Microsoft Word Viewer - 104118_1-1.docxTeacher Retirement System of
Texas Pension Administration Line of Business
System Replacement
2:00 p.m., C.T., February 21, 2013
Deadline to Pre-Register for Mandatory Pre-Offer Conference
Attendance via Audio Conference:
2:00 p.m., C.T., February 21, 2013
Mandatory Pre-Offer Conference: 2:00 p.m., C.T., February 28,
2013
Technical Offer Response Deadline: 2:00 p.m., C.T., April 12,
2013
Detailed Pricing Response Deadline:
Page 2 of 375
1. Introduction
................................................................................................................................................6
2. Definitions and Acronyms
..........................................................................................................................6
3.
Background................................................................................................................................................6
13.1. Receipt by TRS
.............................................................................................................................23
13.2. Offer Submission and Formatting
.................................................................................................23
13.3. Offer Content and Organization
....................................................................................................25
1. Contract Specific Terms and
Conditions................................................................................................133
1.1. Contract
Term.................................................................................................................................133
1.2.
Renewal..........................................................................................................................................133
1.3.
Termination.....................................................................................................................................133
1.4. Amendments to Contract
................................................................................................................134
1.5. Additional
Work...............................................................................................................................135
1.6.
Pricing.............................................................................................................................................135
1.7. Warranty
.........................................................................................................................................135
1.8. Electronic and Information Resources Accessibility
Standards......................................................137
1.9. Contractor
Requirements................................................................................................................137
1.10. Acceptance, Invoicing, and Payment
..........................................................................................138
1.11. Performance Payment
................................................................................................................139
1.12. Contractor Limitation of Liability
..................................................................................................139
1.13. Liquidated Damages
...................................................................................................................139
SECTION VII. – APPENDICES
........................................................................................................................242
APPENDIX 1 – Additional TRS
Information..................................................................................................243
APPENDIX 2 – TRS Enterprise Risk Management Policy
...........................................................................257
APPENDIX 3 – TRS Laws and Rules
.............................................................................................................261
APPENDIX 4 – TRS CAFR
..............................................................................................................................262
APPENDIX 5 – TRS Handbooks and General Information
..........................................................................263
APPENDIX 6 – TRS Records Retention Schedule
.......................................................................................264
APPENDIX 7 – TRS Business Processes
.....................................................................................................268
APPENDIX 8 – TRS Web Self-Service Business Processes
.......................................................................272
APPENDIX 9 – TRS Website Accessibility
Standards.................................................................................273
APPENDIX 10 – Keyboard Navigation
..........................................................................................................275
APPENDIX 11 – Current Employer Reporting (Reporting Entity) Format
.................................................276 APPENDIX
12 – TRS Signature
Data.............................................................................................................302
APPENDIX 13 – Future Employer Reporting Needs – GAP Analysis
........................................................312
APPENDIX 14 – Employer Reporting Functionality Preferred
Implementation Timeframe.....................315 APPENDIX 15
– Actuarial Extract File
Layout..............................................................................................316
APPENDIX 16 – TRS Chart of Accounts
.......................................................................................................318
APPENDIX 17 – Deposit Type
Codes............................................................................................................351
APPENDIX 18 – Composite Framework Architecture
.................................................................................353
APPENDIX 19– TRS FileNet P8 Imaging Process
Flow...............................................................................354
APPENDIX 20 – Correspondence, Document and Forms Management
Services ....................................356 APPENDIX 21
– TRS Segregation of Duty Rules
.........................................................................................357
SECTION VIII. – APPENDICES - CONFIDENTIAL
.........................................................................................375
PLEASE NOTE: This RFO consists of separately provided Appendices
(Appendices 22 through 37), that contain information pertaining to
TRS computer systems that is sensitive and confidential. These
Appendices are referenced throughout the RFO. To obtain these
additional Appendices, interested parties must (1) indicate they
meet the minimum requirements stated in Section II, 13.3 TAB 2; (2)
indicate an intent to submit an Offer in response to this RFO; and
(3) execute a Non-Disclosure Agreement (See Attachment L) for this
information. To comply, interested parties must submit the
completed Non-Disclosure Agreement (Attachment L) via email to John
Dobrich at
[email protected] and the additional
Appendices will be made available. Additionally, if Respondent
reveals or uses any information that is derived from TRS’ sensitive
or confidential Appendices in an Offer, Respondent shall
conspicuously mark all such information as “Confidential” wherever
such information is revealed or used in the Offer.
The following documents are included as separate files on the
Electronic State Business Daily. Attachment N - Detailed Pricing
Matrix – Excel spreadsheet Attachment O - HUB Subcontracting Vendor
Listing – Excel spreadsheet
Page 6 of 375
SECTION I – DESCRIPTION OF PROCUREMENT 1. Introduction The Teacher
Retirement System of Texas (TRS) seeks an experienced pension
administration line of business solution contractor for the
development and implementation of a pension administration system
and integration to related systems in accordance with the
specifications contained in this Request for Offer (“RFO”).
2. Definitions and Acronyms Please see Attachment M for the
definitions and acronyms used in this RFO. 3. Background
3.1. TEAM Program Overview
TRS is undertaking a modernization effort of its core processes and
technologies used to administer a range of TRS benefits. The
effort, known as the TRS Enterprise Application Modernization
(“TEAM”) Program, will modernize non-investment TRS applications.
This will be accomplished by several initiatives that will utilize
new technologies to improve the quality of service delivered to its
customers through a new Pension Administration Line of Business
(LOB) system and automated interfaces. The active member, retiree
and beneficiary pension benefits, non-investment, that TRS
administers include:
3.1.1. A defined benefit retirement plan that is a qualified
pension trust under Section 401(a) of the Internal Revenue Code.
The pension trust fund provides service and disability retirement,
as well as death and survivor benefits, to eligible Texas public
education employees and their beneficiaries.
3.1.2. TRS-ActiveCare is a statewide health benefit program for
eligible public education
employees of participating entities. It is financed by plan
participant premium payments and investment income. Participation
in that program has grown to over 445,969 employees and dependents.
Of the 1,246 districts/entities eligible to participate in TRS-
ActiveCare, over 88.9 percent, or 1,108 now do so.
Along with the four Preferred Provider Organization (PPO) plan
options administered by Blue Cross and Blue Shield of Texas and
Medco, there are three health maintenance organization (HMO)
options offered under TRS-ActiveCare for the 2012-2013 plan year:
FirstCare Health Plans, Scott & White Health Plan, and Valley
Baptist Health Plans. These HMO options will provide additional
plan choices to the employees of participating entities in areas
served by these HMOs. These employees will be able to select
TRS-ActiveCare coverage under one of the PPO plans or through the
authorized HMO serving their part of the state.
3.1.3. TRS-Care is the group retiree health benefits program for
TRS retirees and eligible
dependents. This program is financed by contributions from the
state, active public school employees, reporting entities, premium
payments from plan participants, and investment income. TRS-Care is
the group retiree health benefits program administered by TRS. TRS
retirees who are not eligible for ERS, UT, or Texas A&M system
health benefit
Page 7 of 375
coverage may be eligible for TRS-Care. More than 212,742 retirees
and their dependents participate in this plan. Aetna administers
the medical benefits; Express Scripts administers the pharmacy
benefits. Beginning in calendar year 2013, TRS-Care will begin
offering a Medicare Advantage Plan and a Medicare Part D
prescription drug plan in addition to the standard TRS-Care
coverage.
3.1.4. An optional long-term care insurance program for eligible
retirees and public school
employees. Certain family members are also eligible. The plan is
available on an enrollee- pay-all basis. The group long term care
insurer is always selected by the TRS Trustees following a
competitive bidding process. The current group long term care
insurer is Genworth Life Ins. Co. (Genworth), a part of Genworth
Financial.
3.2. TEAM Program Description
This section provides an overview of the TEAM Program organization.
Note that this is the ‘Program’ organization and not the agency
organization.
3.2.1. TEAM Program Organization
3.2.1.1. The TRS Board of Trustees (Board) is responsible for the
administration of the
system under provisions of the state constitution and laws. The
Board will receive routine and ad hoc status reports, and serve as
the final decision- making authority for the TEAM Program. The
board is composed of nine appointed trustees with staggered terms
of six years.
3.2.1.2. Independent Program Assessment (IPA) will provide an
independent assessment of the TEAM Program, interface with other
project contractors, and provide analyses and status reports to the
Board and the Executive Director, or the Executive Director’s
designee.
3.2.1.3. The Executive Sponsor will provide ongoing, day-to-day
oversight of the TEAM Program and leads the Executive Steering
Committee.
3.2.1.4. The Executive Steering Committee (ESC) provides ongoing
oversight of the TEAM Program and reports to TRS’ Executive
Director. ESC Members include the Executive Sponsor, Chief Benefit
Officer; Chief Financial Officer; Director of Healthcare Policy and
Administration; Chief Information Officer, Human Resources
Executive (non-voting, advisory) and Chief Audit Executive (non-
voting, advisory).
3.2.1.5. The State of Texas Quality Assurance Team’s (QAT) primary
purpose is to review the status of major information resources
projects, based on a framework of templates, reports and processes,
and to make recommendations to the legislature to reduce risk of
project overruns and failures. TRS is reporting under the
Department of Information Resources (DIR) Texas Project Delivery
Framework for the TEAM Program.
3.2.1.6. TRS Enterprise Risk Management (ERM) is responsible for
providing risk assessment facilitation and identification for TRS.
ERM interfaces with TEAM Program Management, the Executive Steering
Committee, Core Management Team and the Project Management Office
(PMO).
Page 8 of 375
3.2.1.7. Core Management Team (CMT) is responsible for the daily
operation of the TEAM Program. This team reports to the TEAM
Executive Steering Committee and is comprised of managers and team
leads including, but not necessarily limited to: Benefit
Accounting; Benefit Counseling; Benefit Processing; General
Accounting; and Information Technology.
3.2.1.8. TEAM Program Manager acts as a liaison between the TEAM
projects and selected contractors under the direction of TEAM CMT
and TEAM ESC. The TEAM Program Manager is responsible for overall
Program management and review of the various Program elements
(e.g., data management, reporting entity outreach, new Pension
Administration Line of Business (LOB) system solution, and other
associated Program elements) and will provide independent objective
advice, recommendations, and solutions to achieve Program success,
transparency, and delivery.
3.2.1.9. TRS Project Management Office (PMO) and the TEAM Program
Manager will provide project management of the projects that
comprise the TEAM Program. Daily project management includes: risk
identification and mitigation; issue tracking and resolution;
project scheduling and resource loading; project status reporting;
deliverable review; and requirements traceability.
3.2.1.10. Core Program Team (CPT) supports the entire TEAM Program
and consists of
Business Process Managers, Business Process Analysts, and the
Solutions Architect, all of whom are one hundred percent (100%)
dedicated to the TEAM Program and each project within the TEAM
Program.
Page 9 of 375
Page 10 of 375
3.2.3. TEAM Program: Project Descriptions
The TEAM Program is a cohesive collection of projects that, upon
completion, will enable TRS to meet business and technology
objectives over the next ten to twenty (10-20) years. The following
projects make up the TEAM Program and will be conducted at various
stages throughout the new LOB development cycle. Additionally,
these projects may be scheduled to run concurrently or individually
and the individual projects may be conducted by TRS staff or by
contractors.
3.2.3.1. Pension Administration Line of Business (LOB) System
Replacement
Project
The Pension Administration Line of Business (LOB) System
Replacement project is at the core of the TEAM Program. The LOB
project is singularly larger and more complex than all of the other
projects combined, for it is the vehicle that delivers the
administration of benefits. The LOB project will provide all of the
necessary functionality to support every transaction that can occur
during the life of the relationship between a member and an
employer with TRS. This includes replacing functionality found in
TRS’ current internally developed and maintained pension
administration systems containing member contribution, benefit,
demographic, financial, and health care related data (including but
not limited to the following applications):
1. DCLM – Death claim application used to track the status of death
claims for active and retired TRS members.
2. HEIN – Health insurance application used to track information
about health insurance for retirees.
3. LGRS – The ledger application displays demographic and financial
information
(including financial history) for members past and present.
4. MEMR – The member records application used to maintain and
display demographic, service, and salary information for TRS
members including historical information.
5. REFM - The refunds application that tracks refund information
when people
terminate TRS membership and request the return of their
contributions and any posted interest.
6. RETP – The retirement setup application used to transition
members to a retiree
status.
7. TRAQS – The TRS Reporting and Query system is used by the
reporting entities (e.g., school districts, higher education
institutions, service centers, and charter schools) to provide
contract, contribution, and salary information for TRS members and
it is used internally for the management of the reporting and
financial functions.
8. SSBB – The special service buy back application is used to track
the status and
payments for service purchases. It includes functionality for the
monthly installment payment option and tracking incoming rollover
payments.
Page 11 of 375
3.2.3.2. Data Management Project
The Data Management Project will prepare TRS’ data for migration to
the new LOB. To ensure that the data contained in the new LOB is
accurate, complete and consistent, TRS needs to analyze existing
data on all platforms to determine the scope of potential data
issues and identify redundant data that can be eliminated with the
modernization effort. TRS can then address the issues and eliminate
redundancies by correcting the data through a conditioning process.
Appropriate data will then be ready to migrate to the new
LOB.
3.2.3.3. Financial System Replacement Project
The Financial System Replacement Project (FSR) will replace the
current General Ledger Accounting System (GLAS) and the Budget,
Expense and Vouchering System (BEVO). In addition to financial
management functionality, purchasing and contract management,
budget planning, and human resources and payroll management
functionality is included within the FSR scope.
3.2.3.4. Organizational Change Management Project
The Organizational Change Management (OCM) Project addresses the
unique challenges that arise when implementing a large initiative
such as TEAM. It involves strategies to help TRS employees
transition to the new business processes, roles and
responsibilities resulting from TEAM with the least amount of
confusion, resistance, and anxiety possible. The OCM efforts are
distinct from technical project change management activities.
3.2.3.5. Business Rules Project
The Business Rules Project is chartered with creating a single
source for recording and maintaining business rules. The business
rules need to be maintained as frequently as changes occur and be
readily available to both internal and external parties who may
need the rules, including TRS staff and potential or current
contractors.
The Business Rules Project will capture all TRS business rules
related to the LOB in a template to be developed for this purpose.
The project consists of two teams: a writing team that will prepare
the templates and draft initial business rules, and a
review/approval team that will review and approve all business
rules as they are prepared for accuracy and completeness of
information.
3.2.3.6. Reporting Entity Outreach Project
The Reporting Entity Outreach Project will prepare Reporting
Entities, Education Service Centers, and Software Providers
(collectively referenced here as “REs”) to use the new LOB,
including a new web interface, reporting format, queries, reports,
enrollment and payroll reporting screens. To ensure that REs are
fully prepared, the project includes frequent communication with
REs, and comprehensive training for all REs on the new screens,
queries, report submission process, and other features of the new
web interface.
This project will also help to ensure that all REs have as much
time as possible to change their current reports. New reporting
formats will be provided to the REs as soon as they’re available
and all REs will be provided with access to a testing environment.
Each RE will
Page 12 of 375
submit report(s) to a certification environment for final
validation and approval which will help to ensure a successful
transition to the new LOB.
3.2.3.7. Business Procedures and Training Project
The Business Procedures and Training Project will ensure that TRS
staff is trained on new business processes and are well-prepared to
use the new LOB. This will be accomplished by developing desk-side
procedures and conducting a comprehensive training program for all
staff which covers all features and functionality of the new
LOB.
3.2.3.8. Legacy System Decommissioning Project
TRS has determined that the new LOB will be implemented in stages.
As functionality becomes available in the new LOB following each
staged implementation, there will be components of the current TRS
legacy system(s) that need to be turned off (decommissioned,
disabled, or removed.) Examples of items included in the
decommissioning effort are disabling or removing full and partial
screens, reports, batch jobs, etc.
The decommissioning effort requires changes to the TRS Legacy
system(s). When TRS decommissions components of the legacy
system(s), TRS has to test to be certain those changes do not
affect other associated TRS legacy system components or programs
that are still needed. This testing also ensures that the remaining
components in the TRS legacy systems(s) continue to work properly
with the new functionality provided by the new LOB. The Legacy
System Decommissioning Project is responsible for managing the
updates, testing, and deployment of the remaining portions of the
TRS legacy system(s) at each stage of deployment of the LOB.
3.2.3.9. Maintenance & Enhancements (M&E) of the New
LOB
After functionality in the new LOB is deployed into production
there will be a need to maintain (fix) and possibly enhance the new
LOB functionality. The M&E of the new LOB will be responsible
for managing the development, testing and deployment of the
maintenance and enhancements in the new LOB.
3.2.3.10. TRS Website Enhancements
Maintaining and improving the external TRS website are ongoing
responsibilities that are included in the TEAM Program. The website
was last updated in December, 2006. The project to enhance the TRS
Website will ensure consistency with the look and feel with the
LOB, enhance the website with new functionality, and provide
additional security. Usability changes that will make it easier and
faster to find information on the TRS website are also required.
These enhancements will allow TRS to provide enhanced services to
participants.
Page 13 of 375
4. Objective The goal of the Pension Administration Line of
Business System Replacement RFO and the resulting project is for
the Teacher Retirement System of Texas to select an experienced,
successful public pension solution contractor that will develop and
implement a cost effective, efficient, and sustainable program of
business and technological functionality and processes that will
enable TRS to serve the expanding and ever-changing needs of its
customers. The Pension Administration Line of Business System
Replacement project will be part of the TEAM Program that TRS has
undertaken. The LOB project shall include the following business
and technical functionality and processes:
a. General LOB b. 1099R c. Annuity Payroll d. Audit e. Benefit
Adjustments f. Benefit Calculation g. Benefit Estimates h. Cash
Receipts i. Check Payment j. Contact Management k. Conversion and
Bridging l. Death Benefits m. Disability Benefits n. Employer
Reporting o. Employer Setup p. Enrollment q. Health Insurance r.
Legal Orders s. Member Account Maintenance t. Member Statements u.
Refunds v. Retirement Application Process w. Retirement System
Transfer x. Service Credit Calculation y. Service Credit Purchase
z. Statistical Reporting aa. Sub ledger bb. Training and Agency
Support cc. Web Self-Service dd. Workflow ee. General Technical ff.
Hardware gg. Software hh. Disaster Recovery ii. Post Implementation
Support jj. Security
Page 14 of 375
SECTION II – GENERAL OFFER INFORMATION Respondents must read this
Section II carefully. TRS may disqualify a Respondent’s Offer if
the criteria listed in this Section II are not met, demonstrated or
provided. 1. Respondent Minimum Qualifications This RFO contains
minimum qualifications a Respondent must meet to be considered for
a contract award. See Section II, 13.3, TAB 2 below for a detailed
description of minimum qualifications.
2. Point-of-Contact for this Procurement
John Dobrich, CPPB, CTPM, CTCM Purchasing and Contracts Manager
Teacher Retirement System of Texas 1000 Red River St. Austin, TX
78701-2698 Telephone: (512) 542-6569 Email:
[email protected] Respondents shall make no contact
concerning this RFO with TRS Board members, TRS management, or
other TRS personnel, except to the Point-Of-Contact listed above.
Failure to comply with this requirement may result in
disqualification of Offer.
3. Deadline for Submission of Offer
The deadline for submitting a response to this Request for Offer is
Friday, April 12, 2013 at 2:00 p.m. Central Time (CT).
4. Calendar of Events
This information is provided for planning purposes only and is
subject to change as TRS deems necessary. Any changes affecting the
schedule up to and including the point of the RFO Response Due
Dates will be effected via the issuance of an addendum (see Section
II, 7.)
DATE EVENT
January 23, 2013 Posted to the Electronic State Business
Daily
February 21, 2013 at 2:00 p.m. C.T. Deadline for Submission of
Written Questions
February 21, 2013 at 2:00 p.m. C.T. Pre-registration deadline for
Mandatory Pre-Offer Conference Attendance via Audio
Conference
February 28, 2013 at 2:00 p.m. C.T. Mandatory Pre-Offer
Conference
March 18, 2013 Final Question and Answer Document Posted to the
Electronic State Business Daily
April 12, 2013 at 2:00 p.m. C.T. Technical Offer and Preliminary
Budget Estimate Due
May 6, 2013 to May 17, 2013 Respondents Site Visits to TRS –
Current Functionality Assessment
June 6, 2013 at 2:00 p.m. C.T. Detailed Price Responses to RFO
Due
Page 15 of 375
June 11, 2013 Finalists Notified
June 24,2013 to June 27, 2013 Finalists’ Interviews and Product
Demonstrations
July 10, 2013 Notification of Intent to Award Proof of
Concept
July 15, 2013 Start Contract Negotiations / Best and Final Offer
for Proof of Concept
July 31, 2013 to September 27, 2013 Proof of Concept
September 30, 2013 Notification of Intent to Award Pension
Administration Line of Business System Replacement
November 1, 2013 Start Contract Negotiations / Best and Final Offer
for Pension Administration Line of Business System
Replacement
October 21, 2013 Start Date of Contract for Pension Administration
Line of Business System Replacement
5. Events
5.1. Submission of Non-Disclosure Agreement Form
5.1.1. This RFO consists of separately provided Appendices
(Appendices 22 through 37), that contain information pertaining to
TRS computer systems that is sensitive and confidential. These
Appendices are referenced throughout the RFO. To obtain these
additional Appendices, interested parties must (1) indicate they
meet the minimum requirements stated in Section II, 13.3 TAB 2; (2)
indicate an intent to submit an Offer in response to this RFO; and
(3) execute a Non-Disclosure Agreement (See Attachment L) for this
information. To comply, interested parties must submit the
completed Non-Disclosure Agreement (Attachment L) via email to John
Dobrich at
[email protected] and the additional
Appendices will be made available. Additionally, if Respondent
reveals or uses any information that is derived from TRS’ sensitive
or confidential Appendices in an Offer, Respondent shall
conspicuously mark all such information as “Confidential” wherever
such information is revealed or used in the Offer.
5.2. Submission of Written Questions Requirements
5.2.1. Respondents may submit questions in writing regarding this
RFO prior to the Pre-Offer
Conference. Written questions must be submitted no later than 2:00
p.m. C.T. on Thursday, February 21, 2013. All questions shall, to
the highest degree possible, cite the specific RFO section and
paragraph number(s) to which the question refers. Selected
questions received by TRS prior to the date and time above will be
answered at the Pre- Offer Conference and all questions received
will be answered in a question and answer written document issued
by TRS. Only questions provided in writing and answered in writing
by TRS are official or binding.
5.2.2. All query submissions must include the identity of the
sender, the sender's title, as well as Respondent’s name, mailing
address, telephone number, and email address as applicable.
5.2.3. Questions must be submitted to the Point-Of-Contact via
email, postal mail, or hand delivery using the Point-Of-Contact
information found in Section II., 2. TRS is not responsible for
answering questions received after the submittal deadlines.
Page 16 of 375
5.2.4. Only information in the materials constituting this RFO,
including its appendices,
attachments, exhibits, and forms, the question and answer
document(s), and any RFO addenda issued shall be binding on
TRS.
5.3. Pre-Registration for Audio Conference Participation in the
Pre-Offer Conference
5.3.1. TRS requests that any Respondent who intends to participate
in the Pre-Offer
Conference via audio conference pre-register by sending an email to
the Point of Contact listed in Section II, 2 no later than 2:00
p.m., C.T. on Thursday, February 21, 2013. The contents of the
email shall include the following:
5.3.1.1. Subject Line: Pre-registration for Pre-Offer Conference
for Pension
Administration Line of Business System Replacement Services
5.3.1.2. Name of person attending the audio conference; 5.3.1.3.
Respondent’s company name and complete address; and 5.3.1.4.
Telephone number and email address of person attending the audio
conference. 5.3.1.5. Please ensure accuracy of this information as
it will be used to contact
Respondents in the event an addendum is issued.
5.4. Pre-Offer Conference
5.4.1. Mandatory Pre-Offer Conference
5.4.1.1. A mandatory Pre-Offer conference will be held at 2:00
p.m., C.T. on Thursday, February 28, 2013 in the cafeteria at TRS’
facility located at 1000 Red River Street in Austin, Texas. This
Pre-Offer Conference is mandatory. All Respondents are required to
attend either in person or via audio conference. Offers will only
be accepted from those Respondents who had a representative
attending the conference.
5.4.1.2. The purpose of this conference will be to highlight
specific RFO information, and
review questions received as well as TRS’ intended responses. Any
prospective Respondent attending this conference is encouraged to
raise additional questions or seek additional clarification. All
questions received as well as all additional questions and
clarifications will be addressed in the question and answer
document posted to the ESBD as specified in Section II., 5.5.
5.4.1.3. The Pre-Offer conference will be recorded.
5.4.1.4. TRS will conduct the Pre-Offer conference both in-person
and by audio
conference.
Page 17 of 375
5.4.1.4.1.1. TRS recommends in-person attendance at the Pre-Offer
conference. Respondents shall make arrangements to be at the
meeting at the listed starting time. Respondents attending
in-person will be required to provide information on a sign-in
sheet to verify attendance.
5.4.1.4.2. Audio Conference
5.4.1.4.2.1. TRS will make a reasonable effort to ensure the
availability
of audio conferencing.
5.4.1.4.2.2. TRS requests that any Respondent who intends to
participate via audio conference pre-register as stated in Section
II, 5.3.
5.4.1.4.2.3. Audio conference attendees are requested to call in no
later than ten (10) minutes prior to the meeting start time. A roll
call of pre-registered attendees will be conducted to verify
attendance.
5.4.1.4.2.4. TRS will not be responsible for technical
difficulties.
5.4.1.4.2.5. If more than one person is attending via audio
conference, please participate as a group and dial in from a single
number.
5.4.1.4.2.6. Dial-In Instructions:
To access the Pre-Offer conference specified dial toll free
877-820-7831. When prompted, use the passcode 674040 followed by
the pound sign (#) and you should be connected.
5.5. Answers Posted
5.5.1. Questions properly submitted and Answers to all questions
(See Section II, 5.2 above) will
be made available in writing on the Electronic State Business Daily
(ESBD) website (See Section II., 5.5.2 below) no later than the
date and time indicated in the Calendar of Events (See Section II.,
4).
5.5.2. The ESBD web address for this solicitation is:
http://esbd.cpa.state.tx.us/bid_show.cfm?bidid=104118
5.6. Submission of Technical Offer and Preliminary Budget
Estimate
5.6.1. Offers are due no later than 2:00 p.m., C.T. on Friday,
April 12, 2013. Offers submitted at this time shall include both
technical components (all of the requirements listed in Section
II., 13.3 below and the mandatory commitments as listed in Section
III. Scope of Work), as well as the estimated total price of the
Offer. All Respondents shall provide estimated pricing in the
format included as a separate file on the Electronic State Business
Daily (Attachment N). Please note this estimated pricing will not
be evaluated at the time of initial Offer submission, but will be
used
Page 18 of 375
for budgeting purposes. TRS will begin evaluating required
components, minimum qualifications, and performing an evaluation of
the Technical components of the Offer.
Submission of detailed pricing is required as described in Section
II., 5.8 below.
5.7. Respondents Site Visits to TRS – Current Functionality
Assessment
5.7.1. Upon completion of the initial evaluation of required
components and demonstration of minimum qualifications, TRS will
invite those Respondents TRS deems initially qualified for an
on-premises visit to TRS’ facility at 1000 Red River Street in
Austin, Texas to review and assess TRS’ current pension
administration system functionality. The Respondent will have the
opportunity to review existing hardware, software, processes, and
ask questions of staff. Each Current Functionality Assessment (CFA)
session shall last no longer than 8 hours over a single day and TRS
will work to schedule an appropriate time with qualified
Respondents; however, it is the Respondent’s sole responsibility to
be available for a CFA during the overall time period TRS has
allocated for this activity. TRS intends to complete the CFA
sessions quickly, thus the Respondent staff attending the CFA will
only be able to split into a maximum of two separate teams. The
Respondent attending the last CFA shall have a minimum of 13 days
to prepare detailed pricing.
5.7.2. This assessment is the opportunity for the Respondent to
appropriately price out the
following commitment as defined in the General LOB commitment
section:
5.7.2.1. ”Shall implement a system to allow for all of the current
core system functionality for the retirement plan and the active
member and retiree health care programs in order to perform
day-to-day business as defined in Revised Statutes of Texas
applicable to TRS and TRS Board rules in the Texas Administrative
Code. These provisions will be described in detail during the
requirement gathering sessions and documented. (See TRS Statutes in
Appendix 3)”
5.8. Submission of Detailed Price Responses
5.8.1. Detailed Price Responses are due no later than the date and
time indicated in the
Calendar of Events in Section II., 4. All Respondents shall provide
detailed pricing in the format included as Attachment N (a separate
file on the Electronic State Business Daily). Pricing must be
received in this format to allow accurate price comparison. FAILURE
TO SUBMIT TIMELY DETAILED PRICING MAY RESULT IN THE REMOVAL OF THE
OFFER FROM FURTHER CONSIDERATION FOR AWARD.
5.8.2. Offers submitted in response to this solicitation shall be
irrevocable for one hundred eighty (180) calendar days following
the closing date. This period may only be extended at the TRS
Purchasing Manager’s request, or the Purchasing Manager’s
designated agent, and with Respondent’s written agreement.
5.9. Finalists Notified
Page 19 of 375
5.9.1. While the exact number of finalists cannot be determined
until the evaluation committee has concluded their evaluation of
both Technical Offers and Detailed Price Responses received, TRS
intends to invite all qualified Respondents to the next phase of
the procurement process. TRS will notify a group of finalists no
later than the date and time indicated in the Calendar of Events in
Section II., 4. and allow sufficient time to prepare for Finalist
Interviews and Product Demonstrations.
5.10. Finalist Interviews and Product Demonstrations
5.10.1. Finalist Interviews serve the purpose of providing an
additional opportunity for both TRS
and the Respondent to clarify the requested services and the
Respondent’s Offer. Following the Finalist Interview process,
Finalists will have the opportunity to provide Product
Demonstrations to convey the features and capabilities of the
offered solution. Upon completion of the Product Demonstrations,
TRS’ evaluation committee will select the solutions that in TRS’
evaluation committee’s sole judgment would best meet TRS’ needs.
Representations made during Interviews or Demonstrations may be
documented and agreed upon. Once documented and agreed upon, these
representations may be incorporated into the Finalist’s
offer.
5.10.2. The Finalist Interviews and Product Demonstrations will be
held at:
Teacher Retirement System of Texas 1000 Red River St. Austin, TX
78701-2698
5.10.3. Respondent shall be available for a Finalist Interview in
accordance with the Calendar of
Events in Section II., 4. Respondents that are not available within
this timeframe may not be considered for a contract award.
5.10.4. Attendance of the key staff Respondent intends to assign to
the Pension Administration
Line of Business System Replacement Services Project is mandatory
at both the Finalist Interview and Product Demonstration.
5.10.5. Respondent’s key staff offered to perform work for TRS must
present all information during
the Finalist Interview. However, Respondent may have anyone present
information during the initial (30) minutes of the Interview.
5.10.6. Respondent is hereby notified that TRS’ evaluation
committee will rely on the accuracy
and content of information conveyed to TRS during Finalist
Interviews in forming opinions of the Respondent’s offered
solution. As such, TRS considers all information provided during
Finalist Interviews to be binding on Respondent and TRS intends to
record the Finalist Interview sessions. Representations made during
Interviews or Demonstrations may be documented and agreed upon.
Once documented and agreed upon, these representations may be
incorporated into the Finalist’s offer.
5.10.7. TRS will not be responsible for payment of any amounts
associated with the Finalist
Interview or Product Demonstration, either prior to, or after
contract award.
5.11. Review and Discussion
Page 20 of 375
5.11.1. When Offers are reviewed and evaluated, a contract may be
awarded. However, TRS may request Best and Final Offer (BAFO)
phases for both a Proof of Concept and the Pension Administration
Line of Business System award. If TRS elects to request a BAFO, TRS
may conduct discussions with Respondents who submitted Offers. In
this context, “discussions” means clarifying, modifying, or
negotiating. Additionally, after the initial evaluation TRS may
determine it is necessary to discuss acceptable or potentially
acceptable Offers with Respondents in order to determine a
Respondent’s ability to meet the RFO requirements. If discussions
are conducted for this purpose, Respondents whose Offers are found
to be acceptable or potentially acceptable may be given equal
opportunity to discuss their Offer with TRS and resubmit them
accordingly. In this context “potentially acceptable” means
reasonably susceptible to being made acceptable. No changes to
responses or prices shall be allowed after BAFOs are received
unless TRS, in its sole discretion, determines that resubmission is
in TRS’ best interest.
5.12. Best and Final Offer for Proof of Concept
5.12.1. TRS intends to invite a limited number of Finalists to
submit a Best and Final Offer (BAFO) to conduct a Proof of Concept
(POC). As the specific POC scope is anticipated to vary based on
the solutions Offered, TRS will further define the POC scope and
requirements when a BAFO is requested. With a BAFO response, the
Respondent may choose to modify the original Offer to (a) lower the
overall price of the offered solution, (b) increase the level of
features of the offered solution, (c) increase the level of
associated services provided for the offered solution, (d) provide
additional options not listed in this section, or (e) provide a
combination of these options, for the purposes of making the
original POC offered more attractive to TRS. Upon review and
evaluation of the POC BAFO response, TRS intends to contract with a
selected Finalist for preparation and implementation of a
POC.
5.13. Proof of Concept
5.13.1. TRS intends to contract with the selected Respondent to
prepare and implement a POC
for the offered solution, methods, or functionalities to
demonstrate the solution’s feasibility on a limited scale and in a
controlled environment. This POC is intended to provide TRS with a
broad understanding and a level of appropriate, demonstrated
success. The POC must establish a useable solution for TRS, the
ease of TRS configuration through hands- on experience for a select
group of subject matter experts, information technology personnel,
and users.
5.13.2. In the event the POC is not acceptable or unsuccessful, TRS
reserves the right to
terminate the POC and request a POC BAFO from another
Respondent.
5.14. Best and Final Offer for Pension Administration Line of
Business System
5.14.1. TRS intends to then invite the successful POC Respondent to
submit a Best and Final Offer (BAFO) for the Pension Administration
Line of Business System. As with the POC BAFO response, the
Respondent may choose to modify the original Offer to (a) lower the
overall price of the offered solution, (b) increase the level of
features of the offered solution, (c) increase the level of
associated services provided for the offered solution, (d) provide
additional options not listed in this section, or (e) provide a
combination of these options, for the purposes of making the
original Offer more attractive to TRS. Upon review and evaluation
of the BAFO response, TRS intends to enter into contract
negotiations.
Page 21 of 375
5.15. Selection and Contract Negotiations
5.15.1. Upon successful contract negotiations, TRS will award a
contract and both parties must execute the final contract
documents. At this time, the Respondent will be the Pension Line of
Business Contractor for the TEAM Program.
6. TRS Options Throughout Solicitation Process
6.1.1. TRS’ rights include, but are not limited to:
1. Cancellation of the RFO at TRS’ sole discretion; 2. Suspension
of the procurement process and/or issuance of RFO addenda; 3.
Rejection of any and/or all Offers received in response to the RFO;
4. Waiver of administrative deficiencies in Offers received; 5.
Requesting any Respondent to submit Offer modifications addressing
a subsequent
RFO amendment; and 6. Requesting any Respondent to clarify their
Offer and/or submit additional information
pertaining to their Offer.
7. Addenda
7.1. If specifications are revised, TRS will issue an addendum
addressing the specific change(s). Any addenda to this RFO will be
made available on the Electronic State Business Daily (ESBD)
website (See Section II., 5.5.2 above.) Respondents are advised
that they are solely responsible for checking the ESBD website for
any addenda prior to submitting a response to this RFO. Respondents
shall indicate receipt of all addenda issued by TRS on Attachment A
- Execution of Offer.
8. Offer Requirements
8.1. Responsibilities of the Respondent
Respondent shall adhere to the following requirements when
submitting an Offer:
8.1.1. Any assumptions made in the Offer must be specifically
identified in a highly conspicuous
manner and presented in written format;
8.1.2. Any exceptions to the RFO provisions must be specifically
identified in a highly conspicuous manner and presented in writing
identifying the specific RFO section and the exception taken (see
Section II., 13.3.3, Tab 10) along with a proposal for
modification. The quantity and substance of exceptions will be used
in evaluation of the quality of an Offer. Only noted exceptions
will be the subject of any contract award negotiations; and
8.1.3. TRS will not return any Offer submission.
9. Procurement and Contract Documents
9.1. TRS operating expenses are paid by a portion of the trust
assets that it administers. Consequently, TRS may be exempt from
some state law requirements applicable to
legislatively-appropriated
Page 22 of 375
general revenue funds. Nevertheless, TRS may conduct this
procurement in accordance with the rules of the Texas Comptroller
of Public Accounts (CPA), including, but not limited to, the
procedures prescribed by the CPA for the RFO process. TRS reserves
the right to vary from CPA rules and procedures when TRS determines
it has a legal responsibility to do so or it is in TRS’ best
interest. The contract terms for this procurement consist of the
provisions in this RFO (including its attachments, exhibits, and
forms), the Respondent’s Offer, and TRS’ Contract or Purchase
Order. The provisions of this RFO and those of any Contract and/or
Purchase Order resulting from this RFO shall control, in the case
of any conflict with any of the provisions in the Respondent’s
Offer, except as otherwise noted on the Contract and/or Purchase
Order.
10. Respondent Forms
10.1. TRS will neither sign nor agree to be bound by any of the
Respondent’s form documents or agreements. Should the Respondent
desire to expound on how the Respondent will satisfy the
specifications, terms and conditions of this solicitation, the
Respondent shall do so without reference to any form documents or
agreements.
11. Waiver of Claims
11.1. By submitting an Offer, Respondent agrees to waive any claim
it has or may have against TRS, TRS board members, and/or TRS
employees, arising out of or in connection with the administration,
evaluation, or recommendation of any Offer, the waiver of any
requirements under the RFO, the acceptance or rejection of any
Offer, and/or the award of a contract.
12. Disclosure of Offers Under the Public Information Act
12.1. Respondents are advised that information included in their
Offer is subject to the Texas Public Information Act, Chapter 552
of the Texas Government Code (the Act). Information a third party
submits to or prepares on behalf of TRS is subject to the Act and
must qualify for an exception provided by the Act to be withheld
from public disclosure. Information is not confidential under the
Act simply because the party submitting the information anticipates
or requests that it be kept confidential.
12.2. TRS cannot bring information within an exception to
disclosure under the Act merely through a
contract or agreement to keep the information confidential.
Accordingly, a Respondent whose Offer may include information that
Respondent believes in good faith to be proprietary or commercial
information and that Respondent otherwise keeps confidential for
competitive reasons, is responsible for identifying and proving
that such information qualifies for an exception to public
disclosure under the Act. Each item of such information must be
separately and conspicuously labeled “Confidential Proprietary
Information” and the Respondent must state in its Offer that the
labeled information would not have been provided to TRS, if
Respondent knew the information would be disclosed publicly.
12.3. When Respondent marks or identifies any confidential,
proprietary, or commercial information within
its Offer, Respondent shall list in a separate attachment to its
Offer a listing of section reference, and page number of all such
confidential information.
12.4. TRS, its trustees, officers, employees, agents, attorneys,
and any trust fund managed by TRS shall
not be liable for any disclosure of any information submitted in a
response to this RFO. By submitting an Offer, Respondent waives any
claim against, and releases from liability, TRS, its trustees,
officers, employees, agents, attorneys and/or any trust fund
managed by TRS with respect to disclosure of any information
included in the Offer, including information labeled as
“Confidential
Page 23 of 375
Proprietary Information.” Respondent also authorizes TRS, at its
sole option, to submit any information contained in the Offer,
including information Respondent has labeled as being confidential
and proprietary, to the Office of the Attorney General for a
determination as to whether any such information submitted by
Respondent may be excepted from public disclosure under the Act,
either by its provisions alone or in conjunction with other law.
For the purpose of asking the Office of the Attorney General to
determine whether an exception to disclosure exists for information
Respondent deems to be confidential and proprietary, TRS will
submit to the Office of the Attorney General for its consideration
only that information Respondent has specifically labeled
“Confidential Proprietary Information” to the Office of the
Attorney General for consideration. If TRS does not have a good
faith belief that information may be subject to an exception to
disclosure, TRS is not obligated to submit the information to the
Office of the Attorney General. Consequently, Respondent should not
expect TRS to submit to the Office of the Attorney General an
entire Offer that Respondent has labeled “Confidential Proprietary
Information.”
13. Offer Instructions
13.1. Receipt by TRS Respondent’s Offer shall be physically
received by TRS no later than the date and time listed in the
Calendar of Events (Section II., 4). Facsimiles and emails of the
Offer will not be accepted.
Responses shall be mailed or delivered to: Teacher Retirement
System of Texas 1000 Red River Street, Room 416E Austin, Texas
78701-2698 Attn: John Dobrich
When submitting an Offer by regular mail, certified mail, or
express mail, or delivery service, it is incumbent upon Respondent
to allow for sufficient time to permit delivery by the U.S. Postal
Service or any other delivery service or agent and by mail services
internal to TRS. THE OFFER SHALL BE RECEIVED BY TRS LOCATED AT 1000
RED RIVER STREET, AUSTIN, TEXAS BY THE REQUIRED DEADLINE. TRS’
MAILROOM TIME AND DATE STAMP WILL BE THE FINAL DETERMINANT OF
WHETHER AN OFFER HAS BEEN TIMELY RECEIVED BY TRS’ PURCHASING AND
CONTRACTS DEPARTMENT. OFFERS RECEIVED BY TRS AFTER THE DUE DATE AND
TIME SHALL BE REJECTED. 13.2. Offer Submission and Formatting The
Respondent shall format the Offer using the following rules.
Replace the text between the <> symbols with the
corresponding requested information:
13.2.1. Delivery and Labeling
13.2.1.1. All documents associated with Respondent’s Offer (minimum
qualifications, technical, pricing, and others), and copies
thereof, shall be received at TRS prior to the response deadlines
listed in Section II., 4.
13.2.1.2. The Respondent shall deliver all response documents and
copies in a sealed
container labeled with:
13.2.1.2.1. <Respondent’s legal name and address> - in the
upper left corner of the top side of the container;
Page 24 of 375
13.2.1.2.2. <TRS Name and Address> - in the center of the top
side of the
container; and
13.2.1.2.3. <RFO No. 0123136A-JD for Pension Administration Line
of Business System Replacement Services, Due Date: April 12, 2013
at 2:00 p.m. CT> - in the lower left corner of the top side of
the container for the Submission of Technical Offer and Preliminary
Budget Estimate.
13.2.1.2.4. <RFO No. 0123136A-JD for Pension Administration Line
of
Business System Replacement Services, Due Date: June 6, 2013 at
2:00 p.m. CT> - in the lower left corner of the top side of the
container for the Submission of Detailed Price Responses.
13.2.2. Offer Formatting
13.2.2.1. The Respondent shall submit seven (7) printed copies of
the Offer. Each copy
shall be stored in a 3-ring binder.
13.2.2.2. If supplemental materials are included with the Offer,
each copy of the Offer must include such supplemental materials.
All Offers and accompanying documentation become the property of
TRS and will not be returned.
13.2.2.3. In addition to the seven (7) copies, the Respondent shall
submit one (1) printed
copy of the Offer with the words “Master Copy” marked on the title
page and on every page header. The “Master Copy” shall (1) be
unbound; (2) contain no divider sheets or tabs; (3) be printed on
one side only of 8-1/2 in. x 11 in. white paper to enable copying
if needed; and (4) be a complete copy of all information submitted
with Respondent’s Offer. Colors must reproduce in a legible manner
on a black-and-white copier.
13.2.2.4. One (1) complete copy of the “Master Copy” of the Offer
shall also be submitted
on electronic media (e.g., USB Drive [TRS’ preference], CD-ROM, or
DVD- ROM) in a Microsoft Office (Word, Excel, Project and
PowerPoint files) version 2003 or later format, or searchable Adobe
.PDF files. Pertaining to the electronic version, Respondent shall
submit separate electronic files containing (1) Attachment A –
Execution of Offer, and (2) Confidential Information. In the event
Respondent submits information with the Offer that Respondent
wishes to assert a claim of protection from disclosure (e.g.,
Confidential, Proprietary, or any other form), Respondent shall
ensure such information is included in a separate electronic file
with the words “Confidential Information” included within the
filename.
13.2.2.5. Every page shall contain the Respondent’s legal name in
the header.
13.2.2.6. Every page footer shall contain “Page <page number>
of <total pages>” and
<submission date>
13.2.2.7. A legally authorized representative of the Respondent’s
company shall manually sign the printed “Master Copy” of the
Offer.
Page 25 of 375
13.3. Offer Content and Organization
13.3.1. The submitted Offers shall be titled “Pension
Administration Line of Business System Replacement Services” and
shall clearly show the due date and time.
13.3.2. Respondent’s submitted Offer shall include all information
and be organized as
required below. Offers will be evaluated based on the responses to
the information below. Respondents shall provide their best
response to the specifications, terms and conditions contained in
this RFO. Each Respondent shall be solely responsible for its
thorough understanding of the RFO, including its attachments,
exhibits, and forms. In addition, each Respondent shall be solely
responsible for its Offer and all documentation submitted.
Respondents are cautioned to pay particular attention to the
clarity and completeness of their Offer. It is TRS’ intent to
receive offers that provide substantive information to address the
specific areas listed below and not pre-prepared marketing
materials. Respondent shall provide detailed descriptions of how
they will fulfill each requirement. The clarity and completeness of
the Offer may be considered by TRS’ evaluators. TRS has no
responsibility to point out weaknesses in an Offer that result from
a lack of diligence, competence, effectiveness, or creative
solutions.
13.3.3. Respondent shall provide written responses to each of the
following areas
identified in the tab sections below reproducing the original
information request or question with each answer. TRS shall view
responses to the following Tabs and questions as current
capabilities of the Respondent’s solution. Further, TRS will assume
that all features and functionality described therein will be
delivered for the quoted not-to-exceed price presented in the
Respondents’ pricing offered. If Respondents wish to provide
information on Optional functionality that is not included in the
price offered, Respondent shall explicitly state as much in every
applicable case and include not-to-exceed pricing for such Optional
functionality with the Offer.
TAB 1. EXECUTIVE SUMMARY Respondent shall provide a concise
description of its approach to meeting TRS’ requirements for
Pension Administration Line of Business System Replacement
Services. This description shall not exceed ten (10) pages.
Respondent shall include the highlights of Respondent’s Offer,
including an overview of its plan and/or schedule. Unique
characteristics of Respondent’s Offer shall be emphasized. TAB 2.
MINIMUM QUALIFICATIONS In this section, Respondent shall state how
Respondent and/or specified personnel meet the minimum
qualifications reproducing the qualification with each answer.
Failure to fully address each qualification and to document
Respondent’s specific experience in meeting each qualification may
be cause to disqualify the Offer. TRS has no obligation to seek any
clarification or additional information. A statement that
Respondent “meets the requirement” is not a sufficient response.
Offers not meeting the minimum qualifications will not be reviewed
or evaluated. 1. Company Qualifications
Page 26 of 375
a. Respondent’s company shall have a minimum of five (5) years of
experience implementing public pension systems. Provide the names
of the organizations and a contact for each including the contact’s
information.
b. Respondent’s company shall have a minimum of three (3)
successfully completed public pension system implementations; one
(1) of which must be an entity in the United States. State the
names and locations of the organizations.
c. Respondent’s company shall have a minimum of two (2)
successfully completed
public pension system implementations with a membership size of two
hundred thousand (200,000) or greater.
d. Respondent’s company shall have successfully implemented
web-based pension
functionality, for a public pension plan in the United States,
within the last three (3) years.
2. Key Personnel Qualifications
a. Respondent’s Account/Project Manager, Solutions Architect, and
key Business Analysts must have 3 years of experience working on a
public pension system replacement project in the proposed role. Key
Business Analysts include at a minimum the lead analyst for active
membership, benefits, and financials.
b. Respondent’s Development Manager and Quality Assurance Test
Manager must
have 1 year of experience working on a public pension system
replacement project and 3 years in the proposed role.
TAB 3. ORGANIZATIONAL BACKGROUND Respondents shall review and
answer this section carefully. Omissions or non-responsive
information may result in disqualification of Offer. 1. State
Respondent’s full name and home office address. Describe
Respondent’s
operational structure and legal form of business (e.g.,
corporation, partnership, sole proprietor, etc.) and where it is
legally organized (e.g., Texas, Delaware, etc.). Identify the
locations of the headquarters and/or branch offices that would be
providing services under the contract. State how many employees are
at the location(s) where contract-related services will be
performed. If the office providing services is not in Texas,
describe how the organization would service TRS if awarded a
contract. If the Respondent is providing an offer on behalf of one
or more individual entities, Respondent shall provide this
information for each individual entity as well as state the
relationship of the individual entities. Please limit the
information requested in this section to five (5) pages.
2. Respondent shall provide a discussion of the Respondent’s unique
qualifications which set them apart from other pension line of
business solution companies. The Respondent shall limit the
discussion to two (2) pages.
3. Respondent shall provide financial statements: income
statements, balance sheets, and cash flow statements for the most
recent three (3) years, if available. If not specifically stated in
the previously requested documents, the Respondent shall
state
Page 27 of 375
the percentage of their revenue and profits attributed only to
pension system implementations where the Respondent was the prime
contractor, if available.
4. The Respondent shall provide a copy of their current
Comprehensive Insight Plus Report from Dunn and Bradstreet. If not
available, Respondent shall explain the unavailability.
5. Describe Respondent's processes and procedures to protect both
hard copy data and
electronic information from intrusion or unauthorized
dissemination. 6. Describe Respondent’s implementation and
documentation of a comprehensive
information-security program. Respondent shall use, implement, and
document reasonable and appropriate security practices to make all
data and information secure.
7. Describe Respondent’s business continuity plan for the recovery
of Respondent’s
electronic data and data processing equipment and how the
Respondent assures that the data processing system will be
operational within ten (10) days of a natural disaster, or any
other business interruption, whether natural or otherwise.
8. State whether during the last ten (10) years Respondent has been
involved in or is currently in a lawsuit involving a regulatory
action.
9. State whether Respondent has ever been involved in or is
currently involved in a lawsuit involving any services similar to
the services requested by this RFO. If so, provide details,
including dates and outcomes.
10. State whether during the past five (5) years Respondent,
related entities (affiliates under common ownership), principals,
or officers have been a party in any civil or criminal litigation,
whether or not directly related to services similar to those
requested by this RFO. If so, provide details, including the name
(style) of the case, the jurisdiction (court in which it was
filed), dates the litigation was started and ended, and
outcome.
11. State whether Respondent, its principals, officers, or
directors has ever been involved in any regulatory proceeding,
judicial proceeding or litigation, of any kind, with TRS. If yes,
please describe.
12. State whether Respondent, its principals, officers, or
directors has ever been (1) required to return public funds for
failure to perform on a contract; (2) in breach of a public
contract; or (3) disbarred from contracting with any (i) State of
Texas agency, (ii) federal agency, (iii) political subdivision,
(iv) any public pension plan, or (v) of any state or territory. If
yes, please describe.
13. Provide a copy of Respondent’s Certificate of Insurance showing
coverage limits. TRS’ insurance requirements are stated in Section
V., 1.24. State whether Respondent will comply with the
requirements as stated in the referenced section.
14. TRS is interested in insurance or other financial instruments
for Security & Privacy
(Cyber) and Media Liability to cover cyber risk, data breach, and
improper personal information disclosures. Describe how insurance
coverage would be made available to TRS to cover these risks.
Page 28 of 375
15. Respondent shall acknowledge that all individuals assigned to
provide services to TRS are subject to background checks in
accordance with Section V., 1.13.
TAB 4. QUESTIONNAIRE Business Solution The following section has
specific questions concerning the Respondent’s business
solution.
1. Cash Receipts
As part of the TEAM Program, TRS is replacing both its financial
systems and its pension LOB system. It is expected that the new
Financial System will be in production before the first phase of
the Pension LOB solution is implemented. Today, TRS uses
functionality in its in-house financial system (GLAS) for managing
and recording all cash receipts, whether they are financial related
or pension related. The existing TRS process is described in detail
in the Cash Receipts Additional Functionality section below. In the
future, TRS will look at the Cash Receipts functionality in both
the proposed LOB Solution and the Financial system to determine
which is best suited to handle processing and management of cash
receipts. The LOB Solution shall have, at a minimum, the
functionality outlined in the Cash Receipts Commitments described
in this RFO. In addition to those commitments, TRS requests
Respondent to provide answers to the following questions.
1.1. In previous implementations of the Respondent’s solution,
describe how the LOB
solution has integrated with financial solutions as it relates to
Cash Receipts.
1.2. How did the financial system process all cash receipts and
flow necessary data back to the LOB solution?
1.3. How did the LOB solution handle all cash receipts and forward
the non-pension-
related receipts to the financial system for processing?
1.4. Were there multiple cash receipt processes for different types
of cash receipts?
1.5. What is the Respondent’s recommendation?
1.6. If TRS wanted to use the LOB Solution for all incoming cash
receipts, both LOB related and non-LOB related, describe how
Respondent would implement the additional cash-receipts control
functionality described in the Cash Receipts Additional
Functionality section below.
2. Cash Receipts Options Pricing
1.1. Respondent shall include Optional pricing for Pension LOB
integration with an
external financial system for all incoming cash receipts.
Respondent shall use the format included as a separate file on the
Electronic State Business Daily (Attachment N).
Page 29 of 375
1.2. Respondent shall include Optional pricing for the LOB Solution
to provide the
additional functionality outlined in the Cash Receipts Additional
Functionality section below. Respondent shall use the format
included as a separate file on the Electronic State Business Daily
(Attachment N).
Cash Receipts Additional Functionality
1 Shall provide functionality to view, add, update, delete, search,
cash
receipts 2 Shall assign a unique sequential register number
for each incoming cash
receipt as mail is opened in the mailroom
3 Shall provide functionality to collect multiple cash receipts in
a batch or group for delivery by the mailroom to the
cashier
4 Shall provide total number of cash receipts in each batch
processed by the mailroom
5 Shall not limit the number of cash receipts in each batch
processed by the mailroom
6 Shall provide total dollar amount of cash receipts in each
batch
7 Shall capture and track various deposit types as defined by TRS
and/ or reason codes for certain actions.
8 Shall provide the ability to create a deposit slip (based on CPA
requirements) and interface transactions to USAS
9 Shall provide the ability to create a deposit transaction with
workflow and approval
10 Shall be able to track multiple incoming checks for one
(lockbox) transaction. Note: Lock box records do not contain check
numbers.
11 Shall provide the ability to require different steps of the cash
receipt process to be completed by different staff members for
purposes of verifying cash receipt totals and amounts (both
individually and by batch).
Technical Solution
The following section has specific questions concerning the
Respondent’s technical solution.
TRS seeks an infrastructure solution that will allow TRS to meet
its business and technology objectives over the next 10 to 20
years. The core of this will be the modernization solution
architecture for the TEAM Program. The modernization solution is
comprised of functionality components that are utilized by TRS to
perform its day-to-day business. These components, when integrated,
form the underlying architecture that supports all pension
administration activities. This includes components such as
imaging, workflow, customer contact/relationship management,
pension administration,
Page 30 of 375
communications, financial/HR application, security, reporting,
business rules management, etc.
The primary functional needs that must be addressed by a
modernization solution adopted by TRS are:
1. The solution must support and provide efficient daily operations
to process and respond to member and annuitant requests.
2. The solution must provide dynamic and functional self-service
interfaces for external constituents to conduct business with TRS
through the most common communications channels available and be
able to incorporate new channels as needed.
3. TRS staff must have a dynamic set of role-based interfaces that
allow consistent and efficient interaction with any application
needed to provide service to constituents.
4. The solution shall contain well-defined data management and
governance services.
5. The solution must be built to accommodate change through
extensibility and loosely coupled integration.
Just as TRS is focused on providing service to its stakeholders, so
must the modernization solution be service-oriented. To accomplish
this, the foundational technologies used to build the modernization
solution must be service-oriented and employ common methods for
invoking services. These technologies must allow for technical,
process or application change without significant impact to other
components of the solution through loosely coupled integration and
flexible extensibility processes. This is most readily accomplished
by implementing a solution based on the Service Oriented
Architecture (SOA) principals of software development. SOA is a set
of principles and methodologies for designing and developing
software in the form of interoperable modular services. These
services are well-defined business functionalities that are built
as stand-alone software components which can be reused for
different purposes. The premise of a SOA is that modular services
can be assembled into new applications, therefore leveraging
application and infrastructure investments. SOA reduces complexity
and rigidity of applications, promotes the integration of diverse
systems, and allows applications to be dynamic, so they can be
built to readily accommodate change. After a thorough review of the
approaches taken by other public pension systems, pension
administration framework vendors, and modern software design and
development methodologies, the architectural approach shall be to
build a composite application framework (See Appendix 18). This
solution architecture has the least associated risk and can be
delivered in the shortest timeframe. It also best meets the stated
primary functionality needs by:
1. Employing pre-built and pre-tested application modules 2.
Allowing for the integration of new technologies in the future 3.
Allowing TRS’ resources to customize the solution as needed 4.
Using experienced vendor resources to assist with customization 5.
Minimizing the impact of future change
Page 31 of 375
6. Establishing a methodology for developing and integrating new
applications in the future
An additional benefit of this approach is that it gives TRS the
ability to deploy the new solution in phases rather than an “all at
once” implementation. A phased implementation approach refers to
structuring the implementation into two or more well-defined stages
and selecting different implementation dates for each stage. Each
implementation is limited to a controlled number of organizational
units or business functional areas, so it allows for a more focused
goal during each phase. This approach has the following
benefits:
1. Reduces disruption to the production environment 2. Performance
issues that occur can be quickly isolated and rectified 3. Allows
for staggered training 4. Allows for a more iterative approach so
reviews can be conducted after each
phase and lessons learned can be incorporated into subsequent
phases. This further reduces risk and helps ensure the success of
the TEAM Program. The Respondent that is selected to provide a
Proof of Concept (POC) will be required to demonstrate its proposed
technical solution by developing a working Proof of Concept that
will meet TRS’ needs as defined in this RFO. 1. Deployment Options
and Topology
1.1. In what operating environment and hardware platform is the
Respondent’s
system most commonly deployed?
1.2. In what operating systems (Windows, Linux etc.) and run-time
environments (application servers) has the Respondent’s solution
been validated or certified?
1.3. What other environments does the Respondent expect to support
in the next 2 –
5 years?
1.4. Describe the overall deployment topology (and options) in
terms of server and server software requirements including their
role or purpose in the architecture (i.e. web servers, app servers,
report servers and database systems).
1.5. Include 3rd party software options and currently supported
versions of each.
2. Hardware Architecture Diagrams
The Respondent should refer to the Composite Framework Architecture
(See Appendix 18), which represents a recommended SOA.
1.1. Provide architecture diagrams that depict the two deployment
scenarios below
including Internet facing and internal/Intranet system components.
The diagram shall also include any external dependencies (other
than basic network components) that are critical to the system’s
operation such as load balancers, user authentication or shared
file systems.
For these configurations please consider:
Page 32 of 375
1. Fault tolerance throughout each tier 2. Load balancing at the
web and application tiers 3. Database sizing and deployment
recommendations
a. TRS-Compatible Configuration: Using performance goals stated in
Section II.,
Technical Solution, 16. Warranty, below and given TRS’ referenced
infrastructure architecture (see Appendix 23), please provide a
configuration (e.g., server types, server quantities, load
balancing configurations etc.) that leverages TRS’ existing
infrastructure to the extent possible.
TRS will estimate infrastructure costs based on the information
provided above. Please provide detail sufficient for TRS to
determine needed infrastructure investments.
b. Respondent Designed Configuration: Using performance goals
stated in the
Section II., Technical Solution, 16. Warranty, below and Section
IV., 1.7 - Warranty, provide a recommended configuration (e.g.,
server types, server quantities, load balancing configurations
etc.), which can be deployed in TRS’ data center with no explicit
requirement to adhere to TRS referenced infrastructure architecture
(Appendix 23).
For the Respondent Designed Configuration, provide the initial
hardware and software pricing as well as ongoing maintenance and
support pricing (spanning 3 years) for the infrastructure. The
Respondent shall also provide the timing of when the hardware and
software will be needed. The ongoing maintenance and support
pricing as well as timing shall be in the format included as a
separate file on the Electronic State Business Daily (Attachment
N)
1.2. What is the Respondent’s strategy (roadmap) for upgrading
their product (end-of-
life strategy) and how will Respondent manage these upgrades during
the course of the LOB system replacement project?
1.3. Provide Respondent’s historical perspective, based on previous
clients, as to
what percentage of the hardware and software will need to be
refreshed and when (during the course of the Project and on-going
maintenance as well).
1.4. How do clients customize and extend the system and how are
those
customizations preserved across system upgrades?
1.5. Given TRS’ performance expectations stated in the Section II.,
Technical Solution, 16. Warranty, below and Section IV., 1.7 -
Warranty provide the recommended processor, memory and storage
requirements for each of the system’s components.
1.6. Describe the disk and storage infrastructure requirements
(e.g., disk speeds,
storage fabric), overall I/O architecture requirements, and any I/O
performance characteristics that are critical to the system’s
performance. This shall include current and projected capacity and
known limitations of different storage solutions.
Page 33 of 375
1.7. What solutions has the Respondent used and what lessons have
they learned from their storage decisions?
1.8. Describe any special network considerations such as
non-standard protocols or
bandwidth requirements.
3. Scalability and Redundancy
1.1. Describe in detail how the system scales at each layer of the
architecture. 1.2. What methods are commonly used to provide fault
tolerance across web,
application, database and integration tiers?
4. Virtualization
1.1. Is the solution validated on vSphere 5?
1.2. Identify any components that would not be suitable for server
virtualization and the rationale behind that recommendation.
1.3. What known limitations, if any, exist when the Respondent’s
solution is running
on virtualized servers in a VMware vSphere environment?
1.4. What other environments has the Respondent used with the
Respondent’s solution (e.g., z/VM)?
5. Non-Production Environments
1.1. Describe what non-production environments (e.g., Development,
Test, QA) the
Respondent recommends having deployed for:
• The Project development cycles (pre-production Project
activities) • The post-production lifecycles and management
1.2. What are the recommended server configurations (number and
types of servers)
for those environments?
1.3. Provide pricing estimates for these environments including
hardware and software pricing in the format included as a separate
file on the Electronic State Business Daily (Attachment N). This
shall include an itemized list of any 3rd party software or tools
used in non-production environments to develop, test, monitor or
support the Respondent’s solution.
6. Software Architecture
1.1. Describe the software architecture for the Respondent’s
solution and include an
architecture diagram, listing the individual software components
that make up the Respondent’s architecture.
1.2. Describe the logical and physical architectures, Provide
architecture diagrams.
Page 34 of 375
1.3. Describe the client-side software requirements and how any
client-side requirements are deployed and updated.
1.4. Which components of the Respondent’s framework are tightly
coupled?
1.5. How does the Respondent’s solution implement a Service
Oriented Architecture?
1.6. Describe the Respondent’s experience in using an Enterprise
Service Bus (ESB)
for communications between applications. If the Respondent does not
have experience implementing an ESB, how would the Respondent
envision an ESB could work with the Respondent’s solution for
integration?
1.7. What application development frameworks are used in the
Respondent’s
solution?
1.8. What services of the Respondent’s solution are published or
exposed for use by other applications? And how are these services
exposed?
1.9. When Respondent integrates with third-party applications does
the Respondent
write directly to their API(s)?
1.10. Please provide a list of the Respondent’s documented API(s).
1.11. Please describe how information about the Respondent’s Web
services would be
exported to an external service registry.
1.12. Describe how the Respondent’s solution supports the messaging
style of integration as described in the publication Enterprise
Integration Patterns: Designing, Building, and Deploying Messaging
Solutions (Messaging – p. 53).
7. Software Updates and Support
1.1. How frequently are updates to the Respondent’s solution
available?
1.2. What is the Respondent’s current software upgrade
strategy?
1.3. On previous engagements how did the Respondent handle major
scope changes
(e.g., Legislative changes)?
1.4. Historically how often does the Respondent roll out patches
and maintenance releases during the entire length of a
project?
1.5. What type of remote support is provided for Respondent’s
solution? 1.6. Describe the Respondent’s process by which TRS would
access support?
1.7. What is the estimated response time to a service call?
1.8. Who is responsible for a problem whose cause is unknown?
8. Data Management and Reporting
Page 35 of 375
1.1. What databases does the Respondent recommend and what
databases are supported by the Respondent’s solution?
1.2. What reporting package(s) does the Respondent use? Which is
the
Respondent’s preference?
1.3. TRS is using another contractor to manage the data cleansing
process. Describe how the Respondent has worked with data
management contractors in the past and how the Respondent would
interface with TRS’ data management contractor on this
Project.
9. Usability and Interface
1.1. What type of usability design and testing has been performed
for the
Respondent’s solution? Please provide an example of the results of
these tests.
1.2. Provide a copy of the Respondent’s user interface
guidelines.
1.3. Does the Respondent perform their own internal Web
accessibility testing? If yes, describe the process and the
results. If no, describe how the Respondent ensures their
application is Web accessible. Does the Respondent use WCAG 2.0 or
Section 508 standards for testing?
10. Integration
1.1. Describe how the Respondent’s software integrates with
existing enterprise
applications. Is it service-oriented?
1.2. How does the Respondent’s solution support and interface with
FileNet P8 for imaging?
1.3. Does the Respondent’s solution support Content Manager on
Demand?
1.4. Has the Respondent implemented integrations with Adobe
LiveCycle for
correspondence and forms management? Describe briefly how that
integration works.
1.5. Describe how the Respondent’s solution interfaces with
third-party financial
applications? Which applications has the Respondent integrated
with?
1.6. Describe how the Respondent’s solution integrates with
Microsoft Exchange for sending and receiving email?
1.7. How does the Respondent’s solution handle attachments to
email?
1.8. How does the Respondent’s solution ensure that mass emails are
handled
appropriately and do not become blacklisted?
1.9. How does the Respondent’s solution handle creation and sending
of SMS text messages?
Page 36 of 375
1.10. TRS requires address validation. How does the Respondent’s
solution handle address validation? TRS currently uses FINALIST for
address validation. How would the Respondent envision integrating
with FINALIST?
1.11. How does the Respondent’s solution handle attachments that
are sent out and
stored when generated out of the LOB system?
11. Disaster Recovery/Business Continuity
1.1. What recommendations and considerations does the Respondent
have for disaster recovery and business continuity efforts for the
Respondent’s solution?
12. Telephony
1.1. Describe how the Respondent’s system integrates with telephony
systems
including telephone switches (TDM and VoIP), IVR, Contact
Management System, and Fax Servers.
1.2. Describe how the Respondent’s system provides screen pop and
other
capabilities for inbound and outbound member interactions including
telephone, callback, chat, fax, and email. Provide a listing of
available API’s, web services and technologies the system uses to
interface with telephony systems,
1.3. Has the Respondent’s system been integrated with the following
telephony
products: Siemens Hipath 4000 telephone system, OpenScape Voice
Portal IVR, OpenScape Contact Center, and Faxination Fax
Server?
13. Software Development Information
1.1. Describe the components or modules in the Respondent’s
software and their
dependencies. What modules are required? Which are optional?
1.2. What programming languages is the system written in? Do
clients have access to its source code?
1.3. Describe the Respondent’s approach to licensing non-production
environments
(e.g., Dev, Test, QA, and DR).
1.4. Describe the solution’s ability to react to, participate in
and trigger external workflows.
1.5. Describe the solution’s ad hoc and batch reporting
capabilities and any facilities
to extract data to various formats. How does the system integrate
or interact with external reporting tools?
1.6. Describe how the Respondent’s software conforms to the open
industry
standards.
1.7. Describe how the solution handles business rules, how they are
expressed and how they are stored.
Page 37 of 375
1.8. Describe the error logging and error codes for the
Respondent’s solution including the types of errors that are logged
and how those logs are stored. Include specific error log utilities
that the Respondent’s solution uses for interactive and batch use.
How do developers use these error codes and utilities to
troubleshoot and maintain the actual program code?
1.9. Describe how extensive the user, administration and de