LAW OFFICES

STORINO, RAMELLO & DURKIN

9501 WEST DEVON AVENUE

ROSEMONT, ILLINOIS 60018

(847) 318-9500 DONALD ..J. STORINO

MICHAEL K. DURKIN

RICHARD ..J. RAMELLO

NICHOLAS S. PEPPERS

THOMAS M. BASTIAN

ANGELO F. DEL MARTO

.JAMES E. MACHOLL

BRIAN W. BAUGH

ANTHONY ..J. CASALE

ANDREW Y. ACKER

PETER A. PACIONE

MELISSA M. WOLF

MATTHEW G. HOLMES

MICHAEL R. DURKIN

FACSIMILE (847) 318-9509

Gerald T. Karr Assistant Attorney General Environmental Bureau Illinois Attorney General's Office 69 W. Washington St., Suite 1800 Chicago, Illinois 60602

Michael S. Roubitchek Assistant Counsel Illinois Environmental Protection Agency 1021 North Grand A venue East P.O. Box 19276 Springfield, Illinois 62794-9276

Maureen Brehmer Bureau of Water Illinois Environmental Protection Agency 9511 W. Harrison Street Des Plaines, Illinois 600 16

June 6, 2016

RE: People of the State of Illinois ex rei. Madigan v. City of Elmhurst, 18th Judicial Circuit Court, No. 2011 CH 3357

Dear Mr. Karr:

THOMAS ..J. HALLERAN

ERIN C. TINAGLIA

ADAM R. DURKIN

.JOSEPH G. KUSPER

MARK R. STEPHENS

BRYAN ..J. BERRY

ANN M. WILLIAMS

LEONARD P. DIORIO

RICHARD F. PELLEGRINO

DONALD ..J. STORINO II

OF COUNSEL

IN REPLY REFER TO FILE NO.

ELMH-85

Pursuant to Section III D 5 of the Consent Order entered by the 18th Judicial Circuit Court on September 17, 2014, in the above-captioned matter, please find enclosed the City of Elmhurst's "Annual Report."

STORINO, RAMELLO & DURKIN June 6, 2016 Page 2

Please contact me at my office if you have any questions or wish to further discuss this matter.

AYA:aa En c.

CC. Renee Cipriano Schiff Hardin, LLP 233 South Wacker Drive Suite 6600 Chicago, IL 60606-64 73

Don Storino Storino Ramello and Durkin 9501 W. Devon Ave., Ste. 800 Rosemont, IL 60018

James Grabowski City Manager City of Elmhurst 209 S. York St. Elmhurst, IL 60126-2759

Howard Killian Public Works Director City of Elmhurst 209 S. York St. Elmhurst, IL 60126-2759

Paul Burris Utility Operations Manager City of Elmhurst 209 S. York St. Elmhurst, IL 60126-2759

601052_1

City of Elmhurst Annual Report

II

II

liLA

The defendant shall notify each contractor to be retained to perform work required in this

Consent order of each of the requirements of this Consent Order relevant to the activities

to be performed by that contractor, including all relevant works schedule's and reporting

deadlines, and shall provide a copy of this consent order to each contractor already

retained no later than thirtv (30) davs after the date of entrv of this Consent Order.

The defendant shall provide copies of all schedules for implementation of the provisions

of this Consent Order to the prime vendor(s) supplying the control technology systems

and other uired by this Consent Order.

The defendant shall pay a civil penalty of Twenty-Five Thousand Dollars ($25,000.00).

Payment shall be tendered at time of entry of the Consent Order. (Certified Check made

ble to the Illinois EPA for deposit into the Environmental Protection Trust Fun (EPTF).

Replacement pumps and equipment at the Jackson Lift Station to increase the operating

capacity of the station. The Jackson Lift Station Improvements will include two (2) dry

10/17/2014

10/17/20151 9/24/2014

9/17/20141 9/17/2014 Completion date

adjusted to

12/31/2016 by

weather pumps, three (3) wet weather pumps, and the upsizing and deepening of the wet I previous

III.D.l.A I well at the Jackson Lift Station. agreement

Upsize the main gravity sewer at the Jackson Street Lift Station from 18 inches to 24

inches. The City shall ensure that the new sewer is deeper and has a greater slope in

III.D.l.B I order to increase the flow velocities and reduce solids settling in the

Install a new 5,900 lineal foot we-weather force main between the Jackson Street Lift

III.D.l.C !Station and Elmhurst WRP in order to decrease flows to the existing force main

Completion date

adjusted to

12/31/2016 by previous

ement

Completion date

adjusted to

12/31/2016 by

previous

ement 5/18/2015

June 15, 2016

1 of 18

City of Elmhurst Annual Report

Completion date

adjusted to

Construction a new 2-million gallon storage tank at the WRF that will provide storage for 112/31/2016 by

wastewater discharge from the City's new wet-weather force main during periods of

III.D.l.D lheavv rain.

Through the focused study, the City shall assess, among other things: I) the types and

categories of sources of 1/1 into the City's Sanitary System within Basins 24 & 26, including

sources of 1/1 from the private section; ii)Recommendations on options for removing or

otherwise addressing those sources; and iii) Funding options for addressing each source

previous

ement

III.D.2.A 2/20141 9/22/2014

Elmhurst shall have RJN prepare a report documenting its findings ("Focused Study

Report") and deliver the Focused Study Report to the City Public Works Committee no

later than September 22, 2014. Elmhurst shall deliver a copy of the Focused Study Report

to the State for review within five days of the receipt by the City Public Works Committee.

The City Public Works Committee shall review and consider the findings presented in the

Focused Study Report and shall assess the following: 1) Feasibility, need and cost benefit

of further dye testing and smoke testing in other areas of the City and prioritization, if

further dye testing and/or smoke testing is recommended; 2) Whether ordinance

amendments are needed to adequately enforce the disconnections of the suspect or"

non-compliant" sumps and drains, and if so, include model language; 3) Feasibility, need

and cost structure of a tiered reimbursement program for the voluntary removal of area

drains, combination sumps and foundation drains; 4) Feasibility, need and cost benefit of

modifying the Overhead Sewer Reimbursement Program and Check Valve Grant Program;

and 5) Feasibility, need and cost benefit of piloting a voluntary Rear yard Rain Garden

III.D.2.B !Grant P m. 9/2 014

June 15, 2016

2 of 18

City of Elmhurst Annual Report

By December 31, 2014, the City Public Works Committee shall create a plan that identifies

specific actions to be taken by the City to reduce 1/1 in the Sanitary System and a schedule

III.D.2.C lfor implementation ("Sa Sewer Improvement Plan").

III.D.2.D

The City shall provide the Sanitary Sewer Improvement Plan to the State for review and

approval no later than January 15, 2015. In the event that the Sanitary Sewer

Improvement Plan includes a proposed City ordinance or an amendment to an ordinance,

the proposed ordinance or amendment shall be included with the Sanitary Sewer

rovement Plan which delivered to the State.

Upon approval by the State, the Sanitary Sewer Improvement Plan shall then be

submitted to the City Council for consideration and approval. Plaintiff recognizes that the

City of Elmhurst is a home rule municipality controlled by an independent Council of

elected officials. If any modifications are made by the Elmhurst City council to the

Sanitary Sewer Improvement Plan, those modifications must be submitted to the State

for approval. Once a plan has been approved by the State and adopted by the Elmhurst

City Council, Defendant shall implement the Sanitary Sewer Improvement Plan in

accordance with the schedule contained therein. The Plan shall contain the following

implementation dates: l}lnspection and evaluation of private sector 1/1 sources shall be

completed no later than December 31st, 2017; and 2} Elimination or rehabilitation of

private section 1/1 sources, as identified by the Sanitary Sewer improvement Plan, shall be

III.D.2.E lcomoleted no later than December 31, 2021.

June 15, 2016

12/31/20151 12/8/2014

1/15 014

12/31/2021

3 of 18

City of Elmhurst Annual Report

III.D.3

III.D.4

By no later than December 31, 2014, the City will have a fully operational GIS centric

Computerized maintenance Management System ("CMMS") on line. A CMMS is a vital

component of an overall enhanced Sanitary System. CMMS serves as a central repository

for customer service requests, work orders, tracking of maintenance issues and

accomplishments, and tracking of performance measures. Any CMMS should be GIS

centric so there is seamless interfacing for the City departments with respect to key

information. The City currentlv has a full time GIS soecialist on staff.

Elmhurst shall maintain a Fats, Oils, Grease (FOG) enforcement program that includes

inspections of all food service establishments and auto repair and fuel dispensing facilities

located in the City "FOG Facilities". Elmhurst shall perform inspections of all FOG Facilities

to determine compliance with Chapter 7 of the Municipal Code. For all FOG Facilities with

violations of the Elmhurst Municipal Code, the City shall utilize the enforcement

mechanism available in Divisions 13 and 14 of Article II.Ch7 to ensure that such .... to

comoliance.

The Defendant shall provide annual progress reports to the state on the status of all work

required to be performed under this Consent Order beginning the first calendar year after

the trial court's entry of this Consent Order. Defendant shall submit Progress Reports

Annually on the 15th of June. Defendant shall continue to submit Progress reports until

the parties agree otherwise in writing, until the Illinois EPA provides the Defendant

1/30/20151 1/30/2015

June 15th (every 16/15/2015 written confirmation that its obligations under this Consent Order are completed, or until I year until notified !(first annual

III.D.S

III.E.1.i.

further order of the Court.

Constructions and/or installation of education displays and storm water management

techniques along the Salt Creek Greenway Trail, as outlined in Attachment A to this

Consent Order. The purpose of this SEP is to provide public education as well as functional

reduction of impairments. The project will manage sedimentation/siltation, aid in mineral

and nutrient mitigation (chloride and total phosphorus), aid in storm water detention,

promote indigenous plant growth, and model sustainable practices for the community of

Elmhurst.

otherwise)

5/31/20151 5/31/2015

June 15, 2016

4 of 18

City of Elmhurst

Annual Report

III.E.l.ii

The SEP includes educational displays at each of the four lift stations that educate the

public on each technique being used, rain garden, green roof, native prairie and porous

paving. Elmhurst maintain the installations and education displays for a minimum of 5

Elmhurst shall promote sustainable practices by including information about this project

on its website and other appropriate measures, including, but not limited to, the City's

informational meetings with the public, the City's quarterly "Front Porch" newsletter, and

the City Public Works' annual FOG reception for the public held annually on the Friday

III.E.1.iii lfollowi

June 15, 2016

5 of 18

City of Elmhurst

Annual Report

defendant shall complete the construction of the SEP no later than May 31, 2015, and

within 30 days thereafter, shall submit a project completion report, including a summary lsEP: 5/31/2015;

of all expenditures, to the contact person identified in Section Ill. I for review and Project

confirmation that the SEP was performed pursuant to this Order. The City is allowed one I Completion

(1) growing season following the completion of the construction of the SEP to confirm Report: 6/30/15; ISEP

III.E.2

at all vegetative plantings have taken root. The project completion report call include

the following certification by a responsible corporate official of the defendant.

tion

Update: 5/31/16

Completed:

5/31/15

June 15, 2016

6 of 18

City of Elmhurst

Annual Report

of Consent Order and ments

of Consent Order and schedules

As required by Consent Order, Payment was

made on Seotember 17. 2014.

Waiting contract execution. In February 2015, the City obtained

a modification of the term of the consent order to reflect a new

ina I comoletion date of 9/1/15

Waiting contract execution. In February 2015, the City obtained

a modification of the term of the consent order to reflect a new

comoletion date (original completion date of 9/1/15 •.

Hydro test completed. In February 2015, the City obtained a

modification of the term of the consent order to reflect a new

ion date of 9/1/15 •.

June 15, 2016

7 of 18

City of Elmhurst

Annual Report

m

Comoleted

Contract execution to be completed. In February 2015, the City

obtained a modification of the term of the consent order to

reflect a new completion date (original completion date of

Assessment continues; identification and reoair

June 15, 2016

8 of 18

City of Elmhurst

Annual Report

Public Works & Building Committee met on

12/8/14 to discuss the draft SSIP plan

prepared by RJN Group. This SSIP was not

uired to go to the Council at this time.

e City of Elmhurst submitted a proposed

SSIP to the State of Illinois on December, 31,

2014.

The City of Elmhurst received a response from

the State of Illinois in April 2015 with an

approval subject to minor modifications to

Table 6 to include dates for compliance from

the Consent Order. The PW&B Committee

met on May 26, 2015 to discuss these

recommendations from the State and the

adoption of same with modifications. PW&B

Committee made a recommendation to the

City Council to accept the modifications

proposed by IEPA to the SSIP. This includes the

adoption of the ordinances accompanying the

SSIP and the additional work by the

committee in the SSIP. This was submitted to

the Council on June 1, 2015. The Council

considered the recommendations of the

PW&B Committee and agreed to accept the

recommendations.

June 15, 2016

9 of 18

City of Elmhurst

Annual Report

Current annual

in use

m

GIS oortion of the software is comolete.

The City's FOG program was adopted in 2012, prior to the entry

of the Consent Order. The City's FOG program is ongoing and

ctions for 2014 were oerformed bv the

June 15, 2016

10 of 18

City of Elmhurst Annual Report

Construction comoleted

November 30, 2013- 70 gallons of cooking oil

was collected. November 2014 - 80 gallons of

cooking oil was collected. In the November

2014 "Front Porch," a recycling reminder was

posted that alerted residents about cooking

oil. May 6th, 2015: A community workshop

was held at City hall to inform residents about

rain barrels and rain gardens. The City has

recently adoptive new storm water policies.

Please see attached "New Storm water

Policies." We have pavers either installed or

designed for install this year at the Saylor

Street Lift Station and Park Street Lift Station.

rain gardens and one rain barrel were

incorporated into the Salt Creek Greenway

ils Educational Displays to promote

sustainable practice and serve as an example

for the residents.

Phenolic d nels to be delivered

Cooking oil collected is converted to biofuel; program started in

November 2013.

June 15, 2016

11 of 18

..... N 0 -..... 00

0 :::1 VI n ::::; ro c.. c ro

)> :::1 :::1 c Qj

:::0 ro "0 0 ;::+

n ;:::t < 0 -!!! 3 ::::; c .., VI .....

'-c :::1 ro .....

,U'1

N 0 ..... m

City of Elmhurst

Annual Report

2016 Action Taken

Boller was informed when brought on to

project for storage tank

Boller was informed when brought on to

project for storage tank

N/A

As of June 1st, 2016 the 2 dry weather

pumps have been installed. Currently

working on motor control center,

generator, and wet weather pump

installations

As of June 1st, 2016 the 24" line is 50%

completed with installation from Saylor lift

station to Prospect Street completed

As of June 1st, 2016, the force main is 95%

completed. Anticipated start up when lift

station and tank are completed

June 15, 2016

13 of 18

City of Elmhurst

Annual Report

2016 Action Taken

as of June 1st, 2016 the 2mgd storage tank

85% completed. The tank has been built and

we are currently waiting on discharge

control valve before testing of tank can be

completed

Received 2015 summary from RJN and

currently reviewing the findings for

addressing any issues in the future.

N/A

June 15, 2016

14 of 18

City of Elmhurst

Annual Report

2016 Action Taken

N/A

N/A

Received 2015 summary from RJN and

currently reviewing the findings for

addressing any issues in the future.

June 15, 2016

15 of 18

City of Elmhurst

Annual Report

2016 Action Taken

Of June 1st, 2016, many staff have been

trained on the program and system is in use

for work orders

Of of June 1st, 2016, the City has continued

its annual inspection program

This update completed annual requirement

for period ending June 15th, 2016

As of June 1st 2016, this project has been

completed

June 15, 2016

16 of 18

City of Elmhurst

Annual Report

2016 Action Taken

As of June 1st 2016, this project has been

completed

From June 1, 2015 to June 1, 2016, 80

gallons of recycled cooking oil was gathered

for proper disposal. Increased rain barrel use

by73.

June 15, 2016

17 of 18

City of Elmhurst

Annual Report

2016 Action Taken

According to our maintenance contractor

"The lift stations including the green roofs

continue to be in exceptional health"

June 15, 2016

18 of 18

...... 00 0 .... ...... 00

" )> :::1 :::1 c: Q)

:::tl 11)

"0 0 :::+

("") ;:::;: < 0 .... m 3 ::::r c: .., VI .-+

iiL_.~!Lt-l~f!l.l!_ ____ -- ~ : 1 ;NOTICE TO PROCEED

I

~-~2-lPour concrete base

t ~'"""lA""'~ .. ~ \ 4 Install Flushing System I I t-· ~--j ' 5 :Install Aeration

6 ·underground electrical

\Hut base slab

-:-~:

I 8 !fabricate & Set Handi Hut

~-····-

]Fill tank I test 9

' -·-1

I

10 . .!Set Generator

11 :site Electrical Work & Connections

~--_j 12 '•site Piping

l ···- . 13 Install valves

14 'Instrumentation, Controls, & Final Electrical Connections I

r-------~ 15 Startup & Commissioning

16 Substantial Completion

17 :Final Site Grading & Seeding

18 'Punch list work

19 ---·~Final Completion

\"··-··---·----·-------- --·- ------

Task

Proj~ct Elmhurst SWWCF Stora l Split

Date. Thu 5/26/16 Milestone • Summary

i

Duration ;start i-day -- --Frisiiiii15

10days Tue 11/24/15

75 days Tue 12/8/15

30days Tue 3/22/16

29 days Tue 3/22/16

20 days Tue 3/22/16

5 days Tue 4/19/16

8 days Tue 4/26/16

50 days Tue 5/3/16

5 days Tue 3/22/16

45 days Tue 3/22/16

65 days Mon 2/29/16

15 days Mon S/30/16

15 days Tue S/24/16

10 days Tue 7/12/16

1 day Tue 7/26/16

40 days Mon 5/30/16

20 days Wed 7/27/16

1day Wed 8/24/16

Project Summary

Inactive Task

Inactive Milestone

Inactive Summary

ELMHURST WET WEATHER STORAGE TANK

;Fini!_f.l _______ Fri 5/29/15

Mon 12/7/15

Mon 3/21/16

Mon 5/2/16

Fri 4/29/16

Mon 4/18/16

Mon 4/25/16

Thu 5/5/16

Mon 7/11/16

Mon 3/28/16

Mon 5/23/16

Fri 5/27/16

Fri 6/17/16

Mon 6/13/16

Mon 7/25/16

Tue 7/26/16

Frl7/22/16

Tue 8/23/16

2

3

3

3

6

7

4

3

3

12

11

9

15

12

16

i Jun~. ~'July .d,vgo>! JStPlm!l Q~ob_ei !;<>'lemlt:!&mri)•n".~!Y' f.il>ruilll~n:h LI\Rn!. . Ma.. :J.Y!lL.J)J!!y_ .l&~ou>d ~ptemL I -

~ ----• "'

i

• JIM u

i• h. -r

..... Wed 8/24/16 18 ··~

Maoual Task

Duration-only

Manual Summary Rollup -----­

Manual Summary

Page 1

Start-only

Finish-only

External Tasks

E)lternill Milestone

]

I Deadline • Progress

Manual Progress

f __ --·-~-~-::~

tL•l_~s 8 'll!!i - 9

I -- ---' 10 l· ,-,.····-j ~~ l 13 ' !14l ~---,5- j

16 i

iT j ~-1a-·-·l ' '19 -j :-----1 ' 20

21-~ if '

c--:~:r-i ' -24--i

___ .J

25 '

~~ ; 28 ]t;;!

- J!.~!~-l'i~fl:l_tt__ ·- -NOTICE OF AWARD NOTICE TO PROCEED

lnslall 24" lo Exlsllng PLITlp Slalion

Install 8" Force Main from New Pump Station lnsta1110· Force Main from New Pump Station Install 1e• Force Main lo Existing Valve Chamber Install 1a• Foree Main from Existing Valve Chamber Slart up new pump station

Demo existing pump sta Concrete Demo delay between wans Remove existing piping & pumps Existing Pump Station Concrete mods Form & pour north steps Install New Electrical Gear Install New Generator Comect Power to New Pump Station Remove exisl!ng MCC Existing Pump Station Pip4ng ModificatiOns Existing Pump Station HVAC Modifications Instrumentation install Equip start up I check out Existing Pump Station Startup SUBSTANTIAL COMPLETION

Landscape Pavers Landscaping

Site restoration Punch listv.()rk FINAL COMPLETION

--- -·--··-----

Task

Project Elmhurst SWWCF Pump Slat I sp1n

Date: Thu 5126116 Milestone

Summary

Project Summary

ELHHURST PUMP STATION MODIFICATIONS

Lt:l<I~~~Y' ~~~~r~in~ts;;l' Ma~ J -~~ _; __ !MY __ .J 1 day Fri 5129115 Fri 5129115

7 days Mon 616/16 Tue 611411 10days Wed 6/15/16 Tue6128116

4 days Wed 6129116 Mon 7/4116

5 days Tue 7/5116 Man 7/11/1

7 days Tue 7/5116 Wed 7/13/16_ 2 days Mon 4/4116 Tue 415/161

35 days Wed 416116 Tue 51241161

23 days Wed 5125/16 Fri 8/24116[

5 days Wed 5125/16 Tue 5131/16'

10 days Wed 611/16 Tue 6114/16!

10 days Thu 7/14/16 Wed 7127/1~

23 days Wed 4/6116 Fri 516/1~

2 days Wed 6115/16 Thu 6116116~ 1 day Fri 6117/16 Frl6117/1

3 days Man 6120/16 Wed 6122/1

20 days Mon 6127/16 Fri 7122/1~ 15 days Fri 6117/16 Thu 7/7/1

9 days Fri 7/8/16 Wed 7120/1

9 days Mon 7125/16 Thu 814116.

5 days Fri 815/16 Thu 611111~ 1 day Fri 8112/16 Fri 8112/1&,

8 days Fri 815/16 Tue 81161161

15 days Wed 8117/16 Tue 9/61Hi

10 days Fri 8112/16 Thu 8125116.

30 days Fri 8112/16 Thu 9122/16 1 day Fri 9123116 Fri 9123/16 -------

External Tasks

'''''''''"'"''"''"''' External Mnestone

• Inactive Task

Inactive Milestone

Inactive Milestone

• Inactive Summary

Manual Task

Duration-only

Manual Summary Rollup + Manual Summary •

Page 1

October itlovom~li!M!!f ~.~()' :.f~t~!Y; _M912:LL~nJ _ ~- -~ :r f.p,_~ L _J_l!Jy_;_ ~J s~te!Tibe<.

Slart-only

F inistl-only

External Tasks

External Milestone

Progress

Deadline

I ""'---

.......

J..>

--. t r-- -i

i! t,.__ ... _ -. r ---t- l.__

• www.rjn.com

[Jogroup

PRESENT:

Dan Rosenwinkel

Paul Burris

Chris Dufort

Steve Dalbec

Randy Alcorn

Larry Leable

Greg Hamalainen

Ben Dolan

Peter Zach

Mike Klein

Garry Sementa

Cathy Morley

Mark Smith

Yann Gallin

1. Pump Station

CITY OF ELMHURST (COE) SOUTHWEST WET WEATHER CONTROL FACILITY

PROGRESS MEETING Tuesday, May 24, 2016 10:30am - 12:00pm

Meeting Summary

City of Elmhurst 630-330-1354 Dan.Rosenwinkel@elmhurst.org

City of Elmhurst 630-330-0895 Paui.Burris@elmhurst.org

City of Elmhurst 630-330-3034 Chris.Dufort@elmhurst.org

Boller Construction 847-409-1500 steved@bollerconstruction.com

Boller Construction 847-662-5566 rand:1a@bollerconstruction.com

Boller Construction 847-878-7100 LarsLeable@aol.com

Boller Construction

Homestead 815-451-8687 ben@homesteadelectric.com

Okeh Electric 847-577-7744 BWCSI 815-788-3600 mklein@bwcsi.com

Archon 630-495-0015 garr:1@archononline.com

RJN Group 630-520-3326 cmorle:1@rjnmail.com

RJN Group 630-251-3627 msmith@rjnmail.com

RJN Group 630-682-4700*320 :1gallin@rjnmail.com

o Existing pump station retrofit: ./ Demolition of existing wet well and upstream chamber: Piping, concrete, pumps,

etc.: Work in progress. Due to unforeseen condition in regard to the piping removal, an alternate option is being designed and will be sent to the COE for review beginning of next week .

./ Installation of MCC Panel, SCADA Control Cabinet, Level switches and level transducers: Control Cabinet was delivered May 20th. Work to be completed by the week of June 17th. Demolition of old MCC will follow .

./ Installation of the new generator: 3 weeks out .

./ Installation of new piping: Starting next week .

./ Louver installations: beginning of July after the new generator is installed.

200 West Front Street • Wheaton. IL 60187 • 630.682 4700 • fax 630 682 4754

• www.rjn.com

rJngroup

o New wet well pump station: ./ Installation of 140-HP wet weather pump: The pump is stored in Boller's storage

unit, and is ready to be installed as soon as the new MCC is connected.

o Underground piping: ../ Installation of underground piping (18" FM, 24" sanitary sewer, Meter Vault,

etc.): Starting May 3Pt.

o CornEd's Easement: ../ It was confirmed with CornEd that their easement can be used for the

installation of the new electrical service from the electrical pole to the Control Cabinet connected to Basin 20 Monitoring Manhole located at Spring/McKinley.

2. Storage Tank

o Boller filled the tank with 5-6 feet of water. Cady Aquatore (Tank Manufacturer) did a visual inspection to verify that everything is watertight prior to backfilling around the tank. Sand was delivered on site May 24th, and Backfilling around tank started May 25th.

o Boller will start hauling off the rest of spoil pile May 25th.

o Installation of motor operated valves for Valve Vault 1, 2 & 3: Beginning of June.

o Archon will start the work on water main/RPZ/Meter Vault next week. Once completed, Boller will be testing of flushing system.

o The color of the overflow weir shall match the color of the tank.

o The service for the gates currently terminates at hand holes.

3. Communication devices and conduits

o Temporary communication: ../ A temporary cellular connection will be installed at the pump station to

communicate from the new SCADA Cabinet to the WRF until the fiber optic cable is installed.

200 West Front Street • Wheaton. IL 60187 • 630.682.4700 • fax 630.682 4754

• www.rjn.com

rJngroup

o Fiber Optic Cable installation: ../ Installation of the fiber optic cable to Basin 20 MH and to Storage Tank:

Anticipated to be completed by end of June. Expanded work days will be required and coordinated with the City .

../ Disconnection of F.O. cable from manhole at intersection of McKinley St. and Saylor Ave .

../ Installation of new handhole and conduit to be extended from Saylor Ave. to new SCADA cabinet .

../ Conduit to be extended for about 300 feet from the east of the tank to monitoring manhole No.1 (East of WRF).

ALL DATES ARE WEATHER PERMITTING

Attachments: • Boller Construction: Gantt charts for both projects.

200 West Front Street • Wheaton, IL 60187 • 630 682.4700 • fax 630 682.4754