THE following document is published with and form part of ... · [email protected]. STATUTORY INSTRUMENTS. THE following document is published with and form part of this . Gazette:

Saint Lucia Government Gazette1101Issue 48 Monday December 2, 2013

Government Of Saint Lucia

Ministry of Sustainable Development, Energy, Science and

Technology

Post of Administrative Assistant –

Third National Communications

AN Administrative Assistant (AA) will provide assistance to the National Project Coordinator to facilitate smooth implementation of the project. The AA will be recruited by EA. Her/his involvement in previous activities under Climate Change is a major precondition. The AA will work on a full-time basis and perform the following duties:

Perform other project-related duties as requested by National Project Coordinator. Ensure that there is proper accountability of project funds

Prepare the expenditure statements in line with the UNEP budget code;

Prepares quarterly financial statement

Qualifications:

A university degree in economics or environmental management

A minimum of 3 years of relevant experience in a field related to climate change.

Work experience with international organizations

Knowledge of computers and world processing

He/ she must have worked on a climate change related activities.

Duty Station:

The project office will be housed at the offices of EA.

Duration: 3 years

Interested persons are asked to submit their CVs to the Sustainable Development and Environment Division no later than December 4 2013.

Duties:

To assist the National Project Coordinator in managing the project activities.

Assist the NPC in allocation and re-allocation of the project funds and in controlling the project expenditures.

Assist the NPC in preparing a work plan

Assist the NPC in preparing the quarterly progress report of the project

Facilitate the process of recruitment of the project personnel (draft terms of reference and vacancy announcement, arrangement of interview, maintenance of roster of national consultants, preparation of recruitment package, etc.)

Arrange purchasing of office equipment for the project purposes on a competitive basis. Maintain inventory of non-expendable equipment.

Provide substantial support to the project workshops and trainings. Attend, whenever possible, regional and international trainings relevant to climate change.

Set up and maintain the project filing system.

Provide general administrative support to project activities.

[email protected]

VA

CA

NC

YN

OT

ICE

[email protected]

STA

TU

TO

RY

IN

STR

UM

EN

TS

THE following document is published with and form part of this Gazette:

Statutory Instrument

No. 79 of 2013 — Eastern Caribbean Civil Aviation Agreement Act (Commencement) Order.

No. 80 of 2013 — Financial Services Regulatory Authority (Amendment of Schedules 1 and 3) Order.

Saint Lucia Government Gazette 1102 Issue 48 Monday December 2, 2013


Ministry of Sustainable Development, Energy, Science

and Technology

Post Of Part-Time Accountant –

Third National Communications

AN Accountant will be recruited to work on a part-time basis. The Accountant will work under the direct supervision of the NPC and in cooperation with AA. The responsibilities of the Accountant will be:

Execute the work of book keeping

Track payment/invoices/receipts

and reconcile all expenditures of funds Ensure proper accountability of funds

Prepare the expenditure statements in line with the UNEP budget code

Advise on the proper utilization of funds and sign on the accuracy of the expenditures along with the NPC

Qualifications

A university degree in accounting/economics/management

A minimum of three years of working experience with international agencies

Knowledge of computers and be able to work with Micro Soft Excel 2003 and Microsoft Word

Excellent of national language

Duty Station:

The project office will be housed at the offices of EA.

Duration:

According to the project work plan and terms of reference.

Interested persons are asked to submit their CVs to the Sustainable Development and Environment Division no later than December 4 2013.

[email protected]

NO

TIC

ES

Notice of Company in Dissolution

(International Business Companies Act, Cap.12.14: Section 94(4))

ALPHA FINANCE LIMITEDNo.: 2005 - 00082

TAKE NOTICE that the International Business Company, Alpha Finance Limited, No. 2005 - 00082 which was incorporated on

February 09, 2005 has registered its articles of dissolution.

TAKE NOTICE that dissolution of the above named company commenced on 25th November, 2013 and that the name and address of the liquidator is as follows:

Nicholas JohNCap EstateGros IsletST. LUCIA

Dated this 25th day of November, 2013.

Lester D. MartyrRegistrarInternational Business Companies

Public Service Board of Appeal

TAKE NOTICE that ALL correspondence to the Public Service Board of Appeal should be addressed to:

The SecretaryPublic Service Board of Appealc/o Ministry of Legal AffairsBrazil StreetCastries

Invitation for Bids (IFB)

Government of Saint Lucia

Hurricane Tomas Emergency Recovery Project

IDA Credit 48710 –SLUReplacement of Damaged Items

– Procurement of Appliances

Date: November 13, 2013Contract Identification No:

NCBBIDDING DOCUMENT SLU HTERP / NCB: G POA- 01-13

World Bank Loan/Credit No: IDA Credit 48710 - SLU

World Bank Loan/Credit Name: Saint Lucia Hurricane Tomas

Emergency Recovery Project

THIS invitation for bids follows the General Procurement Notice for this Project, which appeared in Development Business on June 29, 2011.

Saint Lucia has received a Credit from the World Bank towards the cost of Hurricane Tomas Emergency Recovery Project and intends to apply part of the funds to cover eligible payments under the Contract for Replacement of Damaged Items – Procurement of Appliances. Bidding is open to all bidders from eligible source countries as defined in the


Guidelines: Procurement under IBRD Loans and IDA Credits. Saint Lucia invites sealed bids from eligible bidders for the Replacement of Damaged Items – Procurement of Appliances.

Bidding will be conducted through the National Competitive Bidding (NCB) procedures specified in the World Bank’s Guidelines: Procurement under IBRD Loans and IDA Credits, dated May 2004, revised October 2006, and May 2010, and is open to all eligible bidders as defined in the guidelines.

Saint Lucia now invites sealed bids from eligible bidders for the supply of the following:

Gas Stove, Industrial SS, 36”W 18

Gas Stove, Floor Level Grill, 30”W 2

Chest Freezer, 15 Cu.Ft 8

Fridge Freezer 12Cu. Ft./13 Cu. Ft 3

Post Qualifications requirementsinclude:

Bidder must have experience in the field of manufacturing and or supply of goods similar to the goods in the bid for a period of at least three years prior to the deadline for bid submission.

If the bidder is a Joint Venture (JV), the member in charge should meet these requirements.

The Bidders shall submit reference lists for not less than one (1) successfully completed similar contract during the last three (3) years, for supply of appliances.

If the bidder is a Joint Venture (JV), all members should jointly meet all qualification requirements and the member in charge should have at least one successfully completed similar contract during the last four years for supply of appliances.

More details about all requirements related to the Evaluation and Qualification criteria are specified in the Section III of the Bidding Documents and information on the Supply Requirements are specified in Section VI of the Bidding Documents.

Bidding documents may be collected at the Project Coordination Unit, Ministry of Finance, Economic Affairs, Planning and Social Security, 5th floor Conway Business Centre, Waterfront, Castries, Saint Lucia.

Interested bidders may inspect the Bidding Documents and obtain further information at the address below (*) from November 13, 2013 from 0900 hours (9:00am) to 1500 hours (3:00 pm) daily from Monday to Friday.

Bids shall be delivered to the address below (**) on or before December 11, 2013 at 12:00 p.m. (1200 hours) and shall be valid for a period of 90 days after bid submission. Late bids will be rejected. Bids will be opened in the presence of the bidder’s representatives who choose to attend at the address below (***) on December 11, 2013 at 2:00 p.m. 1400 hours.

All bids are to be accompanied by a Bid Securing Declaration to be submitted in the format stipulated in the Bidding Document.

The address(es) referred to above are:

* The Project Coordinator Hurricane Tomas Emergency Recovery Project Ministry of Finance, Economic Affairs, Planning and Social Security 5th Floor, Conway Business Centre Waterfront Castries, Saint Lucia Telephone: 758-468-5814/5 Fax: 758-453-0417 Email: [email protected]

** The Secretary (Submission of Bids) Central Tenders Board Ministry of Finance 2nd floor Financial Centre Bridge Street Castries, Saint Lucia

*** Meeting of the Central Tenders Board Central Tenders Board Ministry of Finance 2nd floor Financial Centre Bridge Street Castries, Saint Lucia

To All Agents And Suppliers

Tenders For The Supply Of Wheat Flour To The


THE Government of Saint Lucia through the Ministry of Commerce, Business Development, Investment and Consumer Affairs is inviting tenders for the supply of Wheat Flour for the period February 2014 to January 2015. The required specifications are shown hereunder:

Characteristics Moisture content

Requirements not more that 15%

Characteristics Ash content:

Requirements not more that 1.2% before adding inorganic matter

Characteristics Protein content:

Requirements 12.0 - 13.5%

Packaging Requirements

Wheat Flour shall be packaged in containers that will safeguard the hygienic, nutritional, and Technological characters of the flour, and protect it against contamination or absorption of moisture.

Containers shall be made of materials that are safe and suitable for the purpose, such as bags or sacks made of new cotton cloth, multi-wall paper, strong paper and new plastic film.

Containers shall not contaminate the product by migration of any toxic substance, or give the flour any undesirable odor or flavour.

Labelling Requirements

The labeling on retail packages of flour shall be in the English Language, clearly and prominently displayed, and readily legible under customary conditions of purchase and use.


3-a The information carried on the label shall include the following:

(a) The name of the food, "Flour", "Wheat Flour" or "White Flour"

(b) Any brand name or trade name

(c) The name of the manufacturer or of the person controlling the brand name or trade name, together with an adequate postal address

(d) The name of the country of origin

(e) The net contents of each package when packed in terms of units of mass in grams (g)or kilograms (Kg), (which may also be shown in avoirdupois pounds and ounces) using Arabic numerals

(f) The batch number, date of manufacture, together with expiry date or best before date of minimum durability

(g) Handling and Storage instructions

3-a Where an indication of the type of flour is included on the label, the protein and ash contents of the flour shall be within the limits set out in Table 3 of the compulsory standard for Wheat Flour (SLNS 10: 1992).

Type of FlourAll purpose] General purpose] Protein content 10.5 to 12.0 % Ash Content up to 0.5 %

Type of Flour Biscuit Protein content 8.0 to 9.0 % Ash Content up to 0.45 %

Type of Flour Bread Protein content 12.0 to 13.5 % Ash Content up to 0.5 %

Type of Flour Cake, Pastry Protein content 7.0 to 10.0 % Ash Content up to 0.45 %

Transportation

Wheat Flour shall be shipped containerized in vessels suitable for transporting foodstuffs for human consumption.

Quality Assurance

It is required that Wheat Flour be produced In accordance with the compulsory standard for Wheat Flour (SLNS10: 1992).

Each shipment should be accompanied by a Certificate of Compliance.

A Certificate of Product test results in conformity with the specifications stipulated in the tender notice must be submitted annually.

A Microbiological test report issued by a third party laboratory or a test laboratory within certified facilities must accompany each shipment.

Quantity

Two hundred thousand (200,000) bags of flour or a part thereof in monthly shipments to be agreed between the Supplier and Buyer for a period of twelve (12) consecutive months, commencing February 2014 to January 2015.

Weight

Flour must be packed in strong bags of not more that 50 kg or 110 pounds.

Insurance

Insurance coverage must provide for settlement of entire amount of lawful claims.

Payment Terms

60 - 90 days at sight.

All quotations (CLF) and credit facilities must be forwarded to the Secretary, Central Tenders Board,

Ministry of Finance to reach no later than 4:00 p.m. on Tuesday, December 10, 2013.

All quotations are binding for the period covered by the Tender Notice.

Envelopes are to be sealed and clearly marked "Confidential - Tenders for Wheat Flour" and to be sent to:

The SecretaryCentral Tenders BoardMinistry of Finance 2rd Floor, Financial CentreBridge Street, CastriesSAINT LUCIA

Faxed Tenders will not be considered.

The Ministry Does Not Bind Itself To Accept The Lowestor Anytender.

Leo Titus PrevillePermanent Secretary

Tender Notice

To All Agents And Suppliers

Tenders For The Supply of Milled Parboiled Rice To The


THE Government of Saint Lucia through the Ministry of Commerce, Business Development, Investment and Consumer Affairs is inviting tenders for the supply of Parboiled (Medium) Rice for the period January 2014 to December 2014. The required specifications are shown hereunder:

Classification

The Rice shall be classified as Grade A Long Grain Rice.

Rice with 80% or more of kernels after milling to a well- milled degree, having a length of at least 6.67 mm and a length/width ratio of over 3.0.

General Organoleptic and Health Characteristics

Rice shall be safe and suitable for human consumption. Rice shall


be free from abnormal flavours, colours, living or dead insects, insect fragments and mites.

The product shall be prepared and handled in accordance with the appropriate sections of the Codex Alimentarius Commission, CAC/RCP 1 - 1969 General Principles of Food Hygiene (Adopted 1969, Amendment 1999, Revision 1997 and 2003).

Rice shall comply with the maximum residue limits for pesticides established by Codex Alimentarius Commission. Pesticide Residues in Food and Feed, commodity details GC 0649 - Rice.

The products shall be free of heavy metals in amounts which may represent a hazard to human health. Concentration of arsenic shall be declared.

Grade RequirementsTable 6 - Requirements of Milled Parboiled Rice

(All values are maximum except where otherwise indicated)

FACTORS Grade A (%)

Moisture Content 14.0Paddy 0.1Broken Kernels 6.0Damaged Kernels 1.0(SingIy or Combined)Non - Gelatinised Kernels 0.2Red Straited Kernels 1.0Total Foreign matter 0.2Organic 0.2Inorganic 0Colour*

*Colour classification applicable to all grades (Kett whiteness meter) Parboiled medium meter reading of 20.0 - 25.9

Category of RiceParboiled MediumPackaging and LabelingRequirements The packaging shall not transmit any smell or taste and shall not contain substances which may

damage the product or constitute a health risk. New, clean sufficiently strong and machine stitched bags shall be used. Labeling on each packages of Rice shall be in the English Language, clearly and prominently displayed, and readily legible under customary conditions of purchase and use.4-a The information carried on the label shall include the following:(a) The name of the food, Parboiled

Rice(b) Any brand name or trade name(c) The name of the manufacturer

or of the person controlling the brand name or trade name, together with an adequate postal address

(d) The name of the country of origin

(e) The net contents of each package when packed in terms of units of mass in grams (g) or kilograms (Kg), (which may also be shown in avoirdupois pounds and ounces) using Arabic numerals

(f) The batch number, date of manufacture, together with expiry date or best before date of minimum durability

(g) Handling and Storage instructions4-a When the optional ingredient butylated hydroxy toluene, is added to the rice the label shall have the following statement prominently stated on the label "Butylated Hydroxytoluene added as a preservative" so that the ordinary individual may understand.

Transportation Parboiled Rice shall be shipped containerized in vessels suitable for transporting foodstuffs for human consumption.

Quality Assurance It is required that Parboiled Rice be produced in accordance with the compulsory standard for Rice (SLNS 69: 2003).

Each shipment should be accompanied by a Certificate of Compliance.

A Certificate of Product test results in conformity with the specifications stipulated in the tender

notice must be submitted annually or when origin of supply changes.

A Microbiological test report issued by an accredited third party laboratory whose scope includes the parameters listed below. must accompany each shipment. Microbiological test report should include the following parameters:

a) Mouldb) Yeastc) Aerobic Plate Countd) Coliform counte) E.coli

Quantity Fifty-two thousand, eight hundred (52,800) bags of Parboiled Rice in monthly shipments to be agreed between the Supplier and Buyer for a period of twelve (12) consecutive months, commencing January 2014.

Weight The Rice must be packed in strong bags of not more that 50 kg or 110 pounds.

Insurance Insurance coverage must provide for settlement of entire amount of lawful claims.

Payment Terms 60 - 90 days at sight.

All quotations (C.I.F) and credit facilities must be forwarded to the Secretary, Central Tenders Board, Ministry of Finance to reach no later than 4:00 p.m. on Tuesday, December 10, 2013. All quotations are binding for the period covered by the Tender Notice.Envelopes are to be sealed and clearly marked "Confidential - Tenders for Parboiled Rice" and to be sent to:

The SecretaryCentral Tenders BoardMinistry of Finance2nd Floor, Financial CentreBridge Street, CastriesSAINT LUCIA

Faxed Tenders will not be considered.

The Ministry Does Not Bind Itself To Accept The Lowest Or Any TenderLeo Titus PrevillePermanent Secretary


[email protected]

TR

AD

EM

AR

KS

AP

PL

ICA

TIO

N

File No (210): TM/2013/ 000067

Mark name: TAKTEK

Applicant (730): Mattel, Inc. (a Delaware Corporation)

Filing date (220): 09/04/2013

Class (511): 16 (Paper, cardboard and goods made from these materials, not included in other classes; printed matter; bookbinding material; photographs; stationery; adhesives for stationery or household purposes; artists' materials; paint brushes; typewriters and office requisites (except furniture); instructional and teaching material (except apparatus); plastic materials for packaging (not included in other classes); printers' type; printing blocks.)

25 (Clothing, footwear and headgear not included in other classes.)

28 (Games and playthings; gymnastics and sporting articles not included in other classes; decorations for Christmas trees.)

Agent: Gordon, Gordon & Co

TAKTEK

File No (210): TM/2013/ 000128

Mark name: THE HOME DEPOT

Applicant (730): Home TLC Inc.

Filing date (220): 15/05/2013

Class (511): 35 (Retail home improvement stores.)

37 (Installation and repair services relating to home improvement projects; installation and maintenance of household appliances, home furnishings and home improvement items; paint mixing and computer paint mixing services; Rental of construction equipment; Rental of floor cleaning machines; Rental of gas or air compressors; Rental of hand and power tools; Technical consultation in the field of building construction; Technical advice related to building construction in the nature of home improvement projects; Consultation in the fields of construction, repair, maintenance and installation in the field of home improvement projects and landscaping and gardening.)

39 (Delivery and transportation of goods by truck and motor vehicle namely, home improvement and gardening products, furnitutre, building supplies, electrical supplies, automtovie supplies, outdoor power equipment, paints, lacquers, varnishes and sundries, plumbing supplies, sanitary ware and sporting goods; storage and packaging services.)

42 (Interior decorating consulation.)

44 (Landscape gardening design for others.)

Agent: Nicholas John & Co.


File No (210): TM/2013/ 000129

Mark name: THE HOME DEPOT

Applicant (730): Homer TLC Inc.

Filing date (220): 15/05/2013

Class (511): 35 (Retail home improvements stores.)

37 (Installation and repair services relating to home improvement projects; Installation and maintenance of household appliances, home furnishings and home improvement items; paint mixing and computer paint mixing services; Rental of construction equipment; Rental of floor cleaning machines; Rental of gas or air compressors; Rental of hand and power tools; Technical consultation in the field of building construction; Technical advice related to building construction in the nature of home improvement projects; Consultation in the fields of construction, repair, maintenance and installation in the field of home improvement projects ad landscaping and gardening.)

39 (Delivery and transportation of goods by truck and motor vehicle namely, home improvement and gardening products, furniture, building supplies, electrical supplies, automotive supplies, outdoor power equipment, paints, lacquers, varnishes and sundries, plumbing supplies, sanitary ware and sporting goods; storage and packaging services."s, plumbing supplies, sanitary ware and sporting goods; storage and packaging services)

42 (Interior decorating consultation .)

44 (Landscape gardening design for others.)

Agent: Nicholas John & Co.

THE HOME DEPOT



NOTICE OF APPLICATION OF SPECIAL SITTING

FOR LIQUOR LICENCE

NOTICE is hereby given that pursuant to Section 7 of the Liquor Licensing Act Cap 13.17 as amended: there will be a Special Sitting of the Liquor Licensing Board on Tuesday December 3rd 2013 at 10:30 a.m. to hear and determine applications for Liquor Certificate granted at the Special Licensing Board Sitting.

Any person who desires to file a Notice of objection to the granting of the Liquor License to any applicant is hereby granted to lodge his/her objection at the First District Court by 29th November 2013, stating the grounds of the objection.

Forms are available at the First and Second District Courts.

NOTICE is hereby given that the pursuant to Section 7 of the Liquor Licensing Act cap 13.17 as Amended; there will be a Special sitting of the Liquor Licence Board on Tuesday 3rd December 2013 at 10:30 a.m. to hear and determine applications for liquor from the following applicant(s)

Name of Address Proposed place of Type of Business Applicant business

Danilla Nyva White La Pansee Road Pointe Seraphine Ref. House

Any person who desires to file-a Notice of Objection to the granting of the Liquor Licence to any of the above-mentioned applicants are hereby required to lodge his/her objection at the First or Second District Courts by Friday, November 29th 2013, stating the grounds of the objection.

Forms are available at the First and Second District Courts.

Chairperson Liquor Licence Board


VEHICLE FOR TENDER

Ministry Of Agriculture, Food Production, Fisheries And Rural Development

Vehicle No. Make Model Year Location Of Vehicle

SLG 601 MITSUBISHI PAJERO 1995 Willa's Garage in Marchand

SLG 745 ISUZU SINGLE CAB 1998 Prio's Garage in Corinth PICKUP

Forms can be picked up at the Department of Finance, Economic Affairs and Social Security, 2nd Floor, Financial Centre Building, Bridge Street Castries.

Vehicles can be inspected at the location mentioned above.

Deadline for submission of tender is December 10, 2013 at 4:00p.m.


IN THE EASTERN CARIBBEAN SUPREME COURT

IN THE HIGH COURT OF JUSTICE(CIVIL)

SAINT LUCIA

CLAIM No. SLUHCV 2011/1124

BETWEEN: (1) LEO ALEXANDER

Claimant

and

(1) FREDERICK PROSPERE (2) CLARENCE RAMBALLY (3) JENNIFER REMY (4) MORGESTA BENJAMIN (5) JOSEPH ACTIE

Defendants

TO: (1) CLARENCE RAMBALLY (2) MORGESTA BENJAMIN (3) JOSEPH ACTIE

NOTICE

TAKE NOTICE that an action has been commenced against you in the High Court of Justice Saint Lucia High Court Suit Number SLUHCV2011/1124 by LEO ALEXANDER, in which the Claimant claims damages for loss of bargain in relation to an agreement to purchase land more particularly described as Block 1257 B Parcel 257 and declarations as regards the Defendants (2) CLARENCE RAMBALL Y, (3) JENNIFER REMY, (4) MORGESTA BENJAMIN and (5) JOSEPH ACTIE regarding their interest in relation to the said land.

AND THE CLAIMANT has filed an application within this suit for an order of judgment against you.

AND service of this application is being effected on you by this advertisement in two consecutive issues of the local newspaper circulating in the island of St. Lucia and two (2) consecutive issues of the Official Gazette.

AND the Notice of Application and all other supporting documents can be viewed at the High Court Office at Peynier Street, Castries, St. Lucia or at the offices of Fraser & Co., #35 Chisel Street, Castries, St. Lucia from 8:30am-4:30pm.

IF you DESIRE TO defend this application, you must within 28 days of the last publication of this advertisement file an Affidavit in Reply at the Registry of the High Court of Justice, Peynier Street, Castries.

IN DEFAULT of filing of such Affidavit in Reply within the time stipulated, the Court may hear the Application in your absence and without further notice enter an order for judgment against you and make any order it deems fit. Dated this 19th day of November, 2013.

Fraser & Co.Legal Practitioners for the Petitioner

Per:Horace Fraser

This Court Office is at Peynier St., Castries, Saint Lucia, Telephone No. (758) 453·1916, Fax No.(758) 453·1917 email address stlueccourts.or. The Office is open between 9:00am and 2:00pm Monday to Friday except public holidays. This Notice is being filed by: Fraser & Co., Chambers, 35 Chisel Street, Castries, Saint Lucia, Telephone: (758) 459·0226/7, Fax: (758) 459·0229, email: [email protected].

[ First Publication ]




SAINT LUCIA


BETWEEN: (1) JOSEPH BADEN ALLAIN

Petitioner

and

(1) SYLVESTER AUGUSTERespondent

TO: (1) SYLVESTER AUGUSTE whose last known address is Soufriere, St. Lucia

NOTICE

TAKE NOTICE that an action has been commenced against you in the High Court of Justice Saint Lucia High Court Suit Number SLUHCV2007/0554 by JOSEPH BADEN ALLAIN, in which the Petitioner seeks an order for Bankruptcy against you in accordance with Article 544(g) for your failure to satisfy the judgment debt in the sum of $6,300.

AND IT HAS BEEN ORDERED that service of notice of the Petition for Bankruptcy be effected on you by this advertisement in two consecutive issues of the local newspaper circulating in the island of St. Lucia and two (2) consecutive issues of the Official Gazette.

AND the Petition for Bankruptcy and all other supporting documents can be viewed at the High Court Office at Peynier Street, Castries, St. Lucia or at the offices of Fraser & Co., #35 Chisel Street, Castries, St. Lucia from 8:30am-4:30pm. IF YOU DESIRE TO defend this action, you must within 28 days of the last publication of this advertisement file an Affidavit in Reply at the Registry of the High Court of Justice, Peynier Street, Castries.

IN DEFAULT of filing of such Affidavit in Reply within the time stipulated, the Court may hear the Petition for Bankruptcy in your absence and without further notice make an order declaring you bankrupt and appointing a receiver to liquidate your property. Dated this 4th day of November, 2013.

Fraser & Co.Legal Practitioners for the Petitioner

Per:Horace Fraser

This Court Office is at Peynier St. Castries, Saint Lucia, Telephone No. (758) 453·1916, Fax No.(758) 453·1917 email address stlueccourts.or. The Office is open between 9:00am and 2:00pm Monday to Friday except public holidays. This Notice is being filed by: Fraser & Co., Chambers, 35 Chisel Street, Castries, Saint Lucia, Telephone: (758) 459·0226/7, Fax: (758) 459·0229, email: [email protected].

[ First Publication ]



IN THE HIGH COURT OF JUSTICESAINT LUCIA


BETWEEN: (1) FIRST CARIBBEAN INTERNATIONAL FINANCE CORPORATION (LEEWARD AND WINDWARD) LIMITED formerly BARCLAYS FINANCE CORPORATION OF THE LEEWARD AND WINDWARD ISLANDS LIMITED

Claimant

and

(1) RANDOLPH TIMAITRE (2) EUGENIA TIMAITRE Of Castries, Saint Lucia

Defendants

TO: (1) RANDOLPH TIMAITRE (2) EUGENIA TIMAITRE whose last known registered address was Castries, Saint Lucia

NOTICE

TAKE NOTICE that in the action herein the Claimant filed a Writ of Execution for seizure and sale of your property viz. Block 1250B Parcel 625 together with an Application to fix an upset price of $440,000.00 for same which was granted by the Court on 5th October, 2011. The Claimant has filed another application for a new upset price of $558,000.00 to be fixed based on a fresh valuation of 2012 thereby revoking the prior upset price .The application comes up for hearing on Wednesday 12th February, 2014 at 9.00 a.m. at the High Court of Justice, Castries, Saint Lucia

AND service of the said Application is being effected upon you by advertisement in two consecutive issues of the local Newspaper circulating in St. Lucia and two consecutive issues of the Official Gazette.

The Application can be viewed at the High Court Office at Peynier Street, Castries, Saint Lucia or at the Chambers of McNamara & Co., 20 Micoud Street, Castries, Saint Lucia

Dated this 21st day of November, 2013.

McNAMARA & CO. Legal Practitioners for the Claimant

Per: Zinaida C McNamara

[ Second Publication ]




SAINT LUCIA


BETWEEN: (1) BENNET PETER also known as BENNETTE PETER Praslin, Micoud

Claimant

and

(1) MAURICE JEAN BAPTISTE Ravineau, Choiseul (2) CHAD BAPTISTE (3) CHARDEN BAPTISTE

Defendants

TO: (1) MAURICE JEAN BAPTISTE

NOTICE

TAKE NOTICE that the Claimant in this matter has applied to the High Court of Justice for Assessment of Damages in the instant Claim.

SERVICE is hereby being effected upon you (pursuant to Rules 6.1, 6.2 and 5.13 of CPR 2000), via two consecutive advertisements in a newspaper circulating in Saint Lucia and the Official Gazette; of the Notice of Application, Affidavit in Support and Certificate of Exhibits.

IF YOU DESIRE to participate in the Assessment of Damages, you may file an Affidavit in Answer at the Court Office, Peynier Street, Castries and attend the hearing which is set for the 30th day of January, 2014 at the said High Court. Even though you do not file an Affidavit in Answer, you are entitled to attend the hearing and make oral representations.

If you fail to file an Affidavit in Answer or attend the hearing of the Assessment, the Court may deal with the matter in your absence.

Dated this 14th day of November, 2013.

Lydia B. Faisal Legal Practitioner for the Claimant

The court office is at Peynier Street Castries Saint Lucia. Telephone number 453·1916 Fax 453·2071. The Office is open between 9:00 am and 2:00pm Mondays to Thursdays and 9:00am to 3:00pm on Fridays except Public Holidays. The Office can also be contacted via Email at [email protected] Claimant's address for service is: Lydia B. Faisal's Chambers. NO.12-16 Lamar Building. 1 sf Floor. Suite No.4, Bridge Street. Castries, Saint Lucia. Tel: (758) 451-7773/8883, Fax 451-7373, Email: [email protected].




IN THE HIGH COURT OF JUSTICE

NOTICE FOR APPEARANCE OF HEIRS

SAINT LUCIA

CLAIM No. SLUHPB 2013/0082

IN THE MATTER of an application for a Grant of Letters of Administration in the Intestate Succession of the Late VICTOR MORTLEY

and

IN THE MATTER of Article 586(3) of the Civil Code and Article 1013 to 1022 of the Code of Civil Procedure Chapters 242 and 243 respectively of the Revised Laws of Saint Lucia 1957.

NOTICE

TAKE NOTICE that a Petition has been filed in the High Court of Justice (Saint Lucia) Claim Number SLUHPB2013/0082 by URISIA MORTLEY for Letters of Administration to be issued in respect of the Estate of the deceased VICTOR MORTLEY a single man in his lifetime of Maynard Hill, Castries, Saint Lucia.

ANY PERSON who is an heir of the said VICTOR MORTLEY or who claims a share or interest in his Estate must, within 28 days of the date of the last publication of this notice which is being advertised in two consecutive issues of this paper, make an appearance at the Registry of the High Court of Justice at Peynier Street in the City of Castries.

Dated this 21st day of November, 2013.

Charles Mangal and Paul Per

Legal Practitioner

Presented for filing by CHARLES MANGAL & PAUL, of No. 24 Bridge Street, Castries and who can be contacted at Telephone Number (.758) 4571056, at Fax (758) 4571057 or at e-mail [email protected]. The court office is situate at Peynier Street, Castries, Saint Lucia, and can be contacted at telephone (758) 4531916, fax (758) 4532071, or at e-mail address [email protected]. The court office is open between 9.00 am and 2.00 p.m. Mondays to Thursdays and 9.00 am to 3.00 p.m. on Fridays except public holidays.



SAINT LUCIA

DECLARATION OF ACQUISITION PURSUANT TO SECTION 3 OF THE LANDACQUISITION ORDINANCE (CHAPTER 5.04)

and

IN THE MATTER of a Declaration by the Governor General acting on the advice of Cabinet that Parcel 168 of Block 1048C situate at Morne Du Don in the Quarter of Castries in the island of Saint Lucia are likely to be acquired for a public purpose.

DECLARATION OF ACQUISITION OF LAND

Whereas, it is enacted by Section 3 of the Land Acquisition Ordinance Chapter 5.04 that if the Governor General acting on the advice of Cabinet considers that any land should be acquired for a public purpose, she may cause a Declaration to that effect to be made.

And Whereas, it is considered by the Governor General acting on the advice of Cabinet that the lands mentioned and described in the Schedule hereto should be acquired for a public purpose to wit: Additional Land for Rationalization and Housing.

Now Therefore, it is hereby declared by the Governor General acting in accordance with the advice of Cabinet, that upon the Second Publication of this Declaration in the Gazette, the lands mentioned in the schedule hereto shall be vested absolutely for a public purpose to wit: Additional Land for Rationalization and Housing.

SCHEDULE 1

All that piece of land being Parcel 168 of Block 1048C situate at Morne Du Don, in the Quarter of Castries belonging to Aldrick Walcott, Colville Walcott, Rufus Bryan Edward Walcott and Pamela Hinkson as Trustees for Sale is bounded as follows:

North : By Gordons Ravine and partly Block 1048C Parcel 361

South : By Morne Du Don Road and Block 1048C Parcels 172, 179 and 177

East : By Block 1048C Parcels 177, 176, 169 and 180

West : By Block 1048C Parcels 337 and 165

The whole shown as undemacated on the Land Register of 1048C 168.

Together with any other easements which may be necessary.

Dated this 18th day of November, 2013

Secretary to Cabinet.
