080117 Mary HoUinrake P:66/120 11:57AM
c •! i i , Kent Cnty MI Rgstr 09/26/2014 SEAL , n f , , ,
failure to make timely payments unocr cms D r o u m r . rnrDranng « ork Detendants shall make
all payments required by this Paragraph in the manner described in Paragraph 54.c.
XVII. INDEMNIFICATION A N D INSURANCE
57; a. The United States does not assume any liability by entering into this
agreement or by virtue of any designation of Settling Work Defendants as EPA's authorized
representatives under Section 104(e) of C E R C L A . Settling Work Defendants shall indemnify,
save and hold harmless the United States and its officials, agents, employees, contractors,
subcontractors, or representatives for-or from any and all claims or causes of action arising from,
or on account of, negligent or other wrongful acts or omissions of Settling Work Defendants,
their officers, directors, employees, agents, contractors, subcontractors, and any persons acting
on their behalf or under their control, in carrying out activities pursuant to this Consent Decree,
including, but not limited to, any claims arising from any designation of Settling Work
Defendants as EPA's authorized representatives under Section 104(e) of C E R C L A . Further, the
Settling Work Defendants agree to pay the United States all costs it incurs including, but not
limited to, attorneys fees and other expenses of litigation and settlement arising from, or on
account of, claims made against the United States based on negligent or other wrongful acts or
omissions of Settling Work Defendants, their officers, directors, employees, agents, contractors,
subcontractors, and any persons acting on their behalf or under their control, in carrying out
activities pursuant to this Consent Decree. The United States shall not be held out as a party to
any contract entered into by or on behalf of Settling Work Defendants in carrying out activities
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 5 0
IIIIIIII IIIIIIIIIJIII 20140926-0080117
Mary Hollinraka P:67/12Q 11:57RM Kent Cnty MI Rgstr 09/26/2014 SEftL
pursuant to this Consent Decree. Neither the Settling Work Defendants nor any such contractor
shall be considered an agent of the United States.
b. The United States shall give Settling Work Defendants notice of any claim
for which the United States plans to seek indemnification pursuant to Paragraph 57.a., and shall
consult with Settling Work Defendants prior to settling such claim.
58. Settling Work Defendants waive all claims against the United States for damages
or reimbursement or for set-off of any payments made or to be made to the United States, arising
from or on account of any contract, agreement, or arrangement between any one or more of
Settling Work Defendants and any person for performance of Work on or relating to the Site,
including, but not limited to, claims on account of construction delays. In addition, Settling
Work Defendants shall indemnify and hold harmless the United States with respect to any and all
claims for damages or reimbursement arising from or on account of any contract, agreement, or
arrangement between any one or more of Settling Work Defendants and any person for
performance of Work on or relating to the Site, including, but not limited to, claims on account
of construction delays.
59. No later than 15 days before commencing any on-site Work, Settling Work
Defendants shall secure, and shall maintain until the first anniversary of EPA's Certification of
Completion of the Remedial Action pursuant to Paragraph 50.b. of Section X I V (Certification of
Completion) comprehensive general liability insurance with limits of one million dollars,
combined single limit, and automobile liability insurance with limits of one million dollars,
combined single limit, naming the United States as an additional insured. In addition, for the
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 51 -
IIIIIIII lllllllllllffilllli 20140926-0080117
Mary HoUinrake P:68/120 11:57fiM Kent Cnty MI Rgstr09/26/2014 SEflL
duration of this Consent Decree, Settling "Work Defendants shall satisfy, or shall ensure, that their
contractors or subcontractors satisfy, all applicable laws and regulations regarding the provision
of worker's compensation insurance for all persons performing the Work on behalf of Settling
Work Defendants in furtherance of this Consent Decree. Prior to commencement of the Work
under this Consent Decree, Settling Work Defendants shall provide to EPA certificates of such
insurance and a copy of each insurance policy. Settling Work Defendants shall resubmit such
certificates and copies of policies each year on the anniversary of the effective date of this
Consent Decree. If Settling Work Defendants demonstrate by evidence satisfactory to EPA that
any contractor or subcontractor maintains insurance equivalent to that described above, or
insurance covering the same risks but in a lesser amount, then, with respect to that contractor or
subcontractor, Settling Work Defendants need provide only that portion of the insurance
described above which is not maintained by the contractor or subcontractor.
XVIII. FORCE M A J E U R E
60. "Force majeure," for purposes of this Consent Decree, is defined as any event
arising from causes beyond the control of the Settling Defendants, of any entity controlled by
Settling Defendants, or of Settling Defendants' contractors, that delays or prevents the
performance of any obligation under this Consent Decree despite Settling Defendants' best
efforts to fulfill the obligation. The requirement that the Settling Defendants exercise "best
efforts to fulfill the obligation" includes using best efforts to anticipate any potential force
majeure event and best efforts to address the effects of any potential force majeure event (1) as it
is occurring and (2) following the potential force majeure event, such that the delay is minimized
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 52 -
IIIIIIIIII iiuiiiiiiiiiniuiuiiii 20140926-0080117
Mary HoUinrake P:69/120 11:57fll»l Kent. Cnty MI Rgstr 09/26/2014 SEflL
to the greatest extent possible. "Force Majeure" does not include "financial inability to complete
the Work or a failure to attain the Performance Standards.
61. If any event occurs or has occurred that may delay the performance of any
obligation under this Consent Decree, whether or not caused by a force majeure event, the
Settling Defendants shall notify orally EPA's Project Coordinator or, in his or her absence, EPA's
Alternate Project Coordinator or, in the event both of EPA's designated representatives are
unavailable, the Director of the Hazardous Waste Management Division, E P A Region 5, within
48 hours of when Settling Defendants-first knew that the event might cause a delay. Within 5
days thereafter, Settling Defendants shall provide in writing to EPA an explanation and
description of the reasons for the delay; the anticipated duration of the delay; all actions taken or
to be taken to prevent or minimize the delay; a schedule for implementation of any measures to
• be taken to prevent or mitigate the delay or the effect of the delay; the Settling Defendants'
rationale for attributing such delay to a force majeure event i f they intend to assert such a claim;
and a statement as to whether, in the opinion of the Settling Defendants, such event may cause or
contribute to an endangerrnent to public health, welfare or the environment. The Settling
Defendants shall include with any notice all available documentation supporting their claim that
the delay was attributable to a force majeure. Failure to comply with the above requirements
shall preclude Settling Defendants from asserting any claim of force majeure for that event for
the period of time of such failure to comply, and for any additional delay caused by such failure.
Settling Defendants shall be deemed to know of any circumstance of which Settling Defendants,
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 53 -
IIIIIIIIIIII IIIIIIIIII IIIIIIIIIIII 20140926-0080117
Mary Hollinrake P:70/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
any entity controlled by Settling Defendants, or Settling Defendants' contractors knew or should
have known.
62. If EPA, after a consultation with the State, agrees that the delay or anticipated
delay is attributable to a force majeure event, the time for performance of the obligations under
this Consent Decree that are affected by the force majeure event will be extended by E P A for
such time as is necessary to complete those obligations. A n extension of the time for
performance of the obligations affected by the force majeure event shall not, of itself, extend the
time for performance of any other obligation. If E P A does-not agree that the delay or anticipated
delay has been or will be caused by a force majeure event, EPA will notify the Settling
Defendants in writing of its decision. If EPA agrees that the delay is attributable to a force
majeure event, EPA will notify the Settling Work Defendants in writing of the length ofthe
extension, i f any, for performance of the obligations affected by the force majeure event.
63. If the Settling Defendants elect to invoke the dispute resolution procedures set
forth in Section X I X (Dispute Resolution), they shall do so no later than 15 days after receipt of
EPA's notice. In any such proceeding, Settling Defendants shall have the burden of
demonstrating by a preponderance of the evidence that the delay or anticipated delay has been or
will be caused by a force majeure event, that the duration of the delay or the extension sought
was or will be warranted under the circumstances, that best efforts were exercised to avoid and
mitigate the effects ofthe delay, and that Settling Defendants complied with the requirements of
Paragraphs 60 and 61, above. If Settling Defendants carry this burden, the delay at issue shall be
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 54 -
iiiiiiiiiiiiiiiii 20140926-0080117 1 Mary HoUinrake P:71/120 11:57?"
Kent Cnty MI Rgstr09/26/2014 SEflL
deemed not to be a violation by Settling ucxenaanxs ot me affected obligation of this Consent
Decree identified to E P A and the Court.
X I X . DISPUTE RESOLUTION
64. Unless otherwise expressly provided for in this Consent Decree, the dispute
resolution procedures of this Section shall be the exclusive mechanism to resolve disputes arising
under or with respect to this Consent Decree. However, the procedures set forth in this Section
shall not apply to actions by the United States to enforce obligations of the Settling Defendants
that have not been disputed in accordance with this Section. - -
65. Any dispute which arises under or with respect to this Consent Decree shall in the
first instance be the subject of informal negotiations between the parties to the dispute. The
period for informal negotiations shall not exceed 20 days from the time the dispute arises, unless
it is modified by written agreement of the parties to the dispute. The dispute shall be considered
to have arisen when one party sends the other parties a written Notice of Dispute.
66. a. In the event that the parties cannot resolve a dispute by informal negotiations
under the preceding Paragraph, then the position advanced by E P A shall be considered binding
unless, within 14 days after the conclusion ofthe informal negotiation period, Settling
Defendants invoke the formal dispute resolution procedures of this Section by serving on the
United States a written Statement of Position on the matter in dispute, including, but not limited
to, any factual data, analysis or opinion supporting that position and any supporting
documentation relied upon by the Settling Defendants. The Statement of Position shall specify
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 55
Ill III IIIIIIIIIIIIIili iii III 20140926-0080117
Mary HoUinrake P:72/120 11:57RM Kent Cnty MI Rgstr09/26/2014 SEAL
the Settling Defendants' position as id whether formal dispute resolution should proceed under
Paragraph 67 or Paragraph 68.
b. Within 14 days after receipt of Settling Defendants' Statement of Position,
E P A will serve on Settling Defendants its Statement of Position, including, but not limited to,
any factual data, analysis, or opinion supporting that position and all supporting documentation
relied upon by EPA. EPA's Statement of Position shall include a statement as to whether formal
dispute resolution should proceed under Paragraph 67 or 68. Within 14 days after receipt of
EPA's Statement of Position, Settling Defendants may submit a Reply.
c. If there is disagreement between EPA and the Settling Defendants as to
whether dispute resolution should proceed under Paragraph 67 or 68, the parties to the dispute
shall follow the procedures set forth in the paragraph determined by EPA to be applicable.
However, if the Settling Defendants ultimately appeal to the Court to resolve the dispute, the
Court shall determine which paragraph is applicable in accordance with the standards of
applicability set forth in Paragraphs 67 and 68.
67. Formal dispute resolution for disputes pertaining to the selection or adequacy of
any response action and all other disputes that are accorded review on the administrative record
under applicable principles of administrative law shall be conducted pursuant to the procedures
set forth in this Paragraph. For purposes of this Paragraph, the adequacy of any response action
includes, without limitation: (1) the adequacy or appropriateness of plans, procedures to
implement plans, or any other items requiring approval by EPA under this Consent Decree.; and
(2) the adequacy ofthe performance of response actions taken pursuant to this Consent Decree.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 56
IIIIIIIIIIII iioiiiiiiiiiiiiwini I I I I I 20140926-0080117
Hary HoUinrake P:73/120 11:57P.M
Nothing in this Consent Decree shall t^ n ^TroOTro P airow way dispute by Settling Defendants
regarding the validity of the ROD's provisions.
a: A n administrative record of the dispute shall be maintained by E P A and
shall contain all statements of position, including supporting documentation, submitted pursuant
to this Section. Where appropriate, E P A may allow submission of supplemental statements of
position by the parties to the dispute.
b. The Director of the Waste Management Division, EPA Region 5, will
issue a final administrative decision resolving the dispute based on the administrative record
described in Paragraph 67.a. This decision shall be binding upon the Settling Defendants,
subject only to the right to seek judicial review pursuant to Paragraph 67.c. and d.
c. Any administrative decision made by EPA pursuant to Paragraph 67.b.
shall be reviewable by this Court, provided that a motion for judicial review of the decision is
filed by the Settling Defendants with the Court and served on all Parties within 10 days of receipt
of EPA's decision. The motion shall include a description of the matter in dispute, the efforts
made by the parties to resolve it, the relief requested, and the schedule, i f any, within which the
dispute must be resolved to ensure orderly implementation of this Consent Decree. The United
States may file a response to Settling Defendants' motion.
d. In proceedings on any dispute governed by this Paragraph, Settling
Defendants shall have the burden of demonstrating that the decision of the Waste Management
Division Director is arbitrary and capricious or otherwise not in accordance with law. Judicial
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 57 -
iniiiiiiiiiiuiiiiiiiii!iwiiii|ii 20140926-0080117 Mary HoUinrake P:74/120 11:57flM
Kent Cnty MI Rgstr 09/26/2014 SEftL
review of EPA's decision shall be on me administrative record compiled pursuant to Paragraph
67.a.
68. Formal dispute resolution for disputes that neither pertain to the selection or
adequacy of any response action nor are otherwise accorded review on the administrative record
under applicable principles of administrative law, shall be governed by this Paragraph.
a. Following receipt of Settling Defendants' Statement of Position submitted
pursuant to Paragraph 66, the Director ofthe Waste Management Division, E P A Region 5, will
issue a final decision resolving the dispute. The Waste Management Division Director's decision'
shall be binding on the Settling Defendants unless, within 10 days of receipt of the decision, the
Settling Defendants file with the- Court and serve on the parties a motion for judicial review of
the decision setting forth the matter in dispute, the efforts made by the parties to resolve it, the
relief requested, and the schedule, i f any, within which the dispute must be resolved to ensure
orderly implementation ofthe Consent Decree. The United States may file a response to Settling
Defendants' motion.
b. Judicial review of any dispute governed by this Paragraph shall be
governed by applicable principles of law.
69. The invocation of formal dispute resolution procedures under this Section shall
hot extend, postpone or affect in any way any obligation of the Settling Defendants under this
Consent Decree, not directly in dispute, unless E P A or the Court agrees otherwise. Stipulated
penalties with respect to the disputed matter shall continue to accrue but payment shall be stayed
pending resolution of the dispute as provided in Paragraph 77. Notwithstanding the stay pf
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 58
11II'I II1,111,11,1 llil 20140926-0080117
Mary HoUinrake P:75/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
payment, stipulated penalties shall accrue from the first day of noncompliance with any
applicable provision of this.Consent Decree. In the event that the Settling Defendants do not
prevail on the disputed issue, stipulated penalties shall be assessed and paid as provided in
Section X X (Stipulated Penalties).
X X . STIPULATED PENALTIES
70. Settling Defendants shall be liable for stipulated penalties in the amounts
set forth in Paragraphs 71 and 72 to the United States for failure to comply with the requirements
of this Consent Decree specified below, unless excused under Section XVIII (Force Majeure).
"Compliance" by Settling Work Defendants shall include completion of the activities under this
Consent Decree, or any schedule or work plan approved under this Consent Decree identified
below, in accordance with all applicable requirements of law, this Consent Decree, the SOW, and
any plans or other documents approved by EPA pursuant to this Consent Decree and within the
specified time schedules established by and approved under this Consent Decree
71. a. The following stipulated penalties shall accrue per violation per day for any
noncompliance identified in Subparagraph b:
Penalty Per Day of Noncompliance
1 -14 Davs 15+ Davs 15-30 Days
$250/day $500/day $l,000/day
b. Failure of Settling Work Defendants to submit the following documents
on time: ARDPP, R A Work Plan, Inspection Report, O & M Plan Addendum, Construction
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 59 -
IIIIIIII iiniiiiillii 20140926-0080117 Mary HoUinrake P:76/120 1 1 : 5 ^ ^ j _
Report, Remedial Action Report, and V K J " L c ^ Y
F o i vAcmeaiar action Completion Report, Work
Reports, Monthly Progress Reports, and other written documents other than those identified.
c. The following stipulated penalties shall accrue per violation per day for
any noncompliance identified in Subparagraph d:
Penalty Per Day of Noncompliance
1-14 Davs 15+ Davs 15-30 Days
$l,000/day . 3,000/day 5,000/day .
d. Failure,of Settling Work Defendants to commence onrsite. construction
activities according to the approved schedule and/or perform the Work and for any other
noncompliance under this Consent Decree.
e. A stipulated penalty of $ 1000.00 per day per violation shall accrue and shall be
payable to the United States by any Settling Cash Defendant for its failure to make timely
payment of the amount payable by such Settling Cash Defendants under Section X V I
(Payment of Response Costs) of this Consent Decree, in addition to any Interest on such amounts
and such other remedies or sanctions available to Plaintiff.
72. In the event that E P A assumes performance of a portion or all of the Work
pursuant to Paragraph 85 of Section X X I (Covenants Not to Sue by Plaintiff), Settling Work
Defendants shall be liable for a stipulated penalty in the amount of $75,000.
73. A l l penalties shall begin to accrue on the day after the complete performance is
due or the day a violation occurs, and shall continue to accrue through the final day ofthe
correction of the noncompliance or completion of the activity. However, stipulated penalties
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 60
•iiniiiWiW 20140926-0080117
• |&TS1tilBia5S.^S//^»iVi^a.
shall not accrue: (1) with respect tu = u « r c i c n i sxroimssion under Section X I (EPA Approval of
Plans and Other Submissions), during the period, i f any, beginning on the 31 st day after EPA's
receipt of such submission until the date that E P A notifies Settling Work Defendants of any
deficiency; (2) with respect to a decision by the Director of the Superfund Waste Management .
Division, EPA Region V , under Paragraph 67.b. or 68.a. of Section X I X (Dispute Resolution),
during the period, if any, beginning on the 21st day after the date that Settlmg Work Defendants'
reply to EPA's Statement of Position is received until the date that the Director issues a final
decision regarding such dispute; or (3) with respect to judicial review by this Court of any
dispute under Section X I X (Dispute Resolution), during the period, i f any, beginning on the 31st
day after the Court's receipt of the final submission regarding the dispute until the date that the
Court issues a final decision regarding such dispute. Nothing herein shall prevent the
simultaneous accrual of separate penalties for separate violations of this Consent Decree.
74. Following EPA's determination that Settling Work Defendants have failed to
comply with a requirement of this Consent Decree, EPA may give Settling Work Defendants
written notification of the same and describe the noncompliance. E P A may send the Settling
Work Defendants a written demand for the payment of the penalties. However, penalties shall
accrue as provided in the preceding Paragraph regardless of whether EPA has notified the
Settling Work Defendants of a violation.
75. A l l penalties accruing under this Section shall be due and payable to the United
States within 30 days of the Settling Work Defendants' receipt from EPA of a demand for
payment of the penalties, unless Settling Work Defendants invoke the Dispute Resolution United States v. Allied Waste Systems, et.al. Butterworth #2 Landfill Superfund Site CONSENT DECREE - 61 -
IIIIIIIIIIII IIIIIIIIII 40926-0080117
Mary HoUinrake P:78/120 11:57AM Kent Cnty MI Rgstr 09/26/2014 SEAL.
20" ary Ha ant Cr
procedures under Section X I X (Dispute Resolution). A l l payments to the United States under
this Section shall be paid by certified or cashier's check(s) made payable to "EPA Hazardous
Substances Superfund," shall be mailed to:
USEPA Superfund Accounting. Office P.O. Box 70753 Chicago, Illinois 60673
and shall indicate that the payment is for stipulated penalties, and shall reference the E P A Region
and Site/Spill ID #MID06222297, the DOJ Case Number 90-11-3-145A, and the name and
address qf the party making payment; Copies of check(s) paid pursuant to this Section, and any
accompanying transmittal letter(s), shall be sent to the United States as provided in Section
X X V I (Notices and Submissions).
76. The payment of penalties shall not alter in any way Settling Work Defendants'
obligation to complete the performance ofthe Work required under this Consent Decree.
77. Penalties shall continue to accrue as provided in Paragraph 73 during any dispute
resolution period, but need not be paid until the following:
a. If the dispute is resolved by agreement or by a decision of E P A that is not
appealed to this Court, accrued penalties determined to be owing shall be paid to EPA within 15
days of the agreement or the receipt of EPA's decision or order;
b. If the dispute is appealed to this Court and the United States prevails in
whole or in part, Settling Work Defendants shall pay all accrued penalties determined by the
Court to be owed to EPA within 60 days of receipt of the Court's decision or order, except as
provided in Subparagraph c below;
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site '
CONSENT DECREE - 62 -
IIIII IIIIIIIIIIII U 20140926-0080117
Mary HoUinrake P:79/120 11 :57flM Kent Cnty MI Rgstr09/26/2014 SEAL
c. If the District Coxirrs aecisidnis appealed by any Party, Settling Work
Defendants shall pay all accrued penalties determined by the District Court to be owing to the
United States into an interest-bearing escrow account within 60 days of receipt of the Court's
decision or order. Penalties shall be paid into this account as they continue to accrue, at least
every 60 days. Within 15 days of receipt of the final appellate court decision, the escrow agent
shall pay the balance of the account to EPA or to Settling Work Defendants to the extent that
they prevail.
- 78. a. If Settling Work Defendants fail to pay stipulated penalties when due, the "
United States may institute proceedings to collect the penalties, as well as interest. Settling
Work Defendants shall pay Interest on the unpaid balance, which shall begin to accrue on the
date of demand made pursuant to Paragraph 74.
b. Nothing in this Consent Decree shall be construed as prohibiting, altering,
or in any way limiting the ability of the United States to seek any other remedies or sanctions
available by virtue of Settling Work Defendants' violation of this Decree or of the statutes and
regulations upon which it is based, including, but not limited to, penalties pursuant to Section
122(1) of CERCLA. Provided, however, that the United States shall not seek civil penalties
pursuant to Section 122(1) of C E R C L A for any violation for which a stipulated penalty is
provided herein, except in the case of a willful violation of the Consent Decree.
79. Notwithstanding any other provision of this Section, the United States may, in its
unreviewable discretion, waive any portion of stipulated penalties that have accrued pursuant to
this Consent Decree.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 63 -
20140926-0080 17 Mary HoUinrake P:80/120 11:67fiM
W T or\^7irXTATvKent Cnty MI Rgstr 09/26/20U SEflL X X I . COVENAJN jro rrxxr x 17 oerr, jp y r i - A U N 1 IFF
80. a. In consideration ofthe actions that will be performed by the Settling Work
Defendants and Settling Owner Defendants under the terms of the Consent Decree, and except as
specifically provided in Paragraphs 81, 82, and 84 of this Section, the United States covenants
not to sue or to take administrative action against Settling Work Defendants and Settling Owner
Defendants pursuant to Sections 106 and 107(a) of C E R C L A and Section 7003 of R C R A
relating to the Site. Except with respect to future liability, these covenants not to sue shall take
effect upon the entry of the Consent Decree by the Court. With respect to future liability, these
covenants not to sue shall take effect upon Certification of Completion of Remedial Action by
E P A pursuant to Paragraph 50.b of Section X I V (Certification of Completion). These covenants
not to sue are conditioned upon the satisfactory performance by Settling Work Defendants of
their obligations under this Consent Decree. These covenants not to sue extend only to the
Settling Work Defendants and do not extend to any other person.
b. In consideration of the payments that will be made by each Settling Cash
Defendant under the terms of the Consent Decree, and except as specifically provided in
Paragraphs 81, 82, and 84 of this Section, the United States covenants not to sue or to take
administrative action against Settling Cash Defendants pursuant to Sections 106 and 107(a) of
C E R C L A and Section 7003 of R C R A relating to the Site. Except with respect to future liability,
these covenants not to sue shall take effect upon the entry of the Consent Decree by the Court.
With respect to future liability, these covenants not to sue shall take effect upon Certification of
Completion of Remedial Action by E P A pursuant to Paragraph 50.b of Section XIV
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 64
IIIIIII IIII IIIIIIIIIIIIIIIUMIIIII 20140926-0080117
Mary HoUinrake P:81/120 11:57flM Kent Cnty MI Rgstr 09/26/20H SEftL
(Certification of Completion). These covenants hot to sue are conditioned upon the satisfactory
performance by Settling Cash Defendants of their obligations under this Consent Decree. These
covenants not to sue extend only to the Settling Cash Defendants and do not extend to any other
person.
81. United States' Pre-certification Reservations. Notwithstanding any other
provision of this Consent Decree, the United States reserves, and this Consent Decree is without
prejudice to, the right to institute proceedings in this action or in a new action, or to issue an
administrative order seeking to compel Settling Work Defendants (1) to perform further response
actions relating to the Site or (2) to reimburse the United States for additional costs of response
if, prior to Certification of Completion of the Remedial Action:
(i) conditions at the Site, previously unknown to EPA, are discovered, or
(ii) information, previously unknown to EPA, is received, in whole or in part,
and these previously unknown conditions or information together with any other relevant
information indicates that the Remedial Action is not protective of human health or the
environment.
82. United States' Post-certification Reservations: Notwithstanding any other
provision of this Consent Decree, the United States reserves, and this Consent Decree is without
prejudice to, the right to institute proceedings in this action or in a new action, or to issue an
administrative order seeking to compel Settling Work Defendants (1) to perform further response
actions relating to the Site or (2) to reimburse the United States for costs of response (other than
EPA oversight costs) if, subsequent to Certification of Completion of the Remedial Action:
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 65 -
IIIIIIIIIIII llUllllillllllill 20140926-0080117
Marv HoUinrake P:82/120 11:57P.H , ' Kent cnty m Rgstr09/26/2014 SEftL
(i) conditions at the aire, previously unknown to EPA, are discovered, or
(ii) information, previously unknown to EPA, is received, in whole or in part,
and these previously unknown conditions or this information together with other relevant
information indicate that the Remedial Action is not protective of human health or the
environment.
83. For purposes of Paragraph 81, the information and the conditions known to EPA
shall include only that information and those conditions known to E P A as of the effective date of
. this Consent Decree and set forth in the administrative record. For purposes of Paragraph 82, the
information and the conditions known to EPA shall include only that information and those
conditions known to EPA as of the date of Certification of Completion of the Remedial Action
and set forth in the Record of Decision, the administrative record supporting the Record of
Decision, the post-ROD administrative record, or in any information received by EPA pursuant
to the requirements of this Consent Decree prior to Certification of Completion of the Remedial
Action.
84. General reservations of rights as to Settling Defendants.
The covenants not to sue set forth above do not pertain to any
matters other than those expressly specified in Paragraph 80. The United States reserves, and
this Consent Decree is without prejudice to, all rights against Settling Defendants with respect to
all other matters, including but not limited to, the following:
(1) claims based on a failure by Settling Defendants to meet a requirement of
this Consent Decree;
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 66 -
IIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIII1 17 20140926-0080'
Mary HoUinrake P:83/120 11:57P.M Kent Cnty MI Rgstr09/26/2014 SEAL
(2) liability arising from the past, present, or future
disposal, release, or threat of release of Waste Materials
outside of the Site;
(3) liability for future disposal of Waste Material at the Site, other than as
provided in the ROD, the Work, or otherwise ordered by EPA;
(4) liability for damages for injury to, destruction of, or
loss of natural resources, and for the costs of any natural resource
damage assessments; . . .
(5) criminal liability;
(6) liability for violations of federal or state law
which occur during or after implementation of the Remedial Action;
(7) with respect to Settling Work Defendants only, liability prior to
Certification of Completion of the Remedial Action, for additional
response actions that EPA determines are necessary to achieve
Performance Standards, but that cannot be required pursuant to
Paragraph 12 (Modification ofthe Remedial Design
Document or Related Work Plans); and
(8) with respect to Settling Work Defendants only, liability for Future
Response Costs pursuant to Paragraph 54 c.
85. Work Takeover In the event EPA determines that Settling Work Defendants have
ceased implementation of any portion of the Work, are seriously or repeatedly deficient or late in
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 67
wiiiiiniiiiiiiioniiifuiiiiiiiiiiii 20 40926-0080117
i Mary HoUinrake P:84/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
their performance of the Work, or are implementing the Work in a manner which may cause an.
endangerrnent to human health or the environment, EPA may assume the performance of all or
any portions of the Work as EPA determines necessary. Settling Work Defendants may invoke
the procedures set forth in Section X I X (Dispute Resolution), Paragraph 67, to dispute EPA's
determination that takeover of the Work is warranted under this Paragraph. Costs incurred by the
United States in performing the Work pursuant to this Paragraph shall be considered Future
Response Costs that Settling Work Defendants shall pay pursuant to Section X V I
(Reimbursement of Response Costs).
86. Notwithstanding any other provision of this Consent Decree, the United States
retains all authority and reserves all rights to take any and all response actions authorized by law.
XXII . COVENANTS B Y SETTLING DEFENDANTS
87. Covenant Not to Sue. Subject to the reservations in Paragraph 88, Settling
Defendants hereby covenant not to sue and agree not to assert any claims or causes of action
against the United States with respect to the Site, Past and Future Response Costs as defined
herein, or this Consent Decree, including, but not limited to:
a. any direct or indirect claim for reimbursement from the Hazardous Substance
Superfund (established pursuant to the Internal Revenue Code, 26 U.S.C. § 9507) through
C E R C L A Sections 106(b)(2), 107, 111, 112, 113 or any other provision of law;
b. any claims against the United States, including any department, agency or
instrumentality of the'United States under C E R C L A Sections 107 or 113 related to the Site, or
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE 68 -
IIIIIIIIII IIIIIIIIIII™ 20140926-0080117
c. any claims arising out of response activities at the Site, including claims based on
EPA's selection of response actions, oversight of response activities or approval of plans for such
activities.
88. The Settling Defendants reserve, and this Consent Decree is without prejudice to,
claims against the United States, subject to the provisions of Chapter 171 of Title 28 of the
United States Code, for money damages for injury or loss of property or personal injury or death
caused by the negligent or wongful act or omission of any employee of the United States while
acting within the scope of his office or employment under circumstances where the United
States, i f a private person, would be liable to the claimant in accordance with the law of the place
where the act or omission occurred. However, any such claim shall not include a claim for any
damages caused, in whole or in part, by the act or omission of any person, including any
contractor, who is not a federal employee as that term is defined in 28 U.S.C. § 2671; nor shall
any such claim include a claim based on EPA's selection of response actions, or the oversight or
approval of the Settling Work Defendants' plans or activities. The foregoing applies only to
claims which are brought pursuant to any statute other than C E R C L A and for which the waiver
of sovereign immunity is found in a statute other than C E R C L A .
89. Settling Defendants agree not to assert any claims and to waive all claims or
causes of action that they may have for all matters relating to the Site, including for contribution,
against any person where the person's liability to Settling Defendants with respect to the Site is
based solely on having arranged for the disposal or treatment, or for transport for disposal or
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE - 69
IIIIIIIIII III llilllllll Mill 20140926-0080117
Mary HoUinrake P: 86/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEflL
treatment, of hazardous substances attne site or naving accepted tor transport for disposal or
treatment of hazardous substances at the Site, if
a. Any materials contributed by such person to the Site constituting,Municipal Solid
Waste (MSW) or Municipal Sewage sludge (MSS) did not exceed 0.2% of the total volume of
waste at the Site; and
b. Any materials contributed by such person to the Site containing hazardous
substances, but. not constituting M S W or MSS, did not exceed the greater of (i) 0.002% of the
total volume of waste at the Site, or (ii) 110 gallons of liquid materials or 200 pounds of solid
materials.
This waiver shall not apply to any claim or cause of action against any person meeting the
above criteria i f EPA has determined that the materials contributed to the Site by such person
contributed or could contribute significantly to the costs of response at the Site.
90. Nothing in this Consent Decree shall be deemed to constitute preauthorization of
a claim within the meaning of Section 111 of C E R C L A , 42 U.S.C. § 9611, or 40 C.F.R.
§ 300.700(d).
XXIII. EFFECT OF SETTLEMENT: CONTRIBUTION PROTECTION
91. Except as provided in Paragraph 89 nothing in this Consent Decree shall be
construed to create any rights in, or grant any cause of action to, any person not a Party to this.
Consent Decree. The preceding sentence shall not be construed to waive or nullify any rights
that any person not a signatory to this decree may have under applicable law. Except as provided
in Paragraph 89 each of the Parties expressly reserves any and all rights (including, but not
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 7 0
wiiiiiiiiiuiiiiniiiliiiii 20140926-0080117
. Mary HoUinrake P:87/120 11:5JWJ Kent Cnty MI Rgst r 09/26/2014 SEAL
limited to, any right to contribution), defenses, claims, demands, and causes of action which each
Party may have with respect to any matter, transaction, or occurrence relating in any way to the
Site against any person not a Party hereto.
92. The Parties agree, and by entering this Consent Decree this Court finds, that the
Settling Defendants are entitled, as of the effective date of this Consent Decree, to protection
from contribution actions or claims as provided by C E R C L A Section 113(f)(2), 42 U.S.C.
§ 9613(f)(2) for Matters Addressed in this Consent Decree.
93. The Settling Defendants agree that with respect to any suit or claim for-
contribution brought by them for matters related to this Consent Decree they will notify the
United States in writing no later than 60 days prior to the initiation of such suit or claim.
94. The Settling Defendants also agree that with respect to any suit or claim for
contribution brought against them for matters related to this Consent Decree they will notify in
writing the United States within 10 days of service of the complaint on them. In addition,
Settling Defendants shall notify the United States within 10 days of service or receipt of any
Motion for Summary Judgment and within 10 days of receipt of any order from a court setting a
case for trial.
95; In any subsequent administrative or judicial proceeding initiated by the United
States for injunctive relief, recovery of response costs, or other appropriate relief relating to the
Site, Settling Defendants shall not assert, and may not maintain, any defense or claim based upon
the principles of waiver, res judicata, collateral estoppel, issue preclusion, claim-splitting, or
other defenses based upon any contention that the claims raised by the United States in the
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE --71 -
20 40926-0080117 i Mary HoUinrake P:88/120 11:57AM
Kent CntyJII Rgstr 09/26/2014 SEAL
subsequent proceeding were or should have been brought mlBe instant case; provided, however,
that nothing in this Paragraph affects the enforceability of the covenants not to sue set forth in
Section XXI (Covenants Not to Sue by Plaintiff).
X X I V . ACCESS TO INFORMATION •
96. Settling Defendants shall provide to EPA, upon request, copies of all documents
and information within their possession or control or that of their contractors or agents relating to
activities at the Site or to the implementation of this Consent Decree, including, but not limited
to, sampling, analysis, chain of custody records, manifests, trucking logs, receipts, reports,
sample traffic routing, correspondence, or other documents or information related to the Work.
Settling Defendants shall also make available to EPA, for purposes of investigation, information
gathering, or testimony, their employees, agents, or representatives with knowledge of relevant
facts concerning the performance of the Work.
97. a. Settling Defendants may assert business confidentiality claims covering part or
all of the documents or information submitted to Plaintiff under this Consent Decree to the extent
permitted by and in accordance with Section 104(e)(7) of C E R C L A , 42 U.S.C. § 9604(e)(7), and
40 C.F.R. § 2.203(b). Documents or information determined to be confidential by EPA will be
afforded the protection specified in 40 C.F.R. Part 2, Subpart B. If no claim of confidentiality
accompanies documents or information when they are submitted to E P A or i f EPA has notified
Settling Work Defendants that the documents or information are not confidential under the
standards of Section 104(e)(7) of C E R C L A , the public may be given access to such documents
or information without further, notice to Settling Defendants.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 72
iii Mi Nil MM 20 40926-0080 17
• Mary HoUinrake P:89/120 11:57flM i rp, o T - N j + Kent Cnty MI Rgstr 09/26/2014 SEflL , ,
b. The Settling Defendants may- a 0 3 C i r orac ccnam aoramcnxs. records and other
information are privileged under the attorney-client privilege or any other privilege recognized
by federal law. If the Settling Defendants assert such a privilege in lieu of providing documents,
they shall provide the Plaintiff with the following: (1) the title ofthe document, record, or
information; (2) the date of the document, record, or information; (3) the name and title of the
author of the document, record, or information; (4) the name and title of each addressee and
recipient; (5) a description of the contents of the document, record, or information: and (6) the
privilege asserted by Settling Work Defendants. However, no documents, reports or other
information created or generated pursuant to the requirements of the Consent Decree shall be
withheld on the grounds that they are privileged.
98. No claim of confidentiality shall be made with respect to any data, including, but
not limited to, all sampling, analytical, monitoring, hydro geologic, scientific, chemical, or *
engineering data, or any other documents or information evidencing conditions at or around the
Site.
X X V . RETENTION OF RECORDS
99. a. Until 10 years after the Settling Defendants' receipt of EPA's notification
pursuant to Paragraph 51 .b of Section X I V (Certification of Completion ofthe Work), each
Settling Defendant shall preserve and retain all records and documents now in its possession or
control or which come into its possession or control that relate in any manner to the performance
of the Work or liability of any person for response actions conducted and to be conducted at the
Site, regardless of any corporate retention policy to the contrary. Until 10 years after the Settling
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 73
1I1IIUIIIIIIII1IIIIIIIIIIIIIIIIIIIII1 20 140926-0080117
Mary HoUinrake P:90/120 11:57P,M Kent Cnty HI Rgstr09/26/2014 SEAL
Defendants' receipt of EPA's notification pursuant to Paragraph 51.b of Section XIV
(Certification of Completion), Settling Defendants shall also instruct their contractors and agents
to preserve all documents, records, and information of whatever kind, nature or description
relating to the performance of the Work.
100. At the conclusion of this document retention period, Settling Defendants shall
notify the United States at least 90 days prior to the destruction of any such records or
documents, and, upon request by the United States, Settling Defendants shall deliver any such
records or documents to EPA. The Settling Defendants may assert that certain documents,
records and other information are privileged under the attorney-client privilege or any other
privilege recognized by federal law. If the Settling Defendants assert such a privilege, they shall
provide the Plaintiffs with the following: (1) the title of the document, record, or information;
(2) the date of the document, record, or information; (3) the name and title of the author of the
document, record, or information; (4) the name and title of each addressee and recipient; (5) a
description of the subject ofthe document, record, or information; and (6) the privilege asserted
by Settling Defendants. However, no documents, reports or other information created or
generated pursuant to the requirements of the Consent Decree shall be withheld on the grounds
that they are privileged.
101. Each Settling Defendant hereby certifies individually that, to the best of its
knowledge and belief, after thorough inquiry, it has not altered, mutilated, discarded, destroyed
or otherwise disposed of any records, documents or other information relating to its potential
liability regarding the Site since notification of potential liability by the United States or the State
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 74
f
ni III iiniiiiiiiiwiwiiiiii 20140926-0080117
Mary HoUinrake P:91/120 11:57AM 4 , c , . r- • , .Kent Cnty MI Rgstr 09/25/2014 SEflL
or the filing of suit against it regarding toe OTTC ana mar it nas lully complied with any and all
E P A requests for information pursuant to Sections 104(e) and 122(e) of C E R C L A , 42 U.S.C.
§§ 9604(e) and 9622(e), and Section 3007 of RCRA, 42 U.S.C. § 6927.
X X V I . NOTICES A N D SUBMISSIONS
102. Whenever, under the terms of this Consent Decree, written notice is required to be
given or a report or other document is required to be sent by one Party to another, it shall be
directed to the individuals at the addresses specified below, unless those individuals or their
successors give notice of a change to the.other Parties in writing.. A l l notices and submissions
shall be considered effective upon receipt, unless otherwise provided. Written notice as specified
herein shall constitute complete satisfaction of any written notice requirement of the Consent
Decree with respect to the United States, EPA, and the Settling Defendants respectively.
As to the United States:
Chief, Environmental Enforcement Section
Environment and Natural Resources Division U.S. Department of Justice P.O. Box 7611 Ben Franklin Station Washington, D.C. 20044 Re: DOJ 90-11-3-145A As to EPA
Director, Superfund Division United States Environmental Protection Agency Region V 77 W. Jackson Ave (Mail Code SR-6J) Chicago, IL 60604
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 75
IIIIIIII IIIIIIIIIIIJI1I1II 20140926-0080117 Mary HoUinrake P:92/120 11= 5™M
Dion Novak Kent Cnty MI Rgstr 09/26/2014 SEAL
EPA Project Coordinator United States Environmental Protection Agency Region 5 77 W. Jackson Ave (Mail Code SR-6J) Chicago, IL 60604
As to the State:
Robert L . Franks Superfund Section Environmental Response Section Michigan Department of Environmental Quality Knapps Centre PO Box 30426 Lansing, MI 48909-7926 (517) 335-3392
As to the Settling Work Defendants:
Linda Hicken RMT, Inc. 744 Heartland Trail Madison, W l 53717
As to the Settling Cash Defendants:
The persons identified as designated agents for service of process for each Settling Cash Defendant on the corresponding signature page to this Consent Decree.
As to Settling Owner Defendants:
The persons identified as designated agents for service of process for each Settling Owner Defendant on the corresponding signature page to this Consent Decree.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 76 -
: IIIIIIII IIIHIUHip 20140926-0080117
: Mary HoUinrake P:93/120 11:57PM Kent Cnty ill Rgstr 09/25/2014 SEftL
X X V I I EFFECTIVE D A T E
103. The effective date of this Consent Decree shall be the date upon which this
Consent Decree is entered by the Court, except as otherwise provided herein.
XXVIII . RETENTION OF JURISDICTION
104. This Court retains jurisdiction over both the subject matter of this Consent Decree
and the Settling Defendants for the duration of the performance of the terms and provisions of
this Consent Decree for the purpose of enabling any of the Parties to apply to the Court at any
time for such further order, direction, and relief as may be necessary or appropriate for the
construction or modification of this Consent Decree, or to effectuate or enforce compliance with
its terms, or to resolve disputes in accordance with Section X I X (Dispute Resolution) hereof.
X X I X . APPENDICES
105. The following appendices are attached to and incorporated into this Consent
Decree:
"Appendix A " is the ROD.
"Appendix B" is the Statement of Work (SOW).
"Appendix C" is the October 1998 Explanation of Significant Differences, as amended
on December 23, 1998.
"Appendix D" is the description and/or map of the Site.
"Appendix E" is the complete list of the Settling Defendants.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 77
20 40926-0080117 : Mary HoUinrake P;94/120 11:57AM
Kent Cnty MI Rgstr09/26/2014 SEflL
X X X . COTvIMUMTTRELATIOT^S
106. Settling Work Defendants shall propose to E P A their participation in the
community relations plan to be developed by EPA. E P A wil l determine the appropriate role for
the Settling Work Defendants under the Plan. Settling Work Defendants shall also cooperate
with EPA in providing information regarding the Work to the public. As requested by EPA,
Settling Work Defendants shall participate in the preparation of such information for
dissemination to the public and in public meetings which may be held or sponsored by E P A to
explain activities at or relating to the Site.
X X X I . MODIFICATION
107. Schedules specified in this Consent Decree for completion of the Work may be
modified by agreement of EPA and the Settling Work Defendants. A l l such modifications shall
be made in writing.
108. Except as provided in Paragraph 13 ("Modification of the Remedial Design
Document or related Work Plans"), no material modifications shall be made to the SOW without
written notification to and written approval of the United States, Settling Defendants, and the
Court. Prior to providing its approval to any modification, the United States will provide the
State with a reasonable opportunity to review and comment on the proposed modification.
Modifications to the SOW that do not materially alter that document may be made by written
agreement between EPA, after consultation with the State, on the proposed modification, and the
Settling Work Defendants.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - - 7 8
IIIIIIII 20140926-0080117
. Mary HoUinrake P:95/120 11:57P.M
109. Nothing in this Decree Srrau xictsmctt X C T and ai\^ \^oxtrt's power to enforce,
supervise or approve modifications to this Consent Decree.
XXXII . LODGING A N D OPPORTUNITY FOR P U B L I C C O M M E N T
110. This Consent Decree shall be lodged with the Court for a period of not less than •
thirty (30) days for public notice and comment in accordance with Section 122(d)(2) of
C E R C L A , 42 U.S.C. § 9622(d)(2), and 28 C.F.R. § 50.7. The United States reserves the right to
withdraw or withhold its consent i f the comments regarding the Consent Decree disclose facts or
. considerations which indicate that the Consent Decree is inappropriate, improper, or inadequate.
Settling Defendants consent to the entry of this Consent Decree without further notice.
111. If for any reason the Court should decline to approve this Consent Decree in the
form presented, this agreement is voidable at the sole discretion of any Party and the terms of the
agreement may not be used as evidence in any litigation between the Parties.
XXXIII . SIGNATORIES/SERVICE
112. Each undersigned representative of a Settling Defendant to this Consent Decree
and the Assistant Attorney General of Environment and Natural Resources Division of the
Department of Justice certifies that she is fully authorized to enter into the terms and conditions
of this Consent Decree and to execute and legally bind such Party to this document.
113. Each Settling Defendant hereby agrees not to oppose entry of this Consent Decree
by this Court or to challenge any provision of this Consent Decree unless the United States has
notified the Settling Defendants in writing that it no longer supports entry of the Consent Decree.
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 79
I I I I I I I I IIIIIIIIIIII • I I I I I I I I I I I I : 20140926-0080117
Mary HoUinrake P:96/120 11:57P.M Kent Cnty MI Rgstr_09/26/2014 SEflL
114. Each Settling Defendant snail identity, on me attached signature page, the name,
address and telephone number of an agent who is authorized to accept service of process by mail
on behalf of that Party with respect to all matters arising under or relating, to this Consent Decree.
Settling Defendants hereby agree to accept service in that manner and to waive the formal
service requirements set forth in Rule 4 of the Federal Rules of Civil Procedure and any
applicable local rules of this Court, including, but not limited to, service of a summons.
SO ORDERED THIS D A Y OF ,19. .
United States District Judge
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 80
IIIIIIIIIIII 20140926-0080117
i Mary HoUinrake P-.97/120 11 :57flM
THE UNDERSIGNED ?A^^%^R£l^'^Jl£L^cree in the matter of United States v. Allied Waste Systems, Inc, et al., (W.D. Michigan), relating to the Butterworth Landfill Superfund Site.
FOR THE UNITED STATES OF A M E R I C A
Date: LOIS J. SCHIFFER Assistant Attorney General Environment and Natural Resources Division U.S. Department of Justice . Washington, D.C. 20530
K A R E N E. TORRENT Trial Attorney Environmental Enforcement Section Environment and Natural Resources Division U.S. Department of Justice P.O. Box 7611 Washington, DC 20044-7611
M I C H A E L DETTMER United States Attorney for the Western District of Michigan
Dated: W. F R A N C E S C A FERGUSON Assistant United States Attorney For the Western District of Michigan P.O. Box 208 Grand Rapids, Michigan 49501-0208 (616)456-2404
United States v. Allied (faste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 81
Date:
IIIIIIIIIIII IIIIIIIIIIIIIIUIIIIIIIUIIIII 20140926-0080117
Mary HoUinrake P:98/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEflL
WILLIAM E. M U N O Director, Superfund Division, Region V U.S. Environmental Protection Agency 77 West Jackson Chicago, Illinois 60604
SEAN M U L R O N E Y LESLIE K I R B Y Assistant Regional Counsels U.S. Environmental Protection Agency 77 West Jackson Boulevard
Chicago, Illinois 60604
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 82
Ullllllllll I I I I I I I I I I I I IIIIIIIIIIII 20140926-0080117
Mary HoUinrake P:99/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL.
THE UNDERSIGNED PAR I IbS enter into this Consent Decree in the matter of United States v. Allied Waste Systems, Inc.et al., (W.D. Michigan), relating to the Butterworth Landfill Superfund Site.
FOR C O M P A N Y , INC.
Date: [Name ~ Please Type] [Title — Please Type] [Address ~ Please Type]
Agent Authorized to Accept Service on Behalf of Above-signed Party:
Name: [Please Type] Title: Address: Tel. Number
United States v. Allied Waste Systems, e t . a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE - 83
IN T H E U N I T E D STATES DISTRICT C O U R T F O R T H E W E S T E R N DISTRICT OF M I C H I G A N
S O U T H E R N DIVISION
U N I T E D STATES OF A M E R I C A ,
Plaintiff,
ALLIED WASTE SYSTEMS, INC. et al.,
Defendants.
20140926-0080117 Mary HoUinrake PM00/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
C I V I L ACTION NO.
C O N S E N T D E C R E E
APPENDICES
Appendix A: Record of Decision (ROD)
Appendix B: Statement of Work (SOW)
Appendix C: October 1998 Explanation of Significant Differences, as amended on December 23,1998.
Appendix D: Map of the Site
Appendix E: List of Settling Defendants
E.1. Settling Cash Defendants
E.2. Settling Owner Defendants
E.3." Settling Work Defendants
United States v. Allied Waste Systems, Inc.,et a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE
APPENDIX A : Record of Decision (ROD)
20 40926-0080117 Mary HoUinrake P:101/120 11:57flM Kent Cnty MI Rgstr09/26/2014 SEAL
United States v. Allied Butterworth #2 Landfill CONSENT DECREE
Waste Systems, Xnc.,et a l . Superfund Site
Appendix B: Statement pf Work (SOW)
20 Tdaaoa' "A'A'Ji'lS I HI ll
United States v. Allied Waste Systems, Inc., et a l . Butterworth #2 Landfill Superfund Site CONSENT DECREE
Appendix C: October 1998 Explanation of Significant Differences , as amended on December 23,1998.
IIIIIIII I I I I I I I I I IIII I flfl 11 IIIII 20140926-0080117
Mary HoUinrake P:103/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEftL
United States v. Allied Waste Systems, I n c . e t a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE
A P P E N D I X D: Map ofthe Butterworth Landfi l l No. 2 Superfund Site
IIIIIIII IIIIIIIIIIII l i l l l l l l l l l 20140926-0080117
Mary HoUinrake P:104/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
United States v. Allied Waste Systems, Inc., et a l . Butterworth #2 Landfill Superfund Site
CONSENT DECREE
20140926-0080117 Mary HoUinrake P:105/120 11:57P.M Kent Cnty MI Rgstr09/26/2014 SEAL
APPENDIX E : LIST OF S E T T L I N G DEJFK^DATSTS""' "
1. Settling Cash Defendants
American Premier Underwriters, Inc. (f/k/a The Penn Central Corporation)
Amway Corporation
BASF Corporation, successor in interest to Inmont Corporation
Bemis Company, Inc. (on behalf of Sackner Products)
Bissell, Inc. (for itself, Imperial Business Forms and Michigan Tag Company)
Blackmer-Dover Resources Company (f/k/a Blackmer Pump Company)
Building Repair of Grand Rapids Inc.
C. Stoddard & Sons
Dayton Walther Corporation ( on behalf of Wolverine Brass Company)
Evans Tempcoh, Inc.
Gallmeyer & Livingston Co.
Haviland Products Company
Ingersoll-Rand Company (on behalf of Clark Equipment Company and Tyler Refrigeration Corporation)
Keebler Company
La-2-Boy, Inc. (on behalf of Rose Manufacturing Company)
Lilly Industries, Inc. (for Guardsman Products, Inc.)
Mannesmann Dematic Rapistan Corporation (for Rapistan Demag Corp.)
Master Lock Company (f/k/a Dexter Lock Company)
Master Finish Company
United States v. Allied Waste Systems, Inc., et al. Butterworth #2 Landfill Superfund Site
CONSENT DECREE
i IIIIIII iiiiiiiiiiiiniiiimi 20140926-0080117
Midwest Plating Company j&y cnty*iiiaRgstr09/26/201V : SEAL
Monarch Hydraulics, Inc. Owens-Corning Fiberglass Corporation
Plastic Plate Inc., a division of,Lacks Enterprises Inc.
Pridgeon & Clay Inc.
Reliance Finishing Company ( f/k/a National Plating Company)'
Ryder Truck Rental (f/k/a Atlas Rent-A-Truck)
State Heat Treat, Inc.
The Goodyear Tire and Rubber Company
Viacom International, Inc. (on behalf of Furniture City Manufacturing Company and Furniture City Plating Company)
2. Settling Owner Defendants
City of Grand Rapids
Consumers Energy Company (formerly Consumers Power Company)
3. Settling Work Defendants
Allied Waste Systems, Inc.
City of Grand Rapids
CSX Transportation, Inc.
Consumers Energy Company (formerly Consumers Power Company)
DaimlerChrylser Corporation (for Kelvinator)
United States v. Allied Waste Systems, Inc.,et al. Butterworth #2 Landfill Superfund Site CONSENT DECREE
UP Jll'il i l l ill I'll III'ill ill ill11 1 A / r t r t. 2M4M26~0080117
General Motors Corporation M a r y H o l l i n r a k e P : 1 0 7 / 1 2 0 i i * ? ™ Kent Cnty MI Rgstr09/26/2014 SEflL
Metromedia International Group, Inc.(for American Seating Company) Rowe International, Inc.
Tenneco Packaging, Inc. (For Packaging Corporation of America)
Steelcase Inc. (For Steelcase Inc, Attwood Brass (currently known as Attwood Corporation) and Stow and Davis)
Wickes Manufacturing Company (on behalf of Michigan Plating & Stamping Company,-a/k/a Michigan Bumper Company, and on behalf of Crampton Manufacturing Company).
Waste. Management of Michigan, Inc., on behalf of itself, United Waste, Folkertsma Refuse Service, Kamps Bros. Refuse Inc., Industrial Disposal Comp., Chemical Waste Management, Able Sanitation, and on behalf of but without admitting liability for Pete's Disposal and Wilson's Disposal., for purposes of this agreement only, hereinafter, "Waste Management." Waste Management does not include United Sanitation, or United Collection Systems of Grand Rapids.
White Consolidated IndustrieSj Inc. (for Kelvinator)
Wolverine World Wide Inc.
United States v. Allied Waste Systems, Inc.,et al. Butterworth #2 Landfill Superfund Site
CONSENT DECREE
~> : IIIIIIII I I I I I I I I I I I I ) 20140926-0080117
Mary HoUinrake P:1O8/120 11:570M Kent Cnty MI Rgstr09/26/2014 SEflL
STATEMENT OF WORK FOR THE REMEDIAL ACTION
BUTTERWORTH #2 LANDFILL SITE
GRAND RAPIDS, KENT COUNTY, MICHIGAN
I . PURPOSE
The purpose o f t h i s Statement o f Work (SOW) i s t o s e t f o r t h r e q u i r e m e n t s f o r i m p l e m e n t a t i o n o f t h e r e m e d i a l a c t i o n s e t f o r t h i n t h e R e c o r d o f D e c i s i o n (ROD), and f u r t h e r d e f i n e d i n t h e Amended Remedial D e s i g n P r o j e c t P l a n (ARDPP). The ROD was s i g n e d by t h e R e g i o n a l A d m i n i s t r a t o r o f t h e U n i t e d S t a t e s E n v i r o n m e n t a l P r o t e c t i o n Agency (EPA) R e g i o n V on September 29, 1992, f o r t h e B u t t e r w o r t h #2 L a n d f i l l S i t e ( S i t e ) . On October 23, 1998,.U.S. EPA approved t h e E x p l a n a t i o n o f S i g n i f i c a n t D i f f e r e n c e s (ESD) t h a t amended t h e ROD t o i n c l u d e g r o u n d w a t e r - s u r f a c e w a t e r i n t e r f a c e c r i t e r i a and r e q u i r e m e n t s f o r a s o i l c o v e r o v e r the R a d i o Tower and S t a t i o n B u i l d i n g a r e a ( S e e Attachment A ) . The S e t t l i n g D e f e n d a n t s s h a l l f o l l o w t h e ROD, t h e ESD, t h e SOW., t h e approved R e m e d i a l D e s i g n Work P l a n , t h e ARDPP, the approved R e m e d i a l A c t i o n Work P l a n , EPA Sup e r f u n d Remedial D e s i g n and Reme d i a l A c t i o n Guidance and any a d d i t i o n a l guidance p r o v i d e d by EPA i n s u b m i t t i n g d e l i v e r a b l e s f o r i m p l e m e n t i n g t h e r e m e d i a l a c t i o n a t • t h e S i t e .
I I . DESCRIPTION OF THE REMEDIAL ACTION/PERFORMANCE STANDARDS
S e t t l i n g D e f e n d a n t s s h a l l meet the f o l l o w i n g performance s t a n d a r d s and s p e c i f i c a t i o n s f o r t h e r e m e d i a l a c t i o n a t t h i s s i t e .
1. I n s t i t u t i o n a l C o n t r o l s • •
I n s t i t u t i o n a l c o n t r o l s i n c l u d e r e s t r i c t i o n s t o c o n t r o l f u t u r e . development o f t h e l a n d f i l l a r e a and t o p r o h i b i t -the i n s t a l l a t i o n o f w a t e r s u p p l y w e l l s w i t h i n an a r e a around t h e s i t e t o be d e f i n e d i n c o n s u l t a t i o n w i t h t h e EPA and t h e M i c h i g a n Department o f E n v i r o n m e n t a l Q u a l i t y (MDEQ). T h i s a r e a w i l l be d e f i n e d i n th e Remedial A c t i o n work p l a n s u b m i t t a l , as r e q u i r e d under S e c t i o n V o f t h i s SOW.
2. E s t a b l i s h A l t e r n a t e C o n c e n t r a t i o n L i m i t s
M i x i n g zone based g r o u n d w a t e r - s u r f a c e w a t e r i n t e r f a c e (GSI) c r i t e r i a w i l l be used as the A l t e r n a t e C o n c e n t r a t i o n L i m i t s (ACL) f o r groundwater a t the s i t e . These c r i t e r i a were d e v e l o p e d f o r t h i s s i t e u nder Michigan'.s P a r t 201 program and t h e i r development
1
mil> 2 ¥ l 4 0 9 2 6 - M 8 0 1 1 7 1
s h a l l r e p l a c e the methodology f o r e s t a b l i s h i n g - A C L s t h a t was s p e c i f i e d i n t h e ROD. I n a d d i t i o n , t h e ACL performance-m o n i t o r i n g program s p e c i f i e d i n t h i s SOW r e p l a c e s t h e s u r f a c e w a t e r , r i v e r sediment, and b i o l o g i c a l m o n i t o r i n g programs a l s o s p e c i f i e d i n t h e ROD.
.'The use o f m i x i n g zone based GSI c r i t e r i a as t h e ACLs f o r . groundwater a t the s i t e i s a p p r o p r i a t e because t h e GSI c r i t e r i a a r e a more d i r e c t measure o f p o t e n t i a l a d v e r s e impacts o f t h e l a n d f i l l on s u r f a c e w a t e r t h a n the ACL methodology and m o n i t o r i n g programs t h a t a re s p e c i f i e d i n the ROD. A f t e r t h e i s s u a n c e o f the ROD, t h e GSI c r i t e r i a were d e v e l o p e d b y the S t a t e o f M i c h i g a n f o r t h e s p e c i f i c p u r p o s e o f e v a l u a t i n g p o t e n t i a l adverse i m p a c t s a s s o c i a t e d w i t h g r o u n d w a t e r v e n t i n g t o s u r f a c e w a t e r . These v a l u e s a r e r i s k - b a s e d c r i t e r i a t h a t were d e v e l o p e d t o p r o t e c t human h e a l t h and a q u a t i c l i f e ' . (See T a b l e 1) Three c r i t e r i a l i s t e d i n T a b l e 1 a r e not f i n a l i z e d f o r t h e s i t e . When, t h e s e t h r e e c r i t e r i a a r e f i n a l i z e d by t h e S t a t e o f M i c h i g a n f o r t h e s i t e , t h e y w i l l r e p l a c e t h e marked e n t r i e s .
3. Development and I m p l e m e n t a t i o n o f ACL Performance M o n i t o r i n g Program
The ACL performance m o n i t o r i n g program s h a l l be deve l o p e d and implemented t o en s u r e t h e c o n t i n u e d absence o f impact from t h e S i t e on the Grand R i v e r . T h i s m o n i t o r i n g program s h a l l be d e s i g n e d t o d e t e c t c o n t a m i n a n t s , changes i n contaminants c h a r a c t e r i s t i c s , i n c l u d i n g i n c r e a s e s and d e c r e a s e s i n hazardous s u b s t a n c e s , p o l l u t a n t s and contaminants i n t h e upper a q u i f e r a t and n e a r t h e s i t e .
ACL performance m o n i t o r i n g s h a l l i n c l u d e i n s t a l l a t i o n , c o l l e c t i o n o f samples and f i e l d and l a b o r a t o r y a n a l y s i s o f samples from 17 ACL w e l l l o c a t i o n s r e q u i r e d by the ROD, i n c l u d i n g a n e s t e d s e n t i n e l w e l l ' a t a minimum o f 4 ACL w e l l l o c a t i o n s , two t o f i v e a d d i t i o n a l GSI w e l l s s o u t h o f t h e RTSB a r e a , and t h r e e l e a c h a t e m o n i t o r i n g w e l l s i n t h e RTSB a r e a . These w e l l s w i l l be i d e n t i f i e d i n the R e m e d i a l A c t i o n Work p l a n s u b m i t t a l . A l t e r n a t e performance m o n i t o r i n g l o c a t i o n s f o r b i o l o g i c a l oxygen demand (BOD) and ammonia may be proposed i n t h e R e m e d i a l A c t i o n Workplan f o r c o m p l i a n c e p u r p o s e s .
Ground-water s h a l l be a n a l y z e d f o r o r g a n i c and i n o r g a n i c a n a l y t e s from EPA's Ta r g e t Compound L i s t and T a r g e t A n a l y t e L i s t (see
. T a b l e 3-2 o f the EPA ap p r o v e d RD workplan) q u a r t e r l y f o r a t l e a s t one (1) y e a r . At t h e end o f the one (1) y e a r p e r i o d , the Respondents may p e t i t i o n EPA t o mod i f y t h e groundwater m o n i t o r i n g network.
ACL performance m o n i t o r i n g s h a l l b e g i n and c o n t i n u e f o r t h i r t y (30) y e a r s a f t e r t h e c o m p l e t i o n o f c o n s t r u c t i o n o f the l a n d f i l l c o v e r a t the s i t e . A t t h e end o f the 30 y e a r m o n i t o r i n g p e r i o d ,
2
. 3 IIIIIII Ull|lli|l|< 20140926-008011'
M , u „ i i i n r a l t p P-110/120 11:57P.M S t f S t y Rl !?.t Pr 09/26/2014 SEAL .
EPA s h a l l - determine the need t o ex t e n d t h e p e r i o d o f m o n i t o r i n g .
Groundwater Contingency P l a n I f , a t any ti m e , a d d i t i o n a l i n f o r m a t i o n i n d i c a t e s t h e groundw a t e r m o n i t o r i n g program s h o u l d be changed, EPA may r e q u i r e m o d i f i c a t i o n s t o the program. M o d i f i c a t i o n s , may i n c l u d e , but a r e no t l i m i t e d t o , a change i n t h e number o f ground-water m o n i t o r i n g w e l l s t o be sampled, i n s t a l l a t i o n o f a d d i t i o n a l ground-water m o n i t o r i n g w e l l s , change i n t h e s e l e c t e d l a b o r a t o r y p arameters a n d / o r the compounds and a n a l y t e s w h i c h s h a l l be m o n i t o r e d .
I f , a t any time,, the r e s u l t s o f t h e groundwater m o n i t o r i n g program i n d i c a t e t h a t t he co n t a m i n a n t s i n t h e a q u i f e r exceed t h e ACLs s p e c i f i e d i n Table 1 i n t h e 17'GSI w e l l s and t h e a d d i t i o n a l 2-5 GSI w e l l s i d e n t i f i e d i n t h e Remedial A c t i o n Work p l a n , Rspondents s h a l l i m m e d i a t e l y p r o c e e d w i t h - t h e a c t i o n s d e s c r i b e d i n t h e c o n t i n g e n c y p l a n , t o be s u b m i t t e d under S e c t i o n V o f t h i s SOW as p a r t o f the Remedial A c t i o n Work p l a n s u b m i t t a l . These a c t i v i t i e s s h a l l i n c l u d e a d d i t i o n a l s a m p l i n g t o v e r i f y t h e exceedance, a d d i t i o n a l groundwater assessment t o determine t h e s o u r c e , n a t u r e , and e x t e n t o f t h e exceedance, and c o r r e c t i v e a c t i o n s n e c e s s a r y t o m i t i g a t e . t h e impact o f an ACL exceedance on t h e Grand R i v e r o r a t h r e a t t o human h e a l t h and the environment. C o r r e c t i v e a c t i o n s i n c l u d e , but a r e n ot l i m i t e d t o , t he f o l l o w i n g :
• i d e n t i f i c a t i o n and removal o f a s o u r c e h o t s p o t , i n s t a l l a t i o n of s l u r r y w a l l s t o reduce o r e l i m i n a t e i n t e r a c t i o n between t h e groundwater and t h e Grand R i v e r , and/or i n s t a l l a t i o n o f a groundwater e x t r a c t i o n system. S e t t l i n g Defendants s h a l l submit d e s i g n documents f o r t h e proposed response a c t i o n f o r EPA r e v i e w and a p p r o v a l .
The t h r e e l e a c h a t e w e l l s d e s c r i b e d above w i l l n o t be p o i n t s o f com p l i a n c e . These w e l l s w i l l be used as s e n t i n e l m o n i t o r i n g p o i n t s t o a s s e s s t e m p o r a l changes i n l e a c h a t e q u a l i t y and h y d r a u l i c head. A t the n e s t e d GSI w e l l l o c a t i o n s . (MZ-10, MZ-11, MZ-21, MZ-22) , t h e w e l l i n t h e w e l l n e s t t h a t i s s c r e e n e d t h r o u g h the waste w i l l a l s o be a s e n t i n e l m o n i t o r i n g p o i n t , and not a p o i n t of compliance. I f a s a m p l i n g r e s u l t from any o f t h e t h r e e l e a c h a t e w e l l s , o r the n e s t e d GSI w e l l s c r e e n e d t h r o u g h t h e waste, exceeds the GSI c r i t e r i a s p e c i f i e d i n T a b l e 1, t h e n a d d i t i o n a l assessment o f w e l l s c r e e n l o c a t i o n s s h a l l be p e r f o r m e d t o ensure t h a t t h e GSI w e l l coverage i s adequate t o a c c u r a t e l y d e t e c t any m i g r a t i o n o f the exceedance from t h e s e n t i n e l w e l l s t o w a r d s the Grand R i v e r .
The d a t a f o r the GSI w e l l s s o u t h o f t h e RTSB a r e a (as i d e n t i f i e d i n t h e Remedial A c t i o n w o r k p l a n s u b m i t t e d p u r s u a n t t o S e c t i o n V of t h i s SOW). w i l l a l s o be use d t o ev a l u a t e - t h e adequacy o f t h e
3
IIIIIIIIII1
20140926-0080117 Mary Hoi1inrake P:111/120 11:57PM Kent Cnty MI Rgstr09/26/2014 SEAL
s o i l c o v e r o v e r t h e RTSB a r e a . I f ah exceedance o f an ACL, as l i s t e d i n T a b l e 1, i s i d e n t i f i e d i n any o f t h e s e w e l l s , S e t t l i n g D e f e n d a n t s s h a l l i m m e d i a t e l y p r o c e e d w i t h t h e a c t i o n s d e s c r i b e d i n t h e c o n t i n g e n c y p l a n , t o be s u b m i t t e d under S e c t i o n V o f t h i s SOW as p a r t o f the Remedial A c t i o n Work p l a n s u b m i t t a l . I f th e s e a c t i v i t i e s c o n f i r m t h i s exceedance, t h e n S e t t l i n g Defendants s h a l l c o v e r t h e RTSB a r e a w i t h a S t a t e o f M i c h i g a n A c t 641 c l a y cap, as d e s c r i b e d i n t h e ROD and t h i s SOW. I f ACL exceedances a r e c o n f i r m e d b e f o r e t h e s o i l c o v e r i s i n s t a l l e d , t h e n S e t t l i n g D e f e ndants s h a l l p l a c e t h e c l a y c o v e r o v e r t h e RTSB a r e a a t t h e same time as on the r e s t o f t h e l a n d f i l l .
4. L a n d f i l l Cover
As d e s c r i b e d i n t h e Amended RDPP and t h e ESD, a l a n d f i l l c o v e r w i l l be c o n s t r u c t e d t o cap a l l l a n d f i l l e d w a s t e s a t the s i t e o u t s i d e o f t h e Radio Tower and S t a t i o n B u i l d i n g (RTSB) a r e a . The c o v e r w i l l c o n s i s t o f , from t o p t o bottom:
A v e g e t a t i v e s o i l l a y e r c o n s i s t i n g o f a minimum o f 6 i n c h e s o f t o p s o i l . Seed and f e r t i l i z e r w i l l be a p p l i e d t o t h i s l a y e r t o e s t a b l i s h v e g e t a t i o n .
An 18 i n c h t h i c k r o o t i n g zone l a y e r . T h i s l a y e r w i l l p r o t e c t the u n d e r l y i n g compacted c l a y l a y e r from f r o s t p e n e t r a t i o n e x p e c t e d i n t h e Grand R a p i d s a r e a .
A l o w p e r m e a b i l i t y c l a y l a y e r , w i t h a minimum t h i c k n e s s ' o f 24 i n c h e s . T h i s l a y e r w i l l be c o n s t r u c t e d t o red u c e i n f i l t r a t i o n t h r o u g h the waste, as s e t f o r t h S o l i d Waste Management A c t 641 (1978), as amended, M i c h i g a n Code o f Laws (MCL) S e c t i o n s 299.401 t h r o u g h 299.436.
Respondents s h a l l p l a c e a s o i l c o v e r o v e r t h e RTSB are a , i d e n t i f i e d on F i g u r e 1. The s o i l c o v e r w i l l be a minimum o f 12 i n c h e s t h i c k , and w i l l i n c l u d e t h e f o l l o w i n g two l a y e r s :
• The lo w e r s i x i n c h e s w i l l c o n s i s t o f l e a n c l a y and s i l t y c l a y (approximate p e r m e a b i l i t y o f 4.0 x 10 (-7) cm/sec)
9 The upper s i x i n c h e s w i l l be a t o p s o i l l a y e r s u i t a b l e f o r growth o f a v e g e t a t i v e c o v e r ( a p p r o x i m a t e p e r m e a b i l i t y o f 7.2 x 10 (-4) cm/sec)
S e t t l i n g Defendants s h a l l ensure t h a t t h e v e g e t a t i v e growth e s t a b l i s h e d i n t h e upper t o p s o i l l a y e r s h a l l n o t impact t h e i n t e g r i t y o r p e r m e a b i l i t y of t h e l o w e r s i x i n c h l a y e r i n t h e RTSB a r e a .
The s l o p e o f t h e f i n a l c o v e r w i l l r e s u l t i n s u r f a c e water r u n o f f from t h e s i t e v i a s h e e t f l o w and c u l v e r t s t o t h e a d j a c e n t b o d i e s of w a t e r .
4
D IIIIIIIIIIII II,I IIIIII I Willi llil 1 20140926-0080117
; Mary HoUinrake P: 112/120 11:57P,M Kent Cnty MI Rgstr 09/26/2014 SEftL
O t h e r components o f the l a n d f i l l c o v e r system i n c l u d e the f o l l o w i n g , , as d e s c r i b e d i n t h e EPA approved RDPP:
L a n d f i l l gas management F l o o d w a y / f l o o d p l a i n p r o t e c t i o n Permanent e r o s i o n and s e d i m e n t a t i o n c o n t r o l s F u g i t i v e d u s t c o n t r o l s
Adequate n o i s e and dust s u p p r e s s a n t measures s h a l l be tak e n t o p r o t e c t t h e community from t h e e f f e c t s o f c o n s t r u c t i o n . Adequate measures s h a l l be employed t o p r o t e c t s u r f a c e w a t e r s from s i l t a t i o n d u r i n g c o n s t r u c t i o n and p o s t - c l o s u r e o f t h e l a n d f i l l .
5 . M i t i g a t i o n o f Wetland
The r e m e d i a l a c t i o n s h a l l implement any and a l l approved d e s i g n p l a n s t h a t a d d r e s s and m i t i g a t e any w e t l a n d s i m p a c t e d by a c t i v i t i e s a t t h e S i t e i n accordance w i t h a p p l i c a b l e law. These p l a n s are d e s c r i b e d i n S e c t i o n 3 . 3 o f t h e RDPP.
6. Drum Removal and D i s p o s a l
The r e m e d i a l a c t i o n s h a l l implement t h e approved drum c o n t i n g e n c y p l a n ( p l a n ) d e v e l o p e d as p a r t o f the d e s i g n (Appendix A o f . t h e S i t e H e a l t h and S a f e t y P l a n - S e c t i o n B o f Volume 2 o f the EPA approved RDPP). The p l a n i d e n t i f i e s p r o c e d u r e s f o r t h e h a n d l i n g and d i s p o s a l o f drums uncovered d u r i n g a c t i v i t i e s c onducted as' p a r t o f t h i s a c t i o n .
I I I . SCOPE OF REMEDIAL ACTION
The Remedial A c t i o n (RA) s h a l l c o n s i s t o f f i v e t a s k s . A l l p l a n s • ar e s u b j e c t t o EPA a p p r o v a l a f t e r c o n s u l t a t i o n w i t h t h e MDEQ.
Task 1: Amended Remedial D e s i g n P r o j e c t P l a n Task 2: Remedial A c t i o n Work P l a n Task 3: Remedial A c t i o n / C o n s t r u c t i o n
A. P r e c o n s t r u c t i o n I n s p e c t i o n and M e e t i n g
B. P r e - f i n a l I n s p e c t i o n
C. F i n a l I n s p e c t i o n
D. R e p o r t s
1. C o m p l e t i o n o f C o n s t r u c t i o n R e p o r t 2 . C o m p l e t i o n of R emedial A c t i o n R e p o r t 3 . C o m p l e t i o n o f Work Report 4. P r o g r e s s R e p o r t s
5
oiiiisiiiiiiiiiiiiiinniiaiiinii 20140926-0080117
Mary HoUinrake P:113/120 11:57fiM Kent Cnty MI Rgstr09/26/2014 SEAL
E. Community R e l a t i o n s Support
Task 4: O p e r a t i o n and Maintenance Task 51 Performance M o n i t o r i n g
Task 1: Amended Remedial Design P r o j e c t P l a n s
T h i s p l a n i n c o r p o r a t e s a s o i l c o v e r o v e r t h e Ra d i o Tower and S t a t i o n B u i l d i n g (RTSB) Area, as i d e n t i f i e d i n F i g u r e 1, and a ' M i c h i g a n A c t 541 c o v e r o ver the o t h e r f i l l a r e a s .
The f o l l o w i n g s u p p o r t i n g p l a n s , w h i c h were i n c l u d e d i n t h e approved R e v i s e d F i n a l Remedial D e s i g n P r o j e c t P l a n ( F i n a l RDPP; F e b r u a r y 1998), a r e i n c l u d e d i n t h e ARDPP.
• F u g i t i v e Dust C o n t r o l and Ambient VOC M o n i t o r i n g P l a n • O p e r a t i o n and Maintenance P l a n ( f o r t h e l a n d f i l l c o v e r ,
s u r f a c e water c o n t r o l s , and t h e l a n d f i l l gas m o n i t o r i n g probes)
• S i t e H e a l t h and S a f e t y P l a n • Drum Co n t i n g e n c y P l a n .•. C o n s t r u c t i o n Q u a l i t y Assurance P r o j e c t P l a n
A p p l i c a b l e s e c t i o n s o f the approved Remedial D e s i g n Work p l a n (October 1995) w i l l be r e f e r e n c e d , i n c l u d i n g p a r t s o f t h e f o l l o w i n g :
* F i e l d Sampling and A n a l y s i s P l a n • Q u a l i t y A s s u r a n c e P r o j e c t P l a n
Task 2: Remedial A c t i o n Work P l a n
The S e t t l i n g Defendants s h a l l submit a d r a f t Remedial A c t i o n Work P l a n , which i n c l u d e s a d e t a i l e d d e s c r i p t i o n and s c h e d u l e f o r t h e r e m e d i a t i o n and c o n s t r u c t i o n a c t i v i t i e s , w i t h i n 45 days a f t e r l o d g i n g o f the-. Consent Decree. The S e t t l i n g Defendants s h a l l submit a RA Work P l a n i n accordance w i t h § V I and p a r a g r a p h 12 o f t h e Consent Decree and S e c t i o n V of t h i s SOW.
T h i s p l a n w i l l i n c l u d e , a t a minimum, t h e f o l l o w i n g :
• A d e s c r i p t i o n o f t h e s t r a t e g y f o r c o m p l e t i n g t h e c o n s t r u c t i o n a c t i v i t i e s
® A bar c h a r t s c h e d u l e f o r c o m p l e t i n g t h e c o n s t r u c t i o n a c t i v i t i e s
• -A d e s c r i p t i o n o f t h e s t r a t e g y f o r i m p l e m e n t i n g the o p e r a t i o n , maintenance, and m o n i t o r i n g a c t i v i t i e s
• A schedule f o r implementing t h e o p e r a t i o n , maintenance, and m o n i t o r i n g a c t i v i t i e s
• The sche d u l e f o r d e l i v e r a b l e s and o t h e r p r o j e c t m i l e s t o n e s ,
6
r . ) , IIIIIIIIIIII lllllllllllllill IIIIIII ") 20140926-0080117 "
Mary HoUinrake P:114/120 11:57ftM ' Kent Cnty MI Rgstr09/26/2014 SEAL
, as c o n t a i n e d i n S e c t i o n V o f t h i s SOW * • I d e n t i f i c a t i o n o f any s u b s t a n t i v e p e r m i t r e q u i r e m e n t s needed
t o implement t h e r e m e d i a l a c t i o n and t h e s c h e d u l e f o r a d d r e s s i n g t h e s e r e q u i r e m e n t s
•» P r e l i m i n a r y i d e n t i f i c a t i o n o f t h e RA p r o j e c t team • D e l i n e a t i o n o f t h e a r e a around the l a n d f i l l i n w h i c h w a t e r
s u p p l y w e l l i n s t a l l a t i o n w i l l be p r o h i b i t e d
The work p l a n s h a l l a l s o i n c l u d e an ACL per f o r m a n c e m o n i t o r i n g p l a n i n c l u d i n g , a t a minimum, t h e f o l l o w i n g : '
• I n s t a l l a t i o n and s a m p l i n g and a n a l y s i s p r o c e d u r e s f o r a l l new g r o u n d w a t e r / s u r f a c e water- i n t e r f a c e (GSI) w e l l s , i n c l u d i n g t h e 17 ACL w e l l l o c a t i o n s and t h e two t o f i v e a d d i t i o n a l GSI w e l l s s o u t h o f t h e RTSB a r e a .
• I n s t a l l a t i o n and s a m p l i n g and a n a l y s i s p r o c e d u r e s f o r t h r e e l e a c h a t e m o n i t o r i n g w e l l s i n the RTSB a r e a .
• A l i s t o f the- m i x i n g zone based GSI c r i t e r i a ( i . e . t h e ACLs) t h a t have been e s t a b l i s h e d f o r t h e B u t t e r w o r t h s i t e by t h e S t a t e o f M i c h i g a n
• A data e v a l u a t i o n p l a n t o a s s e s s c o m p l i a n c e w i t h t h e ACLs and t o e v a l u a t e t h e adequacy o f t h e s o i l c o v e r o v e r the RTSB area
• An o p e r a t i o n and maintenance p l a n f o r t h e groundwater and l e a c h a t e m o n i t o r i n g w e l l s
• A c o n t i n g e n c y r e s p o n s e p l a n , as d e s c r i b e d above, t o ad d r e s s exceedances o f t h e ACLs
• A c o r r e c t i v e a c t i o n p l a n t o m i t i g a t e e xceedances o f the ACLs
• A p p l i c a b l e s e c t i o n s o f the approved Remedial D e s i g n Work p l a n w i l l be r e f e r e n c e d , i n c l u d i n g p a r t s o f t h e f o l l o w i n g : •
• F i e l d S a m p l i n g and A n a l y s i s P l a n •• Q u a l i t y A s s u r a n c e P r o j e c t P l a n
Task 3; Remedial A c t i o n C o n s t r u c t i o n
The S e t t l i n g D e f e n d a n t s s h a l l implement t h e R e m e d i a l A c t i o n as d e t a i l e d i n t h e EPA app r o v e d ARDPP. The f o l l o w i n g a c t i v i t i e s s h a l l be completed i n c o n s t r u c t i n g vthe R e m e d i a l A c t i o n .
A. P r e c o n s t r u c t i o n i n s p e c t i o n and me e t i n g
The S e t t l i n g D e f e n d a n t s s h a l l p a r t i c i p a t e w i t h t h e EPA i n a p r e c o n s t r u c t i o n i n s p e c t i o n and meeting t o :
7
IIIIfllllff7 20140926-0080117
^ ^ ^ ^ ^ ^
1.-Review methods f o r documenting and r e p o r t i n g - i n s p e c t i o n d a t a ;
2. Review methods f o r d i s t r i b u t i n g and s t o r i n g documents and r e p o r t s ;
3. Review work a r e a s e c u r i t y and s a f e t y p r o t o c o l ;
4. D i s c u s s any a p p r o p r i a t e m o d i f i c a t i o n s , o f the c o n s t r u c t i o n q u a l i t y assurance, p l a n t o e n s u r e t h a t s i t e - s p e c i f i c c o n s i d e r a t i o n s a re addressed,- and,
5. Conduct a S i t e w a l k - a r o u n d t o v e r i f y t h a t t h e d e s i g n c r i t e r i a , p l a n s , and s p e c i f i c a t i o n s a r e u n d e r s t o o d and t o r e v i e w m a t e r i a l and equipment s t o r a g e l o c a t i o n s .
The S e t t l i n g D e f e n d a n t s s h a l l document t h e p r e - c o n s t r u c t i o n i n s p e c t i o n and meeting and s h a l l t r a n s m i t a summary t o a l l p a r t i e s .
B. P r e - f i n a l i n s p e c t i o n
W i t h i n f i f t e e n (15) days a f t e r S e t t l i n g D e f e n d a n t s make a p r e l i m i n a r y d e t e r m i n a t i o n t h a t t h e r e m e d i a l , a c t i o n c o n s t r u c t i o n i s complete, the S e t t l i n g D e f e n d a n t s s h a l l n o t i f y t h e EPA f o r t h e p u r p o s e s o f c o n d u c t i n g a p r e - f i n a l i n s p e c t i o n . The p r e - f i n a l i n s p e c t i o n i s r e q u i r e d t o demonstrate c o n s t r u c t i o n i s co m p l e t e and c o n s i s t e n t w i t h t h e ap p r o v e d Amended RDPP. The p r e - f i n a l i n s p e c t i o n s h a l l c o n s i s t o f a w a l k - t h r o u g h i n s p e c t i o n o f t h e e n t i r e S i t e w i t h EPA. Any o u t s t a n d i n g c o n s t r u c t i o n i t e m s d i s c o v e r e d d u r i n g t h e i n s p e c t i o n s h a l l be i d e n t i f i e d and n o t e d by t h e S e t t l i n g D efendants. The S e t t l i n g Defendants s h a l l p r e p a r e t h e p r e - f i n a l i n s p e c t i o n r e p o r t . T h i s r e p o r t s h a l l o u t l i n e t h e o u t s t a n d i n g items r e q u i r e d t o r e s o l v e i t e m s , c o m p l e t i o n d a t e f o r t h e s e i t e m s , and a pr o p o s e d d a t e f o r f i n a l i n s p e c t i o n .
C. F i n a l i n s p e c t i o n
W i t h i n f i f t e e n (15) days a f t e r c o m p l e t i o n of any work i d e n t i f i e d i n t h e p r e - f i n a l i n s p e c t i o n r e p o r t , t h e S e t t l i n g D e f e n d a n t s s h a l l n o t i f y the EPA f o r t h e p u r p o s e s o f c o n d u c t i n g a f i n a l i n s p e c t i o n . The f i n a l i n s p e c t i o n s h a l l c o n s i s t o f a w a l k - t h r o u g h i n s p e c t i o n o f t h e S i t e by EPA and t h e S e t t l i n g D efendants. The S e t t l i n g D e fendants s h a l l p r e p a r e t h e f i n a l i n s p e c t i o n r e p o r t . T h i s r e p o r t s h a l l be used as a c h e c k l i s t w i t h t h e f i n a l i n s p e c t i o n f o c u s i n g on the o u t s t a n d i n g i t e m s i d e n t i f i e d i n t h e p r e - f i n a l i n s p e c t i o n . S e t t l i n g D e f e n d a n t s s h a l l submit a w r i t t e n r e p o r t s h o w i n g c o m p l e t i o n o f any o u t s t a n d i n g items i d e n t i f i e d i n the. p r e - f i n a l i n s p e c t i o n r e p o r t .
D. R e p o r t s
1. Completion o f C o n s t r u c t i o n R e p o r t
8
i IIIIIIIIIIII i i III i IIIIII I I I I I I I I I I I I 20140926-0080117
Mary HoUinrake P:116/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEAL
S e t t l i n g Defendants s h a l l submit t h e C o m p l e t i o n - o f C o n s t r u c t i o n R e p o r t t o U.S.. EPA and. t h e S t a t e o f M i c h i g a n when remedy-c o n s t r u c t i o n i s complete, b u t performance s t a n d a r d s have n o t y e t been a t t a i n e d .
W i t h i n 60 days o f a s u c c e s s f u l f i n a l i n s p e c t i o n , S e t t l i n g D e f e n d a n t s s h a l l submit a C o m p l e t i o n o f C o n s t r u c t i o n Report t o EPA and t h e S t a t e o f M i c h i g a n . I n t h e r e p o r t , a r e g i s t e r e d p r o f e s s i o n a l e n g i n e e r and t h e S e t t l i n g Defendants' p r o j e c t c o o r d i n a t o r s h a l l c e r t i f y t h a t t h e Remedial A c t i o n has been c o n s t r u c t e d i n accordance w i t h t h e approved Amended RDPP. The w r i t t e n r e p o r t s h a l l i n c l u d e a s - b u i l t drawings s i g n e d and stamped by. a p r o f e s s i o n a l e n g i n e e r . The r e p o r t s h a l l c o n t a i n t h e f o l l o w i n g s t atement, s i g n e d by a r e s p o n s i b l e - c o r p o r a t e o f f i c i a l o f a S e t t l i n g Defendant o r t h e S e t t l i n g Defendants' P r o j e c t C o o r d i n a t o r :
"To t h e b e s t o f my knowledge, a f t e r t h o r o u g h i n v e s t i g a t i o n , I c e r t i f y t h a t t h e i n f o r m a t i o n c o n t a i n e d i n o r accompanying t h i s s u b m i s s i o n i s t r u e , a c c u r a t e and complete. I am aware t h e r e a r e s i g n i f i c a n t p e n a l t i e s f o r s u b m i t t i n g f a l s e i n f o r m a t i o n , i n c l u d i n g t h e p o s s i b i l i t y o f • f i n e and imprisonment f o r knowing v i o l a t i o n s . "
2. C o m p l e t i o n o f RA Re p o r t
S e t t l i n g Defendants s h a l l submit t h e C o m p l e t i o n o f Remedial A c t i o n R e p o r t t o U.S. EPA and t h e S t a t e o f M i c h i g a n when remedy c o n s t r u c t i o n i s complete, performance s t a n d a r d s have been a t t a i n e d , and where O&M r e q u i r e m e n t s w i l l c o n t i n u e t o be per f o r m e d .
W i t h i n 45 days a f t e r r e c e i v i n g the a n a l y t i c a l d a t a f o r t h e e i g h t h ACL performance m o n i t o r i n g e v e n t , o r sooner i f a l l o f t h e perf o r m a n c e c r i t e r i a are met- f o r f o u r c o n s e c u t i v e q u a r t e r s , S e t t l i n g Defendants s h a l l submit a C o m p l e t i o n o f Rem e d i a l A c t i o n R e p o r t t o EPA and t h e S t a t e o f M i c h i g a n . I n t h e r e p o r t , a r e g i s t e r e d p r o f e s s i o n a l e n g i n e e r and th e S e t t l i n g D e f e n d a n t s ' P r o j e c t C o o r d i n a t o r s h a l l c e r t i f y t h a t t h e Remedial A c t i o n has been completed i n f u l l s a t i s f a c t i o n o f t h e r e q u i r e m e n t s o f t h i s Consent Decree. The w r i t t e n r e p o r t s h a l l i n c l u d e a s - b u i l t d r a w i n g s s i g n e d and stamped by a p r o f e s s i o n a l e n g i n e e r . The r e p o r t s h a l l c o n t a i n the f o l l o w i n g s t a t e m e n t , s i g n e d by a r e s p o n s i b l e c o r p o r a t e o f f i c i a l o f a S e t t l i n g Defendant o r t h e S e t t l i n g Defendants' P r o j e c t C o o r d i n a t o r :
"To t h e b e s t ' o f my knowledge, a f t e r t h o r o u g h i n v e s t i g a t i o n , I c e r t i f y t h a t t h e i n f o r m a t i o n c o n t a i n e d i n o r accompanying t h i s s u b m i s s i o n i s t r u e , a c c u r a t e and complete. I am aware t h e r e a r e s i g n i f i c a n t p e n a l t i e s f o r s u b m i t t i n g f a l s e i n f o r m a t i o n , i n c l u d i n g t h e p o s s i b i l i t y o f f i n e and imprisonment f o r knowing v i o l a t i o n s . "
9'
20140926-0080117 Mary HoUinrake P: 117/120 11:57AM Kent Cnty MI Rgstr09/26/2014 SEflL
.3. • C o m p l e t i o n of Work Rep o r t .'
S e t t l i n g Defendants s h a l l submit t h e C o m p l e t i o n o f Work R e p o r t t o U.S.-'EPA and the S t a t e o f M i c h i g a n when remedy c o n s t r u c t i o n i s complete, performance s t a n d a r d s have been a t t a i n e d , and 0 & M i s complete.
As i d e n t i f i e d i n p a r a g r a p h 50 o f t h e Consent Decree, S e t t l i n g Defendants s h a l l submit a C o m p l e t i o n o f Work R e p o r t . I n t h e r e p o r t , a r e g i s t e r e d p r o f e s s i o n a l e n g i n e e r and t h e S e t t l i n g
'Defendants' P r o j e c t C o o r d i n a t o r s h a l l c e r t i f y t h a t t h e R e m e d i a l A c t i o n has been completed i n f u l l s a t i s f a c t i o n o f t h e . req u i r e m e n t s o f t h i s Consent Decree. The w r i t t e n r e p o r t s h a l l i n c l u d e a s - b u i l t drawings s i g n e d and stamped by a p r o f e s s i o n a l e n g i n e e r . The r e p o r t s h a l l c o n t a i n t h e f o l l o w i n g s t a t e m e n t , s i g n e d by a r e s p o n s i b l e c o r p o r a t e o f f i c i a l • o f - a S e t t l i n g Defendant o r the S e t t l i n g D e f e n d a n t s " P r o j e c t C o o r d i n a t o r :
"To t h e b e s t o f my knowledge, a f t e r thorough) i n v e s t i g a t i o n , I c e r t i f y t h a t the i n f o r m a t i o n c o n t a i n e d i n o r accompanying t h i s s u b m i s s i o n i s t r u e , a c c u r a t e and complete. I am aware t h e r e a r e s i g n i f i c a n t p e n a l t i e s f o r s u b m i t t i n g f a l s e i n f o r m a t i o n , i n c l u d i n g the p o s s i b i l i t y o f f i n e and imprisonment f o r knowing v i o l a t i o n s . "
4. . P r o g r e s s R e p o r t s
S e t t l i n g Defendants s h a l l , a t a minimum, p r o v i d e EPA and t h e S t a t e o f M i c h i g a n w i t h s i g n e d m o n t h l y p r o g r e s s r e p o r t s d u r i n g t h e c o n s t r u c t i o n phase and, a t a.minimum, q u a r t e r l y p r o g r e s s r e p o r t s d u r i n g o p e r a t i o n and maintenance a c t i v i t i e s , c o n t a i n i n g . -
a. A d e s c r i p t i o n and e s t i m a t e o f t h e p e r c e n t a g e o f RA c o m p l e t e d ; b. Summaries o f a l l f i n d i n g s ; c. Summaries o f a l l changes made d u r i n g t h e r e p o r t i n g p e r i o d ; d. Summaries o f a l l c o n t a c t s w i t h r e p r e s e n t a t i v e o f t h e l o c a l
community, p u b l i c i n t e r e s t g roups o r S t a t e government d u r i n g t h e RA r e p o r t i n g p e r i o d ;
e. Summaries o f a l l problems, o r p o t e n t i a l p r oblems e n c o u n t e r e d d u r i n g the r e p o r t i n g , p e r i o d ;
f . A c t i o n s b e i n g t a k e n t o r e c t i f y p r o b l e m s ; g. Changes i n p e r s o n n e l d u r i n g t h e r e p o r t i n g p e r i o d , i n c l u d i n g .
q u a l i f i c a t i o n s ,-h. P r o j e c t e d work f o r t h e next r e p o r t i n g p e r i o d ; .and I . Copies o f d a i l y r e p o r t s , , i n s p e c t i o n r e p o r t s , l a b o r a t o r y - and
m o n i t o r i n g d a t a .
Any changes i n p e r s o n n e l d u r i n g t h e r e p o r t i n g p e r i o d s h a l l be s u b j e c t t o r e v i e w and a p p r o v a l b y EPA, i n c o n s u l t a t i o n w i t h t h e S t a t e o f M i c h i g a n .
10
20 40926-0080117 1 1 1
: Mary HoUinrake P:118/12B 11:57flM ' Kent Cnty MI Rgstr09/2S/2014 SEAL
: E. Community R e l a t i o n s Support ., . . • *
The U. S. EPA, i n c o n s u l t a t i o n w i t h t h e State- o f M i c h i g a n , s h a l l implement a community r e l a t i o n s p l a n . S e t t l i n g D e f endants s h a l l c o o p e r a t e w i t h . t h e EPA and the S t a t e o f M i c h i g a n b y p a r t i c i p a t i n g i n t h e . p r e p a r a t i o n o f a l l a p p r o p r i a t e i n f o r m a t i o n d i s s e m i n a t e d t o th e p u b l i c and i n p u b l i c meetings t h a t may be h e l d o r s p o n s o r e d by t h e EPA t o e x p l a i n a c t i v i t i e s a t o r c o n c e r n i n g t h e S i t e .
Task 4; O p e r a t i o n and Maintenance
The S e t t l i n g Defendants s h a l l implement t h e O p e r a t i o n and Maintenance (0 & M) P l a n f o r t h e l a n d f i l l c o v e r , s u r f a c e w a t e r r u n o f f c o n t r o l s , and l a n d f i l l gas s y s t e m s - t h a t i s i n c l u d e d i n t h e F i n a l RDPP.. As n e c e s s a r y , m o d i f i c a t i o n s t o t h e 0..& M P l a n s as a r e s u l t of c o n s t r u c t i o n a c t i v i t i e s , w i l l be s u b m i t t e d a t the same t i m e as the C o m p l e t i o n o f C o n s t r u c t i o n R e p o r t .
Task 5: Performance M o n i t o r i n g
The performance c r i t e r i a f o r groundwater a r e t h e ACLs l i s t e d i n T a b l e 1. Compliance w i t h t h e s e performance c r i t e r i a w i l l be e v a l u a t e d by S e t t l i n g Defendants a t the GSI w e l l s and w i l l be -conducted i n accordance w i t h S e c t i o n I I . 3 o f t h i s SOW and t h e Remedial A c t i o n Work P l a n .
Performance m o n i t o r i n g f o r s o i l gas w i l l be p e r f o r m e d i n accordance w i t h t h e O p e r a t i o n and Maintenance P l a n , w h i c h w i l l b e i n c l u d e d i n the Amended RDPP t o be s u b m i t t e d by S e t t l i n g Defendants under S e c t i o n V o f t h i s SOW.
IV. CONTENT OF SUPPORTING PLANS
The EPA approved ARDPP w i l l i n c l u d e t h e f o l l o w i n g s u p p o r t i n g p l a n s : •
1. F u g i t i v e Dust C o n t r o l and Ambient VOC M o n i t o r i n g P l a n 2. O p e r a t i o n and Maintenance P l a n ( f o r t h e l a n d f i l l c o v e r ,
s u r f a c e w a t e r c o n t r o l s , and t h e l a n d f i l l gas m o n i t o r i n g system) .
3. S i t e H e a l t h and S a f e t y P l a n 4. Drum C o n t i n g e n c y P l a n 5 . C o n s t r u c t i o n Q u a l i t y A s surance P l a n
The s a m p l i n g and a n a l y s e s a c t i v i t i e s t o be p e r f o r m e d d u r i n g t h e r e m e d i a l a c t i o n c o n s t r u c t i o n w i l l be p e r f o r m e d i n a c c o r d a n c e w i t h t h e F i e l d Sampling P l a n and Q u a l i t y A s s u r a n c e P r o j e c t P l a n c o n t a i n e d i n the EPA approved Remedial D e s i g n Work p l a n ( O c t o b e r 1995). Sampling a c t i v i t i e s d u r i n g c o n s t r u c t i o n would i n c l u d e , b u t n o t be l i m i t e d t o , s a m p l i n g and a n a l y s i s o f t h e u n d e r l y i n g n a t i v e s o i l i n a r e a s where the t h i c k n e s s o f t h e waste i s f o u n d t o
11
II 20140926-0080117
Mary HoUinrake P: 119/120 11 :5JOT Kent Cnty MI Rgstr 09/26/2014 SEAL
be .thin..and t h e waste i s r e c o n s o l i d a t e d i n t o o t h e r f i l l a r e a s t h a t w i l l be capped w i t h c l a y .
V. SUMMARY OF MAJOR DELIVERABLES/SCHEDULE
A summary o f t h e p r o j e c t s c h e d u l e and r e p o r t i n g r e q u i r e m e n t s c o n t a i n e d i n t h i s SOW i s p r e s e n t e d below:
S u b m i s s i o n Due Date
1. D r a f t Amended R e m e d i a l Design P r o j e c t P l a n s
10 days a f t e r l o d g i n g o f the Consent Decree
2. F i n a l ARDPP 20 days a f t e r ' r e c e i p t of EPA comments on t h e D r a f t ARDPP
D r a f t RA Work p l a n 45 days a f t e r l o d g i n g o f t h e Consent Decree
4. F i n a l RA Work P l a n 20 days a f t e r r e c e i p t of EPA comments on D r a f t RA Work P l a n
5. Award RA C o n t r a c t ( s )
6. P r e - C o n s t r u c t i o n I n s p e c t i o n And M e e t i n g
7. I n i t i a t e C o n s t r u c t i o n o f RA
T h i r t y (3 0) days a f t e r EPA a p p r o v a l o f F i n a l RA work p l a n
F i f t e e n (15) days a f t e r Award o f RA C o n t r a c t ( s )
F i f t e e n (15) days a f t e r the P r e - C o n s t r u c t i o n I n s p e c t i o n and M e e t i n g , o r upon e n t r y of t h e Consent. Decree,- w h i c h e v e r i s l a t e r
8. C o m p l e t i o n o f C o n s t r u c t i o n I n a c c o r d a n c e w i t h t h e EPA's approved RA c o n s t r u c t i o n s c h e d u l e
9. P r e - F i n a l I n s p e c t i o n No l a t e r t h a n f i f t e e n (15) days a f t e r c o m p l e t i o n o f c o n s t r u c t i o n
12
iiiiiniiiiiiiiiiiiiiiiiii 20 40926-0080117
Mary HoUinrake P:120/120 11:57PM Kent Cnty MI Rgstr09/26/20U SEflL
10. - P r e - F i n a l I n s p e c t i o n Report
11. F i n a l I n s p e c t i o n
12. F i n a l I n s p e c t i o n Report
13. O & M P l a n Addendum
14. C o m p l e t i o n o f C o n s t r u c t i o n R e p o r t
15. Completion o f Remedial A c t i o n Report
16. C o m p l e t i o n o f Work Report
F i f t e e n ^(15) days - a f t e r , ,:
c o m p l e t i o n o f p r e - f i n a l . i n s p e c t i o n
F i f t e e n (15) days a f t e r c o m p l e t i o n o f work i d e n t i f i e d i n p r e - f i n a l i n s p e c t i o n r e p o r t
15 days a f t e r c o m p l e t i o n o f f i n a l I n s p e c t i o n
60 days a f t e r " ' c o m p l e t i o n o f f i n a l i n s p e c t i o n
60 days a f t e r c o m p l e t i o n o f f i n a l i n s p e c t i o n
F o r t y f i v e (45) days a f t e r r e c e i v i n g t h e a n a l y t i c a l d a t a f o r t he e i g h t h q u a r t e r l y ACL performance m o n i t o r i n g e v e n t , o r sooner, i f a l l o f t h e p e r f o r m a n c e c r i t e r i a a r e met f o r f o u r c o n s e c u t i v e q u a r t e r s
As i d e n t i f i e d i n p a r a g r a p h 50 o f t h e Consent Decree
13